HOUSE AMENDED PRIOR PRINTER'S NOS. 228, 1100, 1478, PRINTER'S NO. 1890 1574, 1661, 1808
No. 5 Session of 1997
INTRODUCED BY THOMPSON, LOEPER, GERLACH, TOMLINSON, SALVATORE, MUSTO, O'PAKE, ARMSTRONG, ROBBINS, WENGER, HART, RHOADES, MOWERY, WOZNIAK, HECKLER, MURPHY, MADIGAN, DELP, EARLL, CORMAN, LEMMOND AND SLOCUM, JANUARY 29, 1997
AS RE-REPORTED FROM COMMITTEE ON APPROPRIATIONS, HOUSE OF REPRESENTATIVES, AS AMENDED, APRIL 20, 1998
AN ACT 1 Amending Titles 62 (Procurement), 1 (General Provisions) and 42 2 (Judiciary and Judicial Procedure) of the Pennsylvania 3 Consolidated Statutes, adding provisions relating to 4 procurement; and making repeals. 5 TABLE OF CONTENTS 6 TITLE 62 7 PROCUREMENT 8 PART I. COMMONWEALTH PROCUREMENT CODE 9 Chapter 1. General Provisions 10 § 101. Short title of part. 11 § 102. Application of part. 12 § 103. Definitions. 13 § 104. General principles of law otherwise applicable. 14 § 105. Determinations. 15 § 106. Public access to procurement information. 16 § 107. Reciprocal limitations.
1 § 108. Recycled materials. 2 Chapter 3. Procurement Organization 3 Subchapter A. Organization of Public Procurement 4 § 301. Procurement responsibility. 5 Subchapter B. Procurement Policy 6 § 311. Powers and duties. 7 § 312. Procurement regulations. 8 Subchapter C. Powers and Duties of Department 9 § 321. Powers and duties. 10 § 322. Specific construction powers, duties and procedures. 11 Subchapter D. Powers and Duties of the Board 12 of Commissioners of Public Grounds and 13 Buildings and the Office of the Budget 14 § 326. Board of Commissioners of Public Grounds and Buildings. 15 § 327. Office of the Budget. 16 Subchapter E. Coordination, Training and Education 17 § 331. Collection of data concerning public procurement. 18 § 332. Advisory groups. 19 Chapter 5. Source Selection and Contract Formation 20 Subchapter A. Definitions 21 § 501. Definitions. 22 Subchapter B. Methods of Source Selection 23 § 511. Methods of source selection. 24 § 512. Competitive sealed bidding. 25 § 513. Competitive sealed proposals. 26 § 514. Small procurements. 27 § 515. Sole source procurement. 28 § 516. Emergency procurement. 29 § 517. Multiple awards. 30 § 518. Competitive selection procedures for certain services. 19970S0005B1890 - 2 -
1 § 519. Selection procedure for insurance and notary bonds. 2 § 520. Supplies manufactured by, and services performed by, 3 persons with disabilities. 4 Subchapter C. Cancellation of Invitations for Bids or 5 Requests for Proposals 6 § 521. Cancellation of invitations for bids or requests for 7 proposals. 8 Subchapter D. Qualifications and Duties 9 § 531. Debarment or suspension. 10 § 532. Prequalification of bidders and offerors. 11 § 533. Security and performance bonds. 12 § 534. Cost or pricing data. 13 § 535. Printing. 14 Subchapter E. Types of Contracts 15 § 541. Approval of accounting system. 16 § 542. Multiterm contracts. 17 § 543. Effective contracts. 18 Subchapter F. Inspection of Plant and Audit of Records 19 § 551. Right to inspect plant. 20 § 552. Right to audit records. 21 Subchapter G. Determinations and Reports 22 § 561. Finality of determinations. 23 § 562. Anticompetitive practices. 24 § 563. Retention of procurement records. 25 § 564. Record of certain actions. 26 Chapter 7. (Reserved) 27 Chapter 9. Procurement of Construction and Design 28 Professional Services 29 § 901. Definitions. 30 § 902. Bid or proposal security. 19970S0005B1890 - 3 -
1 § 903. Contract performance and payment bonds. 2 § 904. Copies of bonds. 3 § 905. Procurement of design professional services. 4 Chapter 11. (Reserved) 5 Chapter 13. (Reserved) 6 Chapter 15. Supply Management 7 § 1501. Definitions. 8 § 1502. Supply management regulations. 9 § 1503. Proceeds from sale or disposal of surplus supplies. 10 § 1504. Exception. 11 Chapter 17. Legal and Contractual Remedies 12 Subchapter A. General Provisions 13 § 1701. Definitions. 14 § 1702. Sovereign immunity. 15 Subchapter B. Prelitigation Resolution of Controversies 16 § 1711. Authority to resolve protests of solicitations or 17 awards. 18 § 1712. Authority to resolve contract and breach of contract 19 controversies. 20 Subchapter C. Board of Claims 21 § 1721. Function of Board of Claims. 22 § 1722. (Reserved). 23 § 1723. (Reserved). 24 § 1724. (Reserved). 25 § 1725. Hearings, decisions and awards. 26 § 1726. Appeals. 27 Subchapter D. Solicitations or Awards in Violation of Law 28 § 1741. Applicability. 29 § 1742. Remedies prior to execution of contract. 30 § 1743. Remedies after execution of contract. 19970S0005B1890 - 4 -
1 Subchapter E. Interest 2 § 1751. Interest. 3 Chapter 19. Intergovernmental Relations 4 § 1901. Definitions. 5 § 1902. Cooperative purchasing authorized. 6 § 1903. Sale, acquisition or use of supplies by a public 7 procurement unit. 8 § 1904. Cooperative use of supplies or services. 9 § 1905. Joint use of facilities. 10 § 1906. Supply of personnel, information and technical 11 services. 12 § 1907. Use of payments received by a supplying public 13 procurement unit. 14 § 1908. Compliance of public procurement units. 15 § 1909. Review of procurement requirements. 16 § 1910. Contract controversies. 17 § 1911. Immunity. 18 § 1912. Investment management agreements. 19 Chapter 21. Small and Disadvantaged Businesses 20 § 2101. Policy. 21 § 2102. Definitions. 22 § 2103. Regulations. 23 § 2104. Duties of department. 24 § 2105. Bonding and progress payments. 25 § 2106. Business assistance offices. 26 § 2107. Report to General Assembly. 27 § 2108. Compliance with Federal requirements. 28 Chapter 23. Ethics in Public Contracting 29 Subchapter A. General Policy and Standards 30 § 2301. Policy. 19970S0005B1890 - 5 -
1 § 2302. General standards of ethical conduct. 2 § 2303. Reporting of breaches of ethical standards. 3 Subchapter B. Specific Standards 4 § 2311. Bonds. 5 PART II. GENERAL PROCUREMENT PROVISIONS 6 Chapter 31. General Provisions 7 § 3101. Application of part. 8 § 3102. Definitions. 9 Chapter 33. Prevention of Environmental Pollution 10 § 3301. Invitations for bids and requests for proposals. 11 § 3302. Additional work. 12 Chapter 35. (Reserved) 13 Chapter 37. Contract Clauses and Preference Provisions 14 Subchapter A. Labor 15 § 3701. Contract provisions prohibiting discrimination. 16 Subchapter B. Motor Vehicles 17 § 3731. Short title of subchapter and general provisions. 18 § 3732. Definitions. 19 § 3733. Police power. 20 § 3734. Contract provisions. 21 § 3735. Payment under contract and action to recover 22 unauthorized payments. 23 § 3736. Penalty. 24 Subchapter C. Used Oil Products <-- 25 § 3741. Preference. 26 SUBCHAPTER C. MASS TRANSPORTATION VEHICLES <-- 27 § 3741. PROCUREMENT OF MASS TRANSPORTATION VEHICLES. 28 SUBCHAPTER D. USED OIL PRODUCTS 29 § 3746. PREFERENCE. 30 Subchapter D E. Guaranteed Energy Savings Contracts <-- 19970S0005B1890 - 6 -
1 § 3751. Short title of subchapter.
2 § 3752. Definitions.
3 § 3753. Contracting procedures.
4 § 3754. Contract provisions.
5 § 3755. Funding.
6 § 3756. Commonwealth contracts.
7 § 3757. Construction.
8 Chapter 39. Construction Contracts Over $50,000 CONTRACTS <--
9 FOR PUBLIC WORKS
10 Subchapter A. Preliminary Provisions
11 § 3901. Application and purpose of chapter.
12 § 3902. Definitions.
13 Subchapter B. General Provisions
14 § 3911. Time for awarding contract.
15 § 3912. Time for executing contract.
16 § 3913. Release of successful bidder.
17 Subchapter C. Retainage
18 § 3921. Retainage.
19 § 3922. Payment of retainage to subcontractors.
20 Subchapter D. Prompt Payment Schedules
21 § 3931. Performance by contractor or subcontractor.
22 § 3932. Government agency's progress payment obligations.
23 § 3933. Contractors' and subcontractors' payment obligations.
24 § 3934. Withholding of payment for good faith claims.
25 § 3935. Penalty and attorney fees.
26 § 3936. Contracts involving Federal aid.
27 § 3937. Certain provisions unenforceable.
28 § 3938. Applicability.
29 § 3939. Claims by innocent parties.
30 Subchapter E. Substantial/final Payment
19970S0005B1890 - 7 -
1 § 3941. Substantial/final payment under contract. 2 § 3942. Arbitration. 3 Chapter 41. Purchase of Surplus Federal Property 4 § 4101. Contracts with United States. 5 § 4102. Bids and down payments. 6 Chapter 43. Public Facilities Concessions 7 § 4301. Short title of chapter and general provisions. 8 § 4302. Definitions. 9 § 4303. Terms of contracts. 10 Chapter 45. Antibid-Rigging 11 § 4501. Short title of chapter. 12 § 4502. Definitions. 13 § 4503. Prohibited activities. 14 § 4504. Civil action and damages. 15 § 4505. Suspension or debarment. 16 § 4506. Liability for increased costs. 17 § 4507. Noncollusion affidavits. 18 § 4508. Responsibility for enforcement. 19 § 4509. Investigation. 20 The General Assembly of the Commonwealth of Pennsylvania 21 hereby enacts as follows: 22 Section 1. Title 62 of the Pennsylvania Consolidated 23 Statutes is amended by adding parts to read: 24 TITLE 62 25 PROCUREMENT 26 Part 27 I. Commonwealth Procurement Code 28 II. General Procurement Provisions 29 PART I 30 COMMONWEALTH PROCUREMENT CODE 19970S0005B1890 - 8 -
1 Chapter 2 1. General Provisions 3 3. Procurement Organization 4 5. Source Selection and Contract Formation 5 7. (Reserved) 6 9. Procurement of Construction and Design Professional 7 Services 8 11. (Reserved) 9 13. (Reserved) 10 15. Supply Management 11 17. Legal and Contractual Remedies 12 19. Intergovernmental Relations 13 21. Small and Disadvantaged Businesses 14 23. Ethics in Public Contracting 15 CHAPTER 1 16 GENERAL PROVISIONS 17 Sec. 18 101. Short title of part. 19 102. Application of part. 20 103. Definitions. 21 104. General principles of law otherwise applicable. 22 105. Determinations. 23 106. Public access to procurement information. 24 107. Reciprocal limitations. 25 108. Recycled materials. 26 § 101. Short title of part. 27 This part shall be known and may be cited as the Commonwealth 28 Procurement Code. 29 § 102. Application of part. 30 (a) Application to Commonwealth procurement.--This part 19970S0005B1890 - 9 -
1 applies to every expenditure of funds, other than the investment
2 of funds, by Commonwealth agencies under any contract,
3 irrespective of their source, including Federal assistance
4 moneys except as specified in section 2108 (relating to
5 compliance with Federal requirements). This part does not apply
6 to grants nor does it EXCEPT WHERE THE PRIMARY PURPOSE OF THE <--
7 GRANT IS TO PROCURE THE CONSTRUCTION OF BUILDINGS FOR THE
8 GRANTOR. THIS PART DOES NOT apply to contracts between
9 Commonwealth agencies or between the Commonwealth and its
10 political subdivisions or other governments except as provided
11 in Chapter 19 (relating to intergovernmental relations). Nothing
12 in this part or in accompanying regulations shall prevent any
13 Commonwealth agency or political subdivision from complying with
14 the terms and conditions of any grant, gift, bequest or
15 cooperative agreement.
16 (b) Application to disposal of Commonwealth supplies.--This
17 part applies to the disposal of supplies of Commonwealth
18 agencies.
19 (c) Application to General Assembly and unified judicial
20 system.--The General Assembly and its agencies and the unified
21 judicial system and its agencies may use the department as its
22 purchasing agency for the purchase of supplies under this part
23 and may use the department to dispose of surplus supplies under
24 Chapter 15 (relating to supply management).
25 (d) Application to certain entities.--Nothing in this part
26 shall apply to the entity created by the act of August 7, 1963
27 (P.L.549, No.290), referred to as the Pennsylvania Higher
28 Education Assistance Agency Act.
29 (E) APPLICATION TO MEDICAL ASSISTANCE PROVIDERS.--NOTHING IN <--
30 THIS PART SHALL APPLY TO MEDICAL ASSISTANCE PROVIDER AGREEMENTS
19970S0005B1890 - 10 -
1 ENTERED INTO BY THE DEPARTMENT OF PUBLIC WELFARE UNDER THE
2 MEDICAL ASSISTANCE PROGRAMS.
3 (e) (F) Impact on existing acts.--Nothing in this part shall <--
4 affect the scope, effect or applicability of the act of August
5 15, 1961 (P.L.987, No.442), known as the Pennsylvania Prevailing
6 Wage Act, the act of March 3, 1978 (P.L.6, No.3), known as the
7 Steel Products Procurement Act, and the act of July 23, 1968
8 (P.L.686, No.226), entitled "An act equalizing trade practices
9 in public works procurement; authorizing the purchase by the
10 Commonwealth, its political subdivisions, and all public
11 agencies, of aluminum and steel products produced in a foreign
12 country, provided the foreign country does not prohibit or
13 discriminate against the importation to, sale or use in the
14 foreign country of supplies, material or equipment manufactured
15 in this Commonwealth; establishing procedures for determining
16 whether foreign countries discriminate against supplies,
17 materials or equipment manufactured in this Commonwealth; and
18 imposing penalties and providing for relief for violation of
19 this act."
20 § 103. Definitions.
21 Subject to additional definitions contained in subsequent
22 provisions of this part which are applicable to specific
23 provisions of this part, the following words and phrases when
24 used in this part shall have the meanings given to them in this
25 section unless the context clearly indicates otherwise:
26 "Change order." A written order signed by the contracting
27 officer directing the contractor to make changes which the
28 changes clause of the contract authorizes the contracting
29 officer to order. The change order may be either with the
30 consent of the contractor or a unilateral order by the
19970S0005B1890 - 11 -
1 contracting officer. 2 "Commonwealth agency." An executive agency, an independent 3 agency or a State-affiliated entity. 4 "Construction." The process of building, altering, 5 repairing, improving or demolishing any public structure or 6 building or other public improvements of any kind to any public 7 real property. The term does not include the routine operation 8 or maintenance of existing structures, buildings or real 9 property. 10 "Contract." A type of written agreement, regardless of what 11 it may be called, for the procurement or disposal of supplies, 12 services or construction. 13 "Contract modification." A written alteration in 14 specifications, delivery point, rate of delivery, period of 15 performance, price, quantity or other provisions of any contract 16 accomplished by mutual action of the parties to the contract. 17 "Contracting officer." A person authorized to enter into and 18 administer contracts and make written determinations with 19 respect to contracts. 20 "Department." The Department of General Services of the 21 Commonwealth. 22 "Design/Build contract." A construction contract in which 23 the contractor is responsible for both the design and 24 construction of any public structure or building or other public 25 improvements of any kind to any public real property. 26 "Employee." An individual drawing a salary or wages from a 27 Commonwealth agency, whether elected or not, and any 28 noncompensated individual performing personal services for any 29 Commonwealth agency. 30 "Executive agency." The Governor and the departments, 19970S0005B1890 - 12 -
1 boards, commissions, authorities and other officers and agencies 2 of the Commonwealth. The term does not include any court or 3 other officer or agency of the unified judicial system, the 4 General Assembly and its officers and agencies or any 5 independent agency or State-affiliated entity. 6 "Firm, fixed-price contract." A contract where the total 7 amount to be paid to the contractor is fixed and is not subject 8 to adjustment by reason of the cost experience of the 9 contractor. The term includes contracts where the unit price is 10 set but the total price varies because actual quantities 11 purchased deviate from the quantities estimated to be purchased. 12 The term also includes contracts where the price may be adjusted 13 in accordance with a contractually established price adjustment 14 provision which is not based upon the contractor's costs. 15 "Grant." The furnishing of assistance by the Federal <-- 16 Government, Commonwealth or any person, whether financial or 17 otherwise, to any person to support a program authorized by law. 18 The term does not include an award whose primary purpose is to 19 procure for the grantor an end product, whether in the form of 20 supplies, services or construction. A contract resulting from 21 such an award is not a grant but a procurement contract. 22 "Independent agency." Boards, commissions and other agencies 23 and officers of the Commonwealth which are not subject to the 24 policy supervision and control of the Governor. The term does 25 not include any State-affiliated entity, any court or other 26 officer or agency of the unified judicial system, the General 27 Assembly and its officers and agencies, any State-related 28 institution, political subdivision or any local, regional or 29 metropolitan transportation authority. 30 "Policy statement." Any document, except an adjudication, 19970S0005B1890 - 13 -
1 regulation or privileged communication prepared by a 2 Commonwealth agency which sets forth substantive or procedural 3 personal or property rights, privileges, immunities, duties, 4 liabilities or obligations of the public or any person, 5 including any document interpreting or implementing any statute 6 enforced or administered by the agency. 7 "Procurement." Buying, purchasing, renting, leasing, 8 licensing or otherwise acquiring any supplies, services or 9 construction. The term also includes all functions that pertain 10 to the obtaining of any supply, service or construction, 11 including description of requirements, selection and 12 solicitation of sources, preparation and award of contract and 13 all phases of contract administration. 14 "Purchasing agency." A Commonwealth agency authorized by 15 this part or by other law to enter into contracts for itself or 16 as the agent of another Commonwealth agency. When purchasing for 17 another Commonwealth agency, the purchasing agency acts on 18 behalf of the principal which needs the supplies, services and 19 construction and shall coordinate and cooperate with that 20 agency. 21 "Regulation." A regulation as defined in 45 Pa.C.S. § 501 22 (relating to definitions). This term shall include the 23 amendment, revision or otherwise alteration of the terms and 24 provisions of a regulation. 25 "Services." The furnishing of labor, time or effort by a 26 contractor not involving the delivery of a specific end product 27 other than drawings, specifications or reports which are merely 28 incidental to the required performance. The term shall include 29 the routine operation or maintenance of existing structures, 30 buildings or real property. The term does not include employment 19970S0005B1890 - 14 -
1 agreements, OR collective bargaining agreements or agreements <-- 2 with litigation consultants. The term includes utility services 3 and those services formerly provided by public utilities such as 4 electrical, telephone, water and sewage service. 5 "Specification." A description of the physical or functional 6 characteristics or the nature of a supply, service or 7 construction item, including a description of any requirement 8 for inspecting, testing or preparing a supply, service or 9 construction item for delivery. 10 "State-affiliated entity." A Commonwealth authority or a 11 Commonwealth entity. The term includes the Pennsylvania Turnpike 12 Commission, the Pennsylvania Housing Finance Agency, the 13 Pennsylvania Municipal Retirement System, the Pennsylvania 14 Infrastructure Investment Authority, the State Public School 15 Building Authority, the Pennsylvania Higher Educational 16 Facilities Authority and the State System of Higher Education. 17 The term does not include any court or other officer or agency 18 of the unified judicial system, the General Assembly and its 19 officers and agencies, any State-related institution, political 20 subdivision or any local, regional or metropolitan 21 transportation authority. 22 "State-related institution." The Pennsylvania State 23 University, the University of Pittsburgh, Lincoln University or 24 Temple University. 25 "Statewide requirements contract." A contract entered into 26 by the Department of General Services as purchasing agency which 27 covers the annual, semiannual or quarterly contract requirements 28 of all Commonwealth agencies and allows the agencies to order 29 needed supplies directly from the contractor. 30 "Supplies." Any property, including, but not limited to, 19970S0005B1890 - 15 -
1 equipment, materials, printing, insurance and leases of and
2 installment purchases of tangible or intangible personal
3 property. The term does not include real property or, leases of <--
4 real property OR ALCOHOLIC BEVERAGES OR LIQUOR PURCHASED FOR <--
5 RESALE BY THE PENNSYLVANIA LIQUOR CONTROL BOARD.
6 "Using agency." A Commonwealth agency which utilizes any
7 supplies, services or construction procured under this part.
8 § 104. General principles of law otherwise applicable.
9 Unless displaced by the particular provisions of this part,
10 existing Pennsylvania law, including Title 13 (relating to
11 commercial code), shall supplement the provisions of this part.
12 § 105. Determinations.
13 Written determinations required by this part shall be
14 retained in the appropriate official contract file.
15 § 106. Public access to procurement information.
16 Except as provided in section 512(d) (relating to competitive
17 sealed bidding), any documents created by or provided to any
18 Commonwealth agency for any procurement shall be subject to
19 inspection and copying only to the extent already required under
20 the act of June 21, 1957 (P.L.390, No.212), referred to as the
21 Right-to-Know Law.
22 § 107. Reciprocal limitations.
23 (a) Short title of section.--This section shall be known and
24 may be cited as the Reciprocal Limitations Act.
25 (b) Legislative findings.--It is hereby determined by the
26 General Assembly to reaffirm the legislative findings contained
27 in the act of November 28, 1986 (P.L.1465, No.146), known as the
28 Reciprocal Limitations Act, and codified in this section:
29 (1) The award of contracts to the lowest responsible
30 bidder generally provides for the most economical procurement
19970S0005B1890 - 16 -
1 of supplies and construction. 2 (2) In some cases, award to the lowest responsible 3 bidder may not be the most economical and practicable when 4 the best interests of the Commonwealth are concerned. 5 (3) Some states apply a preference favoring in-state 6 supplies or bidders or they apply a prohibition against the 7 use of out-of-State supplies or bidders. 8 (4) The application of this preference or prohibition by 9 other states diminishes or eliminates opportunities for 10 bidders and manufacturers who reside in this Commonwealth to 11 obtain construction contracts from or to sell supplies to 12 states that have this preference, thereby resulting in the 13 loss of business for resident bidders and manufacturers. 14 Therefore, in order to offset or counteract the 15 discriminatory practices of other states, discourage other 16 states from applying a preference and ultimately to aid 17 employment, help business and industry located in this 18 Commonwealth, attract new business and industry to this 19 Commonwealth and provide additional tax revenue both from 20 those receiving contracts and those employed by contractors, 21 the General Assembly hereby declares that it is the policy of 22 this Commonwealth to respond in like manner against those 23 states that apply preferences or prohibitions by giving a 24 similar offsetting preference to residents in this 25 Commonwealth and bidders offering supplies manufactured in 26 this Commonwealth and by prohibiting the purchase or use of 27 certain supplies, in accordance with the provisions of this 28 section. 29 (c) Preference for supplies.--In all procurements of 30 supplies exceeding the amount established by the department for 19970S0005B1890 - 17 -
1 small procurements under section 514 (relating to small 2 procurements), all Commonwealth agencies shall give preference 3 to those bidders or offerors offering supplies produced, 4 manufactured, mined, grown or performed in this Commonwealth as 5 against those bidders or offerors offering supplies produced, 6 manufactured, mined, grown or performed in any state that gives 7 or requires a preference to supplies produced, manufactured, 8 mined, grown or performed in that state. The amount of the 9 preference shall be equal to the amount of the preference 10 applied by the other state for that particular supply. 11 (d) Preference for resident bidders or offerors.--When a 12 contract for construction or supplies exceeding the amount 13 established by the department for small procurements under 14 section 514 is to be awarded, a resident bidder or offeror shall 15 be granted a preference as against a nonresident bidder or 16 offeror from any state that gives or requires a preference to 17 bidders or offerors from that state. The amount of the 18 preference shall be equal to the amount of the preference 19 applied by the state of the nonresident bidder or offeror. 20 (e) Prohibition.--For public contracts exceeding the amount 21 established by the department for small procurements under 22 section 514, no Commonwealth agency shall specify for, use or 23 procure any supplies which are produced, manufactured, mined, 24 grown or performed in any state that prohibits the specification 25 for, use or procurement of these supplies in or on its public 26 buildings or other works when these supplies are not produced, 27 manufactured, mined, grown or performed in that state. 28 (f) Listing discriminating states.--The department shall 29 prepare a list of the states which apply a preference favoring 30 in-State supplies or bidders or offerors or a prohibition 19970S0005B1890 - 18 -
1 against the use of out-of-State supplies or bidders or offerors 2 and shall publish the list in the Pennsylvania Bulletin. When a 3 state applies a new preference or prohibition, the department 4 shall publish that information in the Pennsylvania Bulletin as 5 an addition to the original list. 6 (g) Inclusion in invitation for bids or request for 7 proposals.--In all invitations for bids and requests for 8 proposals for the procurement of supplies exceeding the amount 9 established by the department for small procurements under 10 section 514 all Commonwealth agencies shall include a list of 11 all the states that have been found by the department to have 12 applied a preference favoring in-State supplies, bidders or 13 offerors and the amount of the preference. All invitations for 14 bids, requests for proposals and notices issued for the purpose 15 of securing bids or proposals for public contracts as issued by 16 any Commonwealth agency exceeding the amount established by the 17 department for small procurements under section 514 shall 18 include a list of all states that have been found by the 19 department to have applied a preference for in-State bidders or 20 offerors and the amount of the preference. All invitations for 21 bids, requests for proposals and notices issued for the purpose 22 of securing bids or proposals for contracts for construction or 23 supplies as issued by any Commonwealth agency exceeding the 24 amount established by the purchasing agency for small 25 procurements under section 514 shall also include a list of all 26 states that apply a prohibition against certain supplies and 27 shall inform potential bidders or offerors that they are 28 prohibited from using supplies from those states. If a bid or 29 proposal discloses that the bidder or offeror is offering 30 supplies from a state which prohibits the use of out-of-State 19970S0005B1890 - 19 -
1 supplies, the bid or proposal shall be rejected. 2 (h) Federal funds.--The provisions of this section shall not 3 be applicable when the application of this section may 4 jeopardize the receipt of Federal funds. 5 (i) Waiver.--The provisions of this section may be waived 6 when the head of the purchasing agency determines in writing 7 that it is in the best interests of the Commonwealth. 8 (j) Definitions.--As used in this section, the following 9 words and phrases shall have the meanings given to them in this 10 subsection: 11 "Resident bidder or offeror." A person, partnership, 12 corporation or other business entity authorized to transact 13 business in this Commonwealth and having a bona fide 14 establishment for transacting business in this Commonwealth at 15 which it was transacting business on the date when bids or 16 proposals for the public contract were first solicited. 17 § 108. Recycled materials. 18 (a) Commonwealth agency review.--All Commonwealth agencies 19 shall review their procurement procedures and specifications in 20 accordance with section 1504 of the act of July 28, 1988 21 (P.L.556, No.101), known as the Municipal Waste Planning, 22 Recycling and Waste Reduction Act. 23 (b) Preference for recycled content.--For contracts 24 exceeding the amount established by the department for small 25 procurements under section 514 (relating to small procurements), 26 the contracting officer shall comply with section 1505 of the 27 Municipal Waste Planning, Recycling and Waste Reduction Act 28 regarding a preference for bids containing a minimum percentage 29 of recycled content for the supply subject to the bid. 30 CHAPTER 3 19970S0005B1890 - 20 -
1 PROCUREMENT ORGANIZATION 2 Subchapter 3 A. Organization of Public Procurement 4 B. Procurement Policy 5 C. Powers and Duties of Department 6 D. Powers and Duties of the Board of Commissioners of 7 Public Grounds and Buildings and the Office of the Budget 8 E. Coordination, Training and Education 9 SUBCHAPTER A 10 ORGANIZATION OF PUBLIC PROCUREMENT 11 Sec. 12 301. Procurement responsibility. 13 § 301. Procurement responsibility. 14 (a) General organization.--Formulation of procurement policy 15 governing the procurement, management, control and disposal of 16 supplies, services and construction for executive and 17 independent agencies shall be the responsibility of the 18 department as provided for in Subchapter B (relating to 19 procurement policy). The procurement and supervision of the 20 procurement of supplies, services and construction for executive 21 agencies and those independent agencies for which the department 22 acts as purchasing agency shall be the responsibility of the 23 department as provided for in Subchapter C (relating to powers 24 and duties of department). 25 (b) Application to independent agencies.--Except as 26 otherwise specifically provided by law and this section, 27 independent agencies shall use the department as their 28 purchasing agency for the procurement of supplies or 29 construction. Independent agencies shall have the authority to 30 procure their own services. However, when any independent agency 19970S0005B1890 - 21 -
1 acts as its own purchasing agency it shall use the procedures 2 provided in this part for any procurement of supplies, services 3 or construction. 4 (c) Exceptions for executive and independent agencies.--The 5 following supplies, services and construction need not be 6 procured through the department, nor shall the procurement 7 policy be established by the department, but shall nevertheless 8 be procured by the appropriate purchasing agency, subject to the 9 requirements of this part: 10 (1) Bridge, highway, dam, airport (except vertical 11 construction), railroad or other heavy or specialized 12 construction including: 13 (i) The construction of facilities and improvements 14 by the Department of Conservation and Natural Resources 15 in State parks and State forests. 16 (ii) Construction activities, excluding buildings, 17 solely within the expertise of the Department of 18 Environmental Protection, including, but not limited to, 19 mine reclamation, oil and gas well plugging, waste site 20 remediation, flood control and stream rehabilitation. 21 (2) Works of art, historic objects and documents for 22 acquisition and public exhibition. 23 (3) Published books, maps, periodicals and technical 24 pamphlets. 25 (4) Perishable food stuffs. 26 (5) The procurement of services, the renting of 27 machinery and equipment and the licensing of specialized 28 computer software by the Office of Attorney General, the 29 Department of the Auditor General and the Treasury 30 Department. 19970S0005B1890 - 22 -
1 (d) Application to State-affiliated entities.--State- 2 affiliated entities may formulate their own procurement policy 3 governing the procurement, management, control and disposal of 4 supplies, services and construction and may act as their own 5 purchasing agency for the procurement of supplies, services and 6 construction, but they are required to use the procedures 7 provided in this part for such procurement. 8 SUBCHAPTER B 9 PROCUREMENT POLICY 10 Sec. 11 311. Powers and duties. 12 312. Procurement regulations. 13 § 311. Powers and duties. 14 Except as otherwise provided in this part, the department may 15 promulgate regulations governing the procurement, management, 16 control and disposal of any and all supplies, services and 17 construction to be procured by Commonwealth agencies. The 18 department shall consider and decide matters of policy within 19 the provisions of this part. The department may audit and 20 monitor the implementation of its regulations and the 21 requirements of this part. 22 § 312. Procurement regulations. 23 Regulations shall be promulgated by the department as 24 provided in 45 Pa.C.S. Part II (relating to publication and 25 effectiveness of Commonwealth documents) and by the appropriate 26 purchasing agencies for those matters contained in section 27 301(c) (relating to procurement responsibility). The regulations 28 shall be subject to the act of June 25, 1982 (P.L.633, No.181), 29 known as the Regulatory Review Act. The department may not 30 delegate its power to promulgate regulations. No regulation may 19970S0005B1890 - 23 -
1 change any commitment, right or obligation of any Commonwealth 2 agency or of a contractor under a contract in existence on the 3 effective date of the regulation. 4 SUBCHAPTER C 5 POWERS AND DUTIES OF DEPARTMENT 6 Sec. 7 321. Powers and duties. 8 322. Specific construction powers, duties and procedures. 9 § 321. Powers and duties. 10 Except as otherwise specifically provided in this part, the 11 department shall have the following powers and duties: 12 (1) Procure or supervise the procurement of all 13 supplies, services and construction needed by executive 14 agencies and those independent agencies for which the 15 department acts as purchasing agency. Procurement authority 16 may be delegated in writing by the Secretary of General 17 Services. 18 (2) Exercise general supervision and control over all 19 inventories of supplies belonging to executive agencies. 20 (3) Sell, trade or otherwise dispose of surplus supplies 21 belonging to executive or independent agencies. 22 (4) Coordinate programs of executive and independent 23 agencies for the inspection, testing and acceptance of 24 supplies and construction to ensure availability of 25 facilities and to avoid a duplication of functions. 26 (5) Establish and maintain a central office where 27 businesses operating in this Commonwealth may obtain 28 information pertaining to the procurement needs of 29 Commonwealth agencies. 30 (6) Participate in the management and maintenance of a 19970S0005B1890 - 24 -
1 contractor responsibility program in coordination with the
2 Office of the Budget and other agencies as may be directed by
3 the Governor.
4 § 322. Specific construction powers, duties and procedures.
5 The following procedure shall apply to construction to be
6 completed by the department which costs more than the amount
7 established by the department under section 514 (relating to
8 small procurements) for construction procurement, unless the
9 work is to be done by Commonwealth agency employees or by
10 inmates or patients of a Commonwealth agency institution:
11 (1) The Commonwealth agency or State-related institution
12 shall notify the department to have plans and specifications
13 for the project.
14 (2) Promptly after the notice, in such cases, or
15 promptly after any appropriation made to it becomes
16 available, the department shall, if necessary, select an
17 architect and/or an engineer, in accordance with the
18 selection procedures of section 905 (relating to procurement
19 of design professional services) to design the work and
20 prepare the specifications therefor. The department may, as
21 an alternative, enter into a design/build contract IN <--
22 ACCORDANCE WITH SECTION 511 (RELATING TO METHODS OF SOURCE
23 SELECTION). Such design/build contracts shall be subject to
24 the requirements of this act and the provisions of the act of
25 August 15, 1961 (P.L.987, No.442), known as the Pennsylvania
26 Prevailing Wage Act, and ACT. DESIGN/BUILD CONTRACTS SHALL <--
27 ALSO BE SUBJECT TO the act of May 1, 1913 (P.L.155, No. 104),
28 entitled "An act regulating the letting of certain contracts
29 for the erection, construction, and alteration of public
30 buildings," to the extent provided in paragraph (6).
19970S0005B1890 - 25 -
1 (3) The department shall enter into a contract with the 2 architect or engineer, which shall provide all of the 3 following: 4 (i) A date for the completion of the plans and 5 specifications. 6 (ii) That the plans and specifications must meet 7 with the approval of the Commonwealth agency or State- 8 related institution for which the building is being 9 erected, altered or enlarged and, in the case of an 10 administrative board or commission of the Commonwealth 11 agency with which the board or commission is respectively 12 connected, to the extent of the type and general 13 character of the building, design of the floor layouts, 14 medical equipment or other equipment of a nature peculiar 15 to the building for which the plans and specifications 16 are being prepared. 17 (iii) That the plans, drawings and specifications 18 must be approved by the department. 19 (iv) That the plans and specifications must be 20 approved by the Department of Labor and Industry, the 21 Department of Health and the Department of Environmental 22 Protection, to the extent to which those Commonwealth 23 agencies, respectively, have jurisdiction to require the 24 submission to them for approval of certain features of 25 the building. 26 The architect or engineer in preparing plans and 27 specifications shall consult with the department and the 28 department shall insist upon the prompt completion of the 29 plans and specifications, within the time prescribed in the 30 architect's or engineer's contracts unless it shall 19970S0005B1890 - 26 -
1 specifically agree in writing to an extension thereof. 2 (4) The enforcement of all contracts provided for by 3 this section shall be under the control and supervision of 4 the department. The department shall have the authority to 5 engage the services of a construction management firm to 6 coordinate the work of the total project. All questions or 7 disputes arising between the department and any contractor 8 with respect to any matter pertaining to a contract entered 9 into with the department or any part thereto or any breach of 10 contract arising thereunder shall be submitted to final and 11 binding arbitration as provided by the terms of the contract 12 which finding shall be final and not subject to further 13 appeal or, if not so provided, shall be referred to the Board 14 of Claims as set forth in the act of May 20, 1937 (P.L.728, 15 No.193), referred to as the Board of Claims Act, whose 16 decision and award shall be final and binding and conclusive 17 upon all parties thereto, except that either party shall have 18 the right to appeal from the decision and award as provided 19 by law. 20 (5) The department shall examine all bills on account of 21 the contracts entered into under the provisions of this 22 section, and, if they are correct, the department shall 23 certify that the materials have been furnished, or that the 24 work or labor has been performed in a workmanlike manner, and 25 in accordance with the contract, approve the bills and issue 26 its requisition therefor, or forward its certificate to the 27 proper Commonwealth agency or State-related institution, as 28 the case may be. Progress payments and final payments shall 29 not estop the department from pursuing its lawful remedies 30 for defects in workmanship or materials or both and other 19970S0005B1890 - 27 -
1 damages. 2 (6) The department may award construction contracts for <-- 3 all the work or separately for parts of the work or both on 4 all projects under $25,000 base construction cost. 5 (6) FOR CONSTRUCTION CONTRACTS WHERE THE TOTAL <-- 6 CONSTRUCTION COSTS ARE LESS THAN $25,000, THE DEPARTMENT 7 SHALL NOT BE REQUIRED TO COMPLY WITH THE ACT OF MAY 1, 1913 8 (P.L.155, NO.104), ENTITLED "AN ACT REGULATING THE LETTING OF 9 CERTAIN CONTRACTS FOR THE ERECTION, CONSTRUCTION, AND 10 ALTERATION OF PUBLIC BUILDINGS," AND THE DEPARTMENT MAY AWARD 11 SUCH CONTRACTS IN ACCORDANCE WITH SECTION 511. All projects 12 equal to or exceeding $25,000 shall be subject to the act of 13 May 1, 1913 (P.L.155, No.104), entitled "An act regulating 14 the letting of certain contracts for the erection, 15 construction, and alteration of public buildings." Whenever 16 the department enters into a single contract for a project, 17 in the absence of good and sufficient reasons, the contractor 18 shall pay each subcontractor within 15 days of receipt of 19 payment from the department, an amount equal to the 20 percentage of completion allowed to the contractor on the 21 account of the subcontractor's work. The contractor shall 22 also require the subcontractor to make similar payments to 23 his subcontractors. 24 (7) The department shall have the right to engage the 25 services of any architect or consulting or supervising 26 engineer or engineers, whom it may deem necessary for the 27 proper designing of or inspection or supervision of projects 28 constructed, altered or enlarged by the department under this 29 section in accordance with the selection procedures of 30 section 905. 19970S0005B1890 - 28 -
1 (8) Changes in scope in the plans or specifications, or 2 both, may be made after their approval only with the consent 3 of the Governor and all of the Commonwealth agencies and 4 State-related institutions whose approval of the original 5 plans or specifications, or both, was necessary under this 6 section. 7 (9) If the appropriation is to a Commonwealth agency, 8 other than the department or State-related institution, the 9 department shall award and enter into the contract as agent 10 for the Commonwealth agency or State-related institution to 11 which the appropriation was made. 12 SUBCHAPTER D 13 POWERS AND DUTIES OF THE BOARD OF COMMISSIONERS OF 14 PUBLIC GROUNDS AND BUILDINGS AND THE OFFICE OF THE BUDGET 15 Sec. 16 326. Board of Commissioners of Public Grounds and Buildings. 17 327. Office of the Budget. 18 § 326. Board of Commissioners of Public Grounds and Buildings. 19 No lease of real estate for use by an executive or 20 independent agency and no sole source procurement of supplies 21 for an executive or independent agency for which the department 22 acts as the purchasing agency shall be valid or effective 23 unless, upon review, it is approved by the Board of 24 Commissioners of Public Grounds and Buildings. Where the board 25 is reviewing a proposed sole source lease or procurement being 26 submitted pursuant to section 515 (relating to sole source 27 procurement), approval of the lease or procurement shall require 28 the unanimous vote of the board. Where the board is reviewing a 29 proposed non-sole source lease, the lease shall be approved when 30 one member of the board votes to approve the lease. All votes 19970S0005B1890 - 29 -
1 shall take place at a public meeting. 2 § 327. Office of the Budget. 3 (a) Encumbrance of funds.--For executive agencies and 4 independent agencies and State-affiliated entities where the 5 department is used as the purchasing agency, Office of the 6 Budget shall encumber sufficient funds for the payment of all 7 invoices for the procurement of supplies, services and 8 construction. 9 (b) Contractor responsibility program.--The Office of the 10 Budget shall participate in the management and maintenance of a 11 contractor responsibility program in coordination with the 12 department and other agencies as may be directed by the 13 Governor. 14 (c) Contracts for services.--Except for contracts awarded <-- 15 pursuant to section 514 (relating to small procurements), the 16 Office of the Budget shall review and approve all contracts for 17 services for executive agencies and independent agencies and 18 State-affiliated entities where the department acts as 19 purchasing agency for: 20 (1) Fiscal responsibility and budgetary appropriateness. 21 (2) Availability of funds. 22 (C) COMPTROLLER REVIEW OF CONTRACTS FOR SERVICES.-- <-- 23 (1) EXCEPT FOR CONTRACTS AWARDED PURSUANT TO SECTION 514 24 (RELATING TO SMALL PROCUREMENTS), THE COMPTROLLER AUTHORIZED 25 IN PARAGRAPH (2) SHALL REVIEW AND APPROVE ALL CONTRACTS FOR 26 SERVICES FOR: 27 (I) FISCAL RESPONSIBILITY AND BUDGETARY 28 APPROPRIATENESS. 29 (II) AVAILABILITY OF FUNDS. 30 (2) WHERE THE SERVICE CONTRACT IS FOR AN EXECUTIVE 19970S0005B1890 - 30 -
1 AGENCY, INDEPENDENT AGENCY OR STATE-AFFILIATED ENTITY FOR 2 WHICH THE OFFICE OF THE BUDGET ACTS AS COMPTROLLER, THE 3 OFFICE OF THE BUDGET SHALL REVIEW AND APPROVE THE CONTRACT. 4 WHERE THE SERVICE CONTRACT IS FOR AN INDEPENDENT AGENCY OR 5 STATE-AFFILIATED ENTITY FOR WHICH THE OFFICE OF THE BUDGET 6 DOES NOT ACT AS COMPTROLLER, THE FISCAL OFFICE OR COMPTROLLER 7 OF THAT AGENCY OR ENTITY SHALL REVIEW AND APPROVE THE 8 CONTRACT. 9 (d) Agency comptrollers.--A Commonwealth agency comptroller 10 may, at his option, serve as a nonvoting member of an evaluation 11 committee for requests for proposals or a similar contract 12 bidding or selection committee for the acquisition of services. 13 (e) Exceptions.--Notwithstanding the foregoing, subsections 14 (a) and (c) shall not apply to procurements made by the Office 15 of Attorney General, the Department of the Auditor General or 16 the Treasury Department. However, where the department is used 17 as the purchasing agency, the Office of Attorney General, the 18 Department of the Auditor General and the Treasury Department 19 shall certify to the department that they have encumbered 20 sufficient funds for the procurement. 21 SUBCHAPTER E 22 COORDINATION, TRAINING AND EDUCATION 23 Sec. 24 331. Collection of data concerning public procurement. 25 332. Advisory groups. 26 § 331. Collection of data concerning public procurement. 27 All executive and independent agencies shall furnish such 28 reports as the department may require concerning usage, needs 29 and stock on hand, and the department may prescribe the format 30 and forms to be used by the agencies in requisitioning, ordering 19970S0005B1890 - 31 -
1 and reporting supplies, services and construction. 2 § 332. Advisory groups. 3 (a) Procurement Advisory Council.--The department may 4 establish a Procurement Advisory Council and allocate funds for 5 it that may be available. If created, the council, upon adequate 6 public notice, shall meet at least once a year for the 7 discussion of problems and recommendations for improvement of 8 the procurement process. When requested by the department, the 9 council may conduct studies, research and analyses and make 10 reports and recommendations with respect to subjects or matters 11 within the jurisdiction of the department. The council may 12 consist of any qualified persons the department deems 13 appropriate. 14 (b) Other advisory groups.--The department may appoint 15 advisory groups to assist with respect to specifications or 16 procurement in specific areas and with respect to any other 17 matters within the authority of the department. 18 (c) Reimbursement of expenses.--Members of the council and 19 other advisory groups may be reimbursed for expenses incurred in 20 the performance of their duties, subject to expenditure 21 limitations prescribed by the department. 22 (d) Conflict of interest.--Members of the council and other 23 advisory groups shall be considered State advisors under the act 24 of July 19, 1957 (P.L.1017, No.451), known as the State Adverse 25 Interest Act, and, as such, shall be subject to the prohibitions 26 for State advisors set forth in that act, provided that a member 27 shall not be deemed to have an adverse interest by virtue of any 28 action taken by the council or other advisory groups if the 29 member discloses the conflict of interest and properly recuses 30 himself from participating in any recommendation of the council 19970S0005B1890 - 32 -
1 or an advisory group. 2 CHAPTER 5 3 SOURCE SELECTION AND CONTRACT FORMATION 4 Subchapter 5 A. Definitions 6 B. Methods of Source Selection 7 C. Cancellation of Invitations for Bids or Requests for 8 Proposals 9 D. Qualifications and Duties 10 E. Types of Contracts 11 F. Inspection of Plant and Audit of Records 12 G. Determinations and Reports 13 SUBCHAPTER A 14 DEFINITIONS 15 Sec. 16 501. Definitions. 17 § 501. Definitions. 18 The following words and phrases when used in this chapter 19 shall have the meanings given to them in this section unless the 20 context clearly indicates otherwise: 21 "Established catalog price." The price included in a 22 catalog, price list, schedule or other form that: 23 (1) is regularly maintained by a manufacturer or 24 contractor; 25 (2) is either published or otherwise available for 26 inspection by customers; and 27 (3) states prices at which sales are currently or were 28 last made to a significant number of any category of buyers 29 or buyers constituting the general buying public for the 30 supplies or services involved. 19970S0005B1890 - 33 -
1 "Invitation for bids." All documents, including those either 2 attached or incorporated by reference, used for soliciting bids. 3 "Life cycle cost." The total cost of the supply in terms of 4 purchase cost, installation cost, maintenance cost, energy cost, 5 supply cost and other costs. 6 "Procurement description." The words used in a solicitation 7 to describe the supplies, services or construction to be 8 procured. The term includes specifications attached to or made a 9 part of the solicitation. 10 "Request for proposals." All documents, including those 11 either attached or incorporated by reference, used for 12 soliciting proposals. 13 "Responsible bidder or offeror." A person who has the 14 capability in all respects to fully perform the contract 15 requirements and the integrity and reliability which will assure 16 good faith performance. 17 "Responsive bidder or offeror." A person who has submitted a 18 bid which conforms in all material respects to the invitation 19 for bids. 20 "Sealed bid or proposal." A bid or proposal whose contents 21 is not disclosed until the bid opening time or the proposal 22 receipt date. Bids and proposals are typically submitted in 23 sealed envelopes to meet this requirement, but electronic 24 submission is not prohibited so long as the purchasing agency 25 has the electronic capability to maintain the confidentiality of 26 the bid or proposal until the bid opening time or proposal 27 receipt date. 28 SUBCHAPTER B 29 METHODS OF SOURCE SELECTION 30 Sec. 19970S0005B1890 - 34 -
1 511. Methods of source selection. 2 512. Competitive sealed bidding. 3 513. Competitive sealed proposals. 4 514. Small procurements. 5 515. Sole source procurement. 6 516. Emergency procurement. 7 517. Multiple awards. 8 518. Competitive selection procedures for certain services. 9 519. Selection procedure for insurance and notary bonds. 10 520. Supplies manufactured by, and services performed by, 11 persons with disabilities. 12 § 511. Methods of source selection. 13 Unless otherwise authorized by law, all Commonwealth agency 14 contracts shall be awarded by competitive sealed bidding under 15 section 512 (relating to competitive sealed bidding) except as 16 provided in: 17 Section 513 (relating to competitive sealed proposals). 18 Section 514 (relating to small procurements). 19 Section 515 (relating to sole source procurement). 20 Section 516 (relating to emergency procurement). 21 Section 517 (relating to multiple awards). 22 Section 518 (relating to competitive selection procedures 23 for certain services). 24 Section 519 (relating to selection procedure for 25 insurance and notary bonds). 26 Section 520 (relating to supplies manufactured by, and 27 services performed by, persons with disabilities). 28 Section 905 (relating to procurement of design 29 professional services). 30 § 512. Competitive sealed bidding. 19970S0005B1890 - 35 -
1 (a) Conditions for use.--Contracts shall be awarded by 2 competitive sealed bidding except as otherwise provided in 3 section 511 (relating to methods of source selection). 4 (b) Invitation for bids.--An invitation for bids shall be 5 issued and shall include a procurement description and all 6 contractual terms, whenever practical, and conditions applicable 7 to the procurement. 8 (c) Public notice.--Adequate public notice of the invitation 9 for bids shall be given a reasonable time prior to the date set 10 for the opening of bids. The purchasing agency shall establish 11 written policies and may promulgate regulations regarding 12 methods of public notice. The method of public notice may 13 include any of the following: 14 (1) Electronic publication which is accessible to the 15 general public. 16 (2) Advertisement as provided for in 45 Pa.C.S. § 306 17 (relating to use of trade publications). 18 (3) Issuance of invitations for bids to bidders on the 19 solicitation mailing list of the purchasing agency. 20 (4) Publication in a newspaper of general circulation. 21 (5) Where prequalification is a requirement of 22 submitting a bid, notification to all contractors who have 23 been prequalified by the purchasing agency. 24 Copies of invitations to bid shall be made available to any 25 interested person upon request to the purchasing agency. 26 Purchasing agencies may establish procedures for the 27 distribution of invitations to bid including the imposition of a 28 fee to reimburse the agency for the costs of photocopying and 29 mailing. 30 (d) Bid opening.--Bids shall be opened publicly in the 19970S0005B1890 - 36 -
1 presence of one or more witnesses at the time and place 2 designated in the invitation for bids. The amount of each bid 3 and any other relevant information as may be specified by 4 regulation, together with the name of each bidder, shall be 5 recorded. The record shall be open to public inspection. 6 (e) Bid acceptance and evaluation.--Bids shall be 7 unconditionally accepted without alteration or modification 8 except as authorized in this part or in the invitation for bids. 9 Bids shall be evaluated based on the requirements set forth in 10 the invitation for bids, which may include criteria to determine 11 acceptability such as inspection, testing, quality, workmanship, 12 delivery and suitability for a particular purpose. Those 13 criteria that will affect the bid price and be considered in 14 evaluation for award shall be objectively measurable, such as 15 discounts, transportation costs and total or life cycle costs. 16 The invitation for bids shall set forth the evaluation criteria 17 to be used. No criteria may be used in bid evaluation that are 18 not set forth in the invitation for bids. 19 (f) Modification or withdrawal of bids.-- 20 (1) Bids may be modified or withdrawn by written notice 21 or in person by a bidder or its authorized representative if 22 its identity is made known and a receipt for the bid is 23 signed prior to the exact hour and date set for the opening 24 of bids. Except as otherwise provided in this part, 25 withdrawals and modifications of bids received after the 26 exact hour and date specified for the opening of bids shall 27 not be considered. 28 (2) Withdrawal of erroneous bids after bid opening but 29 before award based on bid mistakes shall be permitted by the 30 written determination of the contracting officer when the 19970S0005B1890 - 37 -
1 bidder requests relief and presents credible evidence that 2 the reason for the lower bid price was a clerical mistake as 3 opposed to a judgment mistake and was actually due to an 4 unintentional arithmetical error or an unintentional omission 5 of a substantial quantity of work, labor, material or 6 services made directly in the compilation of the bid. The 7 request for relief and the supporting evidence must be 8 received by the contracting officer within a reasonable time 9 period after the bid opening. The time period shall be 10 specified by the department. 11 (3) The contracting officer shall not permit a 12 withdrawal of a bid if the withdrawal of the bid would result 13 in the awarding of the contract on another bid of the same 14 bidder, its partner or a corporation or business venture 15 owned by or in which the bidder has a substantial interest. 16 No bidder who is permitted to withdraw a bid shall supply any 17 material or labor to or perform any subcontract or other work 18 agreement for any person to whom a contract or subcontract is 19 awarded in the performance of the contract for which the 20 withdrawn bid was submitted, without the written approval of 21 the contracting officer. 22 (g) Award.--The contract shall be awarded within 60 days of 23 the bid opening by written notice to the lowest responsible and 24 responsive bidder whose bid meets the requirements and criteria 25 set forth in the invitation for bids or all bids shall be 26 rejected except as otherwise provided in this section. 27 Extensions of the date for the award may be made by mutual 28 written consent of the contracting officer and the lowest 29 responsible and responsive bidder. Within 30 days of the bid 30 opening the contracting officer shall, if bid security was 19970S0005B1890 - 38 -
1 required by the invitation for bids, return the bid security to 2 all but the lowest and next-to-lowest bidders then under 3 consideration for contract award. 4 (h) Multistep sealed bidding.--When it is considered 5 impractical to prepare initially a procurement description to 6 support an award based on price, an invitation for bids may be 7 issued requesting the submission of unpriced offers, to be 8 followed by an invitation for bids limited to those bidders 9 whose offers have been qualified under the criteria set forth in 10 the first solicitation. 11 § 513. Competitive sealed proposals. 12 (a) Conditions for use.--When the contracting officer 13 determines in writing that the use of competitive sealed bidding 14 is either not practicable or advantageous to the Commonwealth, a 15 contract may be entered into by competitive sealed proposals. 16 (b) Request for proposals.--Proposals shall be solicited 17 through a request for proposals. 18 (c) Public notice.--Public notice of the request for 19 proposals shall be given in the same manner as provided in 20 section 512(c) (relating to competitive sealed bidding). 21 (d) Receipt of proposals.--Offerors shall submit their 22 proposal to ensure that their proposals are received prior to 23 the time and date established for receipt of the proposals. 24 Proposals shall be submitted in the format required by the 25 request for proposals. Proposals shall be opened so as to avoid 26 disclosure of their contents to competing offerors. 27 (e) Evaluation.--The relative importance of the evaluation 28 factors shall be fixed prior to opening the proposals. A 29 Commonwealth agency is required to invite its comptroller to 30 participate in the evaluation as a nonvoting member of any 19970S0005B1890 - 39 -
1 evaluation committee. 2 (f) Discussion with responsible offerors and revision of 3 proposals.--As provided in the request for proposals, 4 discussions may be conducted with responsible offerors who 5 submit proposals determined to be reasonably susceptible of 6 being selected for award for the purpose of clarification to 7 assure full understanding of and responsiveness to the 8 solicitation requirements and for the purpose of obtaining best 9 and final offers. Offerors shall be accorded fair and equal 10 treatment with respect to any opportunity for discussion and 11 revision of proposals. In conducting discussions, there shall be 12 no disclosure of any information derived from proposals 13 submitted by competing offerors. 14 (g) Award of contract.--The responsible offeror whose 15 proposal is determined in writing to be the most advantageous to 16 the purchasing agency, taking into consideration price and all 17 evaluation factors, shall be selected for contract negotiation. 18 (h) Contract negotiation.--After selection, the purchasing 19 agency shall proceed to negotiate a contract with the selected 20 offeror. 21 § 514. Small procurements. 22 If the procurement is not the subject of a Statewide 23 requirements contract between the purchasing agency and a 24 contractor, the head of the purchasing agency may authorize in 25 writing procurements without formal bid procedures, not 26 exceeding the amount established by the purchasing agency. The 27 department may authorize procurement OF THE SUPPLY OR SERVICE on <-- 28 a no-bid basis for procurements which do not exceed the amount 29 established by the department for small, no-bid procurements. 30 THE DEPARTMENT MAY AUTHORIZE PROCUREMENT ON A NO-BID BASIS FOR <-- 19970S0005B1890 - 40 -
1 CONSTRUCTION PROJECTS THAT DO NOT EXCEED A TOTAL CONSTRUCTION 2 COST OF $10,000. THE AMOUNT OF $10,000 SHALL BE ADJUSTED 3 ANNUALLY BY THE DEPARTMENT TO REFLECT THE ANNUAL PERCENTAGE 4 CHANGE IN THE COMPOSITE CONSTRUCTION COST INDEX OF THE UNITED 5 STATES DEPARTMENT OF COMMERCE OCCURRING ON THE ONE-YEAR PERIOD 6 ENDING DECEMBER 31 OF EACH YEAR. Procurement requirements shall 7 not be artificially divided so as to constitute a small 8 procurement under this section. Small procurements shall be made 9 in accordance with the requirements of the written authorization 10 and this section. Records of all small procurements shall be 11 transmitted to the purchasing agency. 12 § 515. Sole source procurement. 13 A contract may be awarded for a supply, service or 14 construction item without competition when the contracting 15 officer first determines in writing that one of the following 16 conditions exists: 17 (1) Only a single contractor is capable of providing the 18 supply, service or construction. 19 (2) A Federal or State statute or Federal regulation 20 exempts the supply, service or construction from the 21 competitive procedure. 22 (3) The total cost of the supply, service or 23 construction is less than the amount established by the 24 department for small, no-bid procurements under section 514 25 (relating to small procurements). 26 (4) It is clearly not feasible to award the contract FOR <-- 27 SUPPLIES OR SERVICES on a competitive basis. 28 (5) The services are to be provided by attorneys or 29 litigation consultants selected by the Office of General 30 Counsel, the Office of Attorney General, the Department of 19970S0005B1890 - 41 -
1 the Auditor General or the Treasury Department.
2 (6) The services are to be provided by expert witnesses.
3 (7) The services involve the repair, modification or
4 calibration of equipment and they are to be performed by the
5 manufacturer of the equipment or by the manufacturer's
6 authorized dealer, provided the contracting officer
7 determines that bidding is not appropriate under the
8 circumstances.
9 (8) The contract is for investment advisors or managers
10 selected by the Public School Employees' Retirement System,
11 the State Employees' Retirement System or a State-affiliated
12 entity.
13 (9) The contract is for financial or investment experts
14 to be used and selected by the Treasury Department or
15 financial or investment experts selected by the Secretary of
16 the Budget.
17 (10) It THE CONTRACT FOR SUPPLIES OR SERVICES is in the <--
18 best interest of the Commonwealth.
19 The written determination authorizing sole source procurement
20 shall be included in the contract file. With the exception of
21 small procurements under section 514 and emergency procurements
22 under section 516 (relating to emergency procurement), if the
23 sole source procurement is for a supply for which the department
24 acts as purchasing agency, it must be approved by the Board of
25 Commissioners of Public Grounds and Buildings prior to the award
26 of a contract.
27 § 516. Emergency procurement.
28 The head of a purchasing agency may make or authorize others
29 to make an emergency procurement when there exists a threat to
30 public health, welfare or safety or circumstances outside the
19970S0005B1890 - 42 -
1 control of the agency creates an urgency of need which does not 2 permit the delay involved in using more formal competitive 3 methods. Whenever practical, in the case of a procurement of a 4 supply, at least two bids shall be solicited. A written 5 determination of the basis for the emergency and for the 6 selection of the particular contractor shall be included in the 7 contract file. 8 § 517. Multiple awards. 9 (a) Conditions for use.--Contracts may be entered into on a 10 multiple award basis when the head of the purchasing agency 11 determines that one or more of the following criteria is 12 applicable: 13 (1) It is administratively or economically impractical 14 to develop or modify specifications for a myriad of related 15 supplies because of rapid technological changes. 16 (2) The subjective nature in the use of certain supplies 17 and the fact that recognizing this need creates a more 18 efficient use of the item. 19 (3) It is administratively or economically impractical 20 to develop or modify specifications because of the 21 heterogeneous nature of the product lines. 22 (4) There is a need for compatibility with existing 23 systems. 24 (5) The agency should select the contractor to furnish 25 the supply, service or construction based upon best value or 26 return on investment. 27 (b) Solicitation process.--Invitations to bid or requests 28 for proposals shall be issued for the supplies, services or 29 construction to be purchased. 30 (c) Public notice.--Public notice of the invitation for bids 19970S0005B1890 - 43 -
1 shall be given in the same manner as provided in section 512(c) 2 (relating to competitive sealed bidding). 3 (d) Receipt of bids or proposals.--Bids shall be opened in 4 the same manner as provided in section 512(d). Proposals shall 5 be received in the same manner as provided in section 513(d) 6 (relating to competitive sealed proposals). 7 (e) Award.--The invitation for bids or request for proposals 8 shall describe the method for selection of the successful 9 bidders or offerors. There are three options: 10 (1) Awards shall be made to the lowest responsible and 11 responsive bidder or offeror for each designated 12 manufacturer. 13 (2) Awards shall be made to the two or three lowest 14 responsible and responsive bidders or offerors for each 15 designated manufacturer. 16 (3) Awards shall be made to all responsible and 17 responsive bidders or offers. The Commonwealth agency shall 18 have the discretion to select the contractor to furnish the 19 supply, service or construction based upon best value or 20 return on investment. 21 § 518. Competitive selection procedures for certain services. 22 (a) Conditions for use.--The services of accountants, 23 clergy, physicians, lawyers, dentists and other personal 24 services which are not performed by other Commonwealth employees 25 shall be procured in accordance with this section except as 26 authorized under section 514 (relating to small procurements), 27 515 (relating to sole source procurement) or 516 (relating to 28 emergency procurement). 29 (b) Statement of qualifications.--Persons engaged in 30 providing the types of services specified in subsection (a) may 19970S0005B1890 - 44 -
1 submit statements of qualifications and expressions of interest 2 in providing these services. The contracting officer may specify 3 a uniform format for statements of qualifications. Persons may 4 amend these statements at any time by filing a new statement. 5 (c) Request for proposals.--Adequate notice of the need for 6 the services specified in subsection (a) shall be given by the 7 purchasing agency through a request for proposals. The request 8 for proposals shall describe the services required, list the 9 type of information required of each offeror and state the 10 relative importance of the particular information. 11 (d) Discussions.--The contracting officer may conduct 12 discussions with any offeror who has submitted a proposal to 13 determine the offeror's qualifications for further 14 consideration. Discussions shall not disclose any information 15 derived from proposals submitted by other offerors. 16 (e) Award.--Award shall be made to the offeror determined in 17 writing by the contracting officer to be best qualified based on 18 the evaluation factors set forth in the request for proposals. 19 Fair and reasonable compensation shall be determined through 20 negotiation. If compensation cannot be agreed upon with the best 21 qualified offeror, then negotiations will be formally terminated 22 with the selected offeror. If proposals were submitted by one or 23 more other offerors determined to be qualified, negotiations may 24 be conducted with the other offeror or offerors in the order of 25 their respective qualification ranking. The contract may be 26 awarded to the offeror then ranked as best qualified if the 27 amount of compensation is determined to be fair and reasonable. 28 § 519. Selection procedure for insurance and notary bonds. 29 (a) Conditions for use.--Insurance and notary bonds shall be 30 procured by the department in accordance with this section 19970S0005B1890 - 45 -
1 except as authorized under section 515 (relating to sole source 2 procurement) or 516 (relating to emergency procurement). 3 (b) Statement of qualifications.--Insurance and bond 4 carriers may submit statements of qualifications and expressions 5 of interest in providing insurance or notary bonds. The 6 department may specify a uniform format for statements of 7 qualifications. 8 (c) Request for proposals.--Adequate notice of the need for 9 insurance or notary bond coverage shall be given by the 10 purchasing agency through a request for proposals. The request 11 for proposals shall describe the type of insurance or bond 12 coverage required and list the type of information and data 13 required of each offeror. 14 (d) Receipt of proposals.--Offerors shall submit their 15 proposals prior to the time and date specified. 16 (e) Discussions with responsible offerors and revision to 17 proposals.--Discussions and negotiations may be conducted with 18 responsible offerors who submit proposals determined to be 19 reasonably susceptible of being selected for award. Offerors 20 shall be accorded fair and equal treatment with respect to any 21 opportunity for discussion, negotiation and revision of 22 proposals. Revisions may be permitted after submissions and 23 prior to award for the purpose of obtaining best and final 24 offers. 25 (f) Award.--Award shall be made to the offeror whose 26 proposal is determined in writing by the department to be the 27 most advantageous to the Commonwealth based on criteria 28 determined by the department, including the coverage offered and 29 the cost of the premium. 30 § 520. Supplies manufactured by, and services performed by, 19970S0005B1890 - 46 -
1 persons with disabilities. 2 (a) General rule.--Contracts may be entered into for <-- 3 supplies manufactured by, and services performed by, persons 4 with disabilities without competition in accordance with this 5 section. 6 (A) GENERAL RULE.--CONTRACTS FOR SUPPLIES MANUFACTURED BY <-- 7 AND SERVICES PERFORMED BY PERSONS WITH DISABILITIES SHALL BE 8 ENTERED INTO IN ACCORDANCE WITH THIS SECTION WITHOUT THE 9 REQUIREMENT FOR COMPETITIVE BIDDING. 10 (b) Fair market price.--Upon request from an agency for <-- 11 persons with disabilities OF THE DEPARTMENT and notice to the <-- 12 purchasing agency, the department shall determine the fair 13 market price of any supply manufactured by, or service performed 14 by, persons with disabilities and offered for sale to any 15 Commonwealth agency by an agency for persons with disabilities. 16 The department shall revise the prices in accordance with 17 changing market conditions. 18 (c) Distribution.--At the request of the department, the 19 Department of Public Welfare, or a nonprofit agency with the 20 approval of the Department of Public Welfare, shall facilitate 21 the distribution of orders for supplies manufactured by or 22 services performed by persons with disabilities among agencies 23 for persons with disabilities. 24 (d) Procurement of supplies manufactured by, and services 25 performed by, persons with disabilities.--Except as provided in 26 subsection (e), all supplies manufactured by, and services 27 furnished by, persons with disabilities shall be procured in 28 accordance with applicable specifications of the department or 29 other Commonwealth agencies from any agency for persons with 30 disabilities whenever the supplies and services are available at 19970S0005B1890 - 47 -
1 a price determined by the department to be the fair market 2 price. The head of a purchasing agency shall annually discuss 3 its needs for supplies or services with the ANY agency for <-- 4 persons with disabilities. 5 (e) Procurement from Commonwealth agency.--If any supply 6 manufactured by, or any service performed by, persons with 7 disabilities and offered for sale is available for procurement 8 from any Commonwealth agency and this part or any other statute 9 requires the procurement of the supply or service from the 10 Commonwealth agency, then the procurement of the supply or 11 service shall be made in accordance with the other provisions. 12 (F) EXCEPTION.--NOTWITHSTANDING SUBSECTION (H), WHEN THE <-- 13 COMMONWEALTH ENTERS INTO A CONTRACT UNDER THIS SECTION FOR THE 14 OPERATION OF THE COMMONWEALTH'S DRIVER'S LICENSE PHOTO CENTERS, 15 AT LEAST 70% OF THE AMOUNT PAID BY THE COMMONWEALTH SHALL BE 16 USED TO COVER PAYMENT OF WAGES AND SALARIES TO PERSONS WITH 17 DISABILITIES AND TO COVER ACTUAL MANUFACTURING COSTS, REAL 18 ESTATE LEASE COSTS, PROPERTY INSURANCE AND OTHER COSTS WHICH ARE 19 SPECIFICALLY REQUIRED BY CONTRACT. 20 (G) APPLICATION.-- 21 (1) THIS SECTION SHALL NOT SUPERSEDE ANY CONTRACT 22 CURRENTLY IN FORCE BETWEEN A COMMONWEALTH AGENCY AND ANOTHER 23 PARTY. 24 (2) NOTHING IN THIS SECTION SHALL BE CONSTRUED AS 25 CONFERRING UPON ANY PARTY ANY RIGHT OR INTEREST IN ANY 26 CONTRACT ENTERED INTO WITH THE COMMONWEALTH. 27 (f) (H) Definitions.--As used in this section, the following <-- 28 words and phrases shall have the meanings given to them in this 29 subsection: 30 "Agency for persons with disabilities." Any charitable, 19970S0005B1890 - 48 -
1 nonprofit agency incorporated under the laws of this 2 Commonwealth and approved by the department through which 3 persons with disabilities manufacture supplies or perform 4 services in this Commonwealth. 5 "Mentally retarded." Subaverage general intellectual 6 functioning which originates during the developmental period and 7 is associated with the impairment of maturation, learning or 8 social adjustment. 9 "Persons with a disability." A person who is visually 10 impaired, mentally retarded or physically disabled. 11 "Physically disabled." A limitation of most activities and 12 functioning by virtue of a severe impairment of the various 13 bodily systems which cannot be eliminated, modified or 14 substantially reduced by the usual rehabilitation services and 15 which precludes competitive employment. 16 "Supply manufactured by, or service performed by, person with 17 disabilities." At least 75% of the personnel either engaged in 18 the direct labor of manufacturing of a product or engaged in the 19 direct labor in performing a service in this Commonwealth must 20 be visually impaired, mentally retarded or physically disabled. 21 In addition, at least 75% of the amount paid by the Commonwealth 22 agency for the product or the service shall be remitted to the 23 agency for persons with disabilities to cover payment of wages 24 and salaries to persons with disabilities and to cover other 25 actual manufacturing costs incurred by the agency for persons 26 with disabilities in manufacturing of a product. 27 "Visually impaired." A condition in which central visual 28 acuity does not exceed 20/200 in the better eye with correcting 29 lenses or in which the widest diameter of the visual field 30 subtends an angle no greater than 20 degrees. 19970S0005B1890 - 49 -
1 SUBCHAPTER C 2 CANCELLATION OF INVITATIONS FOR BIDS OR 3 REQUESTS FOR PROPOSALS 4 Sec. 5 521. Cancellation of invitations for bids or requests for 6 proposals. 7 § 521. Cancellation of invitations for bids or requests for 8 proposals. 9 An invitation for bids, a request for proposals or other 10 solicitation may be canceled or any or all bids or proposals may 11 be rejected when it is in the best interests of the 12 Commonwealth. Bids may be rejected in part when specified in the 13 solicitation. The reasons for the cancellation or rejection 14 shall be made part of the contract file. 15 SUBCHAPTER D 16 QUALIFICATIONS AND DUTIES 17 Sec. 18 531. Debarment or suspension. 19 532. Prequalification of bidders and offerors. 20 533. Security and performance bonds. 21 534. Cost or pricing data. 22 535. Printing. 23 § 531. Debarment or suspension. 24 (a) Authority.--After reasonable notice to the person 25 involved and reasonable opportunity for that person to be heard, 26 the head of a purchasing agency, after consultation with the 27 head of the using agency, shall have authority to debar a person 28 for cause from consideration for award of contracts for a period <-- 29 of not more than three years or to suspend a person from 30 consideration for award of contracts if there is probable cause 19970S0005B1890 - 50 -
1 for debarment for a period of not more than three months. FROM <--
2 CONSIDERATION FOR THE AWARD OF CONTRACTS. THE DECISION TO DEBAR
3 SHALL BE BASED UPON SUBSTANTIAL EVIDENCE THAT A CAUSE FOR
4 DEBARMENT OR SUSPENSION UNDER SUBSECTION (B) HAS OCCURRED. IN
5 MAKING THE DECISION OF WHETHER TO DEBAR A CONTRACTOR, THE HEAD
6 OF THE PURCHASING AGENCY SHALL TAKE INTO CONSIDERATION THE
7 SERIOUSNESS OF ANY VIOLATION AND ANY MITIGATING FACTORS. A
8 DEBARMENT MAY BE FOR A PERIOD OF NOT MORE THAN THREE YEARS. THE
9 HEAD OF THE PURCHASING AGENCY MAY SUSPEND A PERSON FROM
10 CONSIDERATION FOR AN AWARD OF CONTRACTS FOR A PERIOD OF UP TO
11 THREE MONTHS IF THERE IS PROBABLE CAUSE FOR DEBARMENT.
12 (b) Causes for debarment or suspension.--The causes for
13 debarment or suspension include:
14 (1) Commission of embezzlement, theft, forgery, bribery,
15 falsification or destruction of records, making false
16 statements or receiving stolen property.
17 (2) Commission of fraud or a criminal offense or other
18 improper conduct or knowledge of, approval of, or
19 acquiescence in such activities by a contractor or any
20 affiliate, officer, employee or other individual or entity
21 associated with:
22 (i) obtaining;
23 (ii) attempting to obtain; or
24 (iii) performing a public contract or subcontract.
25 The contractor's acceptance of the benefits derived from the
26 conduct shall be deemed evidence of such knowledge, approval
27 or acquiescence.
28 (3) Violation of Federal or State antitrust statutes.
29 (4) Violation of any Federal or State law regulating
30 campaign contributions.
19970S0005B1890 - 51 -
1 (5) Violations of any Federal or State environmental 2 law. 3 (6) Violation of any Federal or State law regulating 4 hours of labor, minimum wage standards or prevailing wage 5 standards; discrimination in wages; or child labor 6 violations. 7 (7) Violation of the act of June 2, 1915 (P.L.736, 8 No.338), known as the Workers' Compensation Act. 9 (8) Violation of any Federal or State law prohibiting 10 discrimination in employment. 11 (9) Debarment by any agency or department of the Federal 12 Government or by any other state. 13 (10) Three or more occurrences where a contractor has 14 been declared ineligible for a contract. 15 (11) Unsatisfactory performance, including, but not 16 limited to, any of the following: 17 (i) Failure to comply with terms of a Commonwealth 18 agency contract or subcontract, including, but not 19 limited to: willful failure to perform in accordance with 20 the terms of one or more contracts, a history of failure 21 to perform, or unsatisfactory performance of one or more 22 contracts. 23 (ii) Offering unbalanced bids. 24 (iii) Failure to complete the work in the time frame 25 specified in the contract. 26 (iv) Being declared in default on prior work or 27 project. 28 (v) Failure to submit documents, information or 29 forms as required by contract. 30 (vi) Making false statements or failing to provide 19970S0005B1890 - 52 -
1 information or otherwise to cooperate with the 2 contracting agency, the Office of State Inspector General 3 or other Commonwealth authorities. 4 (vii) Discrimination in violation of laws or 5 regulations in the conduct of business as a contractor. 6 (12) Any other act or omission indicating a lack of 7 skill, ability, capacity, quality control, business integrity 8 or business honesty that seriously and directly affect the 9 present responsibility of a contractor as determined by the 10 purchasing agency. 11 (c) Decision.--After the contractor has been given notice of 12 the potential debarment and the opportunity to be heard, the 13 head of a purchasing agency shall issue a written decision. The 14 decision shall: 15 (1) State the reasons for the action taken. 16 (2) Inform the contractor involved of the right to 17 judicial review as provided in subsection (e). 18 (d) Notice of decision.--A copy of the decision under 19 subsection (c) shall be delivered by registered mail to the 20 contractor, any other party intervening or any interested party 21 that has provided written notice to the purchasing agency of 22 that party's interest in the decision under subsection (c). 23 (e) Finality of decision and appeal.--A decision under 24 subsection (c) shall be final and conclusive unless the 25 contractor appeals to the Commonwealth Court under 42 Pa.C.S. § 26 763(a)(1) (relating to direct appeals from government agencies) 27 within 30 days after receipt of the decision. 28 (f) Effect of suspension/debarment.--Suspension or debarment 29 of a contractor, vendor or other person shall automatically 30 prohibit all Commonwealth agencies from awarding any contract to 19970S0005B1890 - 53 -
1 such contractor, vendor or other person or renewing or extending 2 any contract with such contractor, vendor or other person, 3 unless the contracting officer determines that there are 4 compelling reasons for such award, renewal or extension and the 5 head of the purchasing agency approves the determination. 6 § 532. Prequalification of bidders and offerors. 7 Prospective bidders and offerors may be prequalified for 8 particular types of supplies, services and construction. 9 § 533. Security and performance bonds. 10 (a) Contract for supplies or services.-- 11 (1) In the case of competitive sealed bidding or 12 competitive sealed proposals for a contract for supplies or 13 services, bidders or offerors may be required by the 14 contracting officer to provide bid or proposal security. Bid 15 or proposal security shall be in the form of a certified or 16 bank check or a bond provided by a surety company authorized 17 to do business in this Commonwealth or another form of 18 security as specified in the invitation for bids or request 19 for proposals. Bid or proposal security shall be at least in 20 the minimum amount or percentage of the amount of the bid as 21 shall be specified in the advertisement, invitation for bids 22 or request for proposals. 23 (2) When the invitation for bids or the request for 24 proposals requires security, noncompliance by the bidder or 25 offeror with the instructions in the invitation for bids or 26 request for proposals requires that the bid or proposal be 27 rejected unless it is determined that the bid or proposal 28 fails to comply with the security requirements in a 29 nonsubstantial manner. 30 (3) After the bids are opened, they shall be irrevocable 19970S0005B1890 - 54 -
1 for the period specified in the invitation for bids or the 2 request for proposals except as provided in section 512(f) 3 (relating to competitive sealed bidding). If a bidder or 4 offeror is permitted to withdraw its bid before award, no 5 action shall be had against the bidder or offeror or against 6 the bid or proposal security. 7 (4) A contractor may be required by the contracting 8 officer to provide a performance bond executed by a surety 9 company authorized to do business in this Commonwealth. In 10 lieu of a bond, a contractor may provide other security as 11 permitted by the head of the purchasing agency. The 12 performance bond or other required security shall be in an 13 amount determined by the head of the purchasing agency, and 14 it shall be conditioned upon the faithful performance of the 15 contract. 16 (b) Contract for construction.--Bid security and performance 17 bonds as required for contracts for construction are provided 18 for in sections 902 (relating to bid or proposal security) and 19 903 (relating to contract performance and payment bonds). 20 § 534. Cost or pricing data. 21 (a) Submission by contractor.--A contractor shall, except as 22 provided in subsection (c), submit cost or pricing data and 23 shall certify that, to the best of its knowledge and belief, the 24 cost or pricing data submitted was accurate, complete and 25 current as of a mutually determined specified date prior to the 26 date of: 27 (1) the award of any contract under section 513 28 (relating to competitive sealed proposals) or 515 (relating 29 to sole source procurement) where, under either section, the 30 total contract price is expected to exceed an amount 19970S0005B1890 - 55 -
1 established by the head of the purchasing agency; or 2 (2) the pricing of any change order or contract 3 modification which is expected to exceed an amount 4 established by the head of the purchasing agency. 5 (b) Price adjustment.--Any contract, change order or 6 contract modification under which a certificate is required 7 shall contain a provision that the price to the purchasing 8 agency, including profit or fee, shall be adjusted to exclude 9 any significant sums by which the purchasing agency finds that 10 the price was increased because the cost or pricing data 11 furnished by the contractor was inaccurate, incomplete or not 12 current as of the date agreed upon between the parties. 13 (c) Cost or pricing data not required.--The requirements of 14 this section need not be applied to contracts under any of the 15 following circumstances: 16 (1) When responsive proposals are received from two or 17 more offerors. 18 (2) When the contract price is based on established 19 catalog prices or market prices. 20 (3) When contract prices are set by statute or 21 regulation. 22 (4) When it is determined in writing by the contracting 23 officer that the requirements of this section may be waived 24 and the reasons for the waivers are stated in writing. 25 § 535. Printing. 26 No contract for printing shall be entered into with any 27 contractor until the purchasing agency is satisfied that the 28 contractor is the owner or lessee of machinery and equipment 29 necessary to properly and promptly perform any orders issued to 30 the contractor under the proposed printing contract. 19970S0005B1890 - 56 -
1 SUBCHAPTER E 2 TYPES OF CONTRACTS 3 Sec. 4 541. Approval of accounting system. 5 542. Multiterm contracts. 6 543. Effective contracts. 7 § 541. Approval of accounting system. 8 No contract type shall be used unless it has been determined 9 in writing by the head of the purchasing agency that: 10 (1) The proposed contractor's accounting system will 11 permit timely development of all necessary cost data in the 12 form required by the specific contract type contemplated. 13 (2) The proposed contractor's accounting system is 14 adequate to allocate costs in accordance with generally 15 accepted accounting principles. 16 Notwithstanding the preceding, a contract may be used without a 17 prior written determination where the contract is a firm fixed 18 price contract, or a contract awarded under section 516 19 (relating to emergency procurement). 20 § 542. Multiterm contracts. 21 (a) Specified period.--A contract for supplies, construction 22 or services may be entered into for a period of time deemed to 23 be in the best interests of the Commonwealth. The term of the 24 contract and conditions of renewal or extension, if any, shall 25 be included in the solicitation, and funds shall be available 26 for the first fiscal period at the time of contracting. Payment 27 and performance obligations for succeeding fiscal periods shall 28 be subject to the availability and appropriation of funds. 29 (b) Cancellation for unavailability of funds in succeeding 30 fiscal periods.--When funds are not appropriated or otherwise 19970S0005B1890 - 57 -
1 made available to support continuation of performance in a 2 subsequent fiscal period, the contract shall be canceled, and 3 the contractor shall be reimbursed for the reasonable value of 4 any nonrecurring costs incurred but not amortized in the price 5 of the supplies, services or construction delivered under the 6 contract. Such reimbursement shall not include loss of 7 anticipated profit, loss of use of money or administrative or 8 overhead costs. The cost of cancellation may be paid from any 9 appropriations available for that purpose. The contractor shall 10 not be entitled to any reimbursement where the Commonwealth 11 elects not to exercise a renewal or extension option provided 12 for in the contract. 13 § 543. Effective contracts. 14 (a) General rule.--Irrespective of the type of contract, no 15 contract shall be effective until executed by all necessary 16 Commonwealth officials as provided by law. 17 (b) Certain contracts.--Those Statewide requirements 18 contracts where the total dollar purchasing amount, based upon 19 estimated quantities, is in excess of $1,000,000 shall not be 20 effective unless first approved by the State Treasurer. The 21 $1,000,000 amount shall be adjusted each year by the department 22 to reflect the annual percentage change in the Composite 23 Construction Cost Index of the United States Department of 24 Commerce occurring in the one-year period ending December 31 25 each year. 26 SUBCHAPTER F 27 INSPECTION OF PLANT AND AUDIT OF RECORDS 28 Sec. 29 551. Right to inspect plant. 30 552. Right to audit records. 19970S0005B1890 - 58 -
1 § 551. Right to inspect plant. 2 The purchasing agency may, at reasonable times, inspect the 3 part of the plant or place of business of a contractor or any 4 subcontractor which is related to the performance of any 5 contract awarded or to be awarded by the purchasing agency. 6 § 552. Right to audit records. 7 (a) Audit of cost or pricing data.--The purchasing agency or 8 its designee may, at reasonable times and places, audit the 9 books and records of any person who has submitted cost or 10 pricing data under section 534 (relating to cost or pricing 11 data) to the extent that the books and records relate to the 12 cost or pricing data. A person who receives a contract, change 13 order or contract modification for which cost or pricing data is 14 required shall maintain the books and records that relate to the 15 cost or pricing data for three years from the date of final 16 payment under the contract unless a shorter period is otherwise 17 authorized by the purchasing agency in writing. 18 (b) Contract audit.--The purchasing agency may audit the 19 books and records of a contractor or any subcontractor under any 20 negotiated contract or subcontract other than a firm fixed-price 21 contract to the extent that the books and records relate to the 22 performance of the contract or subcontract. The books and 23 records shall be maintained by the contractor for a period of 24 three years from the date of final payment under the prime 25 contract and by the subcontractor for a period of three years 26 from the date of final payment under the prime contract unless a 27 shorter period is otherwise authorized by the purchasing agency 28 in writing. 29 SUBCHAPTER G 30 DETERMINATIONS AND REPORTS 19970S0005B1890 - 59 -
1 Sec. 2 561. Finality of determinations. 3 562. Anticompetitive practices. 4 563. Retention of procurement records. 5 564. Record of certain actions. 6 § 561. Finality of determinations. 7 The determinations required by the following sections are 8 final and conclusive unless they are clearly erroneous, 9 arbitrary, capricious or contrary to law: 10 Section 512(f) (relating to competitive sealed bidding). 11 Section 513(a) and (g) (relating to competitive sealed 12 proposals). 13 Section 515 (relating to sole source procurement). 14 Section 516 (relating to emergency procurement). 15 Section 518(e) (relating to competitive selection 16 procedures for certain services). 17 Section 519(f) (relating to selection procedure for 18 insurance and notary bonds). 19 Section 534(c) (relating to cost or pricing data). 20 Section 541 (relating to approval of accounting system). 21 § 562. Anticompetitive practices. 22 Collusion among bidders is unlawful. Every contract, 23 combination or conspiracy which unreasonably restrains trade 24 among bidders or offerors is unlawful. Contracts so arrived at 25 may be declared void at the option of the Commonwealth. In 26 addition to remedies available to the Commonwealth in the 27 Federal courts, there shall be the same remedies in the courts 28 of this Commonwealth. When any person has reason to believe 29 collusion or other anticompetitive practices have occurred among 30 any bidders or offerors, a notice of the relevant facts shall be 19970S0005B1890 - 60 -
1 transmitted to the Attorney General who shall investigate the 2 reports. 3 § 563. Retention of procurement records. 4 All procurement records, including any written determinations 5 issued in accordance with section 561 (relating to finality of 6 determinations), shall be retained for a minimum of three years 7 from the date of final payment under the contract and disposed 8 of in accordance with records retention guidelines and schedules 9 as provided by law. In accordance with applicable law, all 10 retained documents shall be made available to the State 11 Treasurer, Auditor General, General Counsel, Inspector General 12 and Attorney General upon request. 13 § 564. Record of certain actions. 14 The purchasing agency shall maintain a record listing all 15 contracts made under sections 514 (relating to small 16 procurements), 515 (relating to sole source procurement) and 516 17 (relating to emergency procurement) for a minimum of three years 18 from the date of final payment under the contract. The record 19 shall contain: 20 (1) Each contractor's name. 21 (2) The amount and type of each contract. 22 (3) A listing of the supplies, services or construction 23 procured under each contract. 24 CHAPTER 7 25 (Reserved) 26 CHAPTER 9 27 PROCUREMENT OF CONSTRUCTION AND DESIGN 28 PROFESSIONAL SERVICES 29 Sec. 30 901. Definitions. 19970S0005B1890 - 61 -
1 902. Bid or proposal security. 2 903. Contract performance security and payment bonds. 3 904. Copies of bonds. 4 905. Procurement of design professional services. 5 § 901. Definitions. 6 The following words and phrases when used in this chapter 7 shall have the meanings given to them in this section unless the 8 context clearly indicates otherwise: 9 "Design professional services." Those professional services 10 within the scope of the practice of architecture, geology, 11 engineering, landscape architecture or land surveying, including 12 studies, investigations, surveying, mapping, tests, evaluations, 13 consultations, comprehensive planning, program management, 14 conceptual design, plans and specifications, value engineering, 15 maintenance manuals and other related services associated with 16 research, planning, development, design, construction, 17 alteration or repair of real property. The term includes 18 services provided under the supervision of a professional 19 engineer to develop engineering software which will aid design 20 professionals in performing their work. The term does not 21 include those services which are not exclusively within the 22 scope of architecture, geology, engineering or landscape 23 architecture, but which are related to capital improvements such 24 as, but not limited to, environmental hygienics, construction 25 management as described in section 322 (relating to specific 26 construction powers, duties and procedures), exhibit design, 27 fine arts or lesser arts and crafts, even though an architect, 28 geologist, engineer or landscape architect may provide such 29 services. 30 § 902. Bid or proposal security. 19970S0005B1890 - 62 -
1 (a) Requirement for bid security.--Bidders or offerors may 2 be required to provide bid or proposal security for construction 3 contracts. Bid or proposal security shall be in the form of a 4 certified or bank check or a bond provided by a surety company 5 authorized to do business in this Commonwealth or another form 6 of security as specified in the invitation for bids or request 7 for proposals. 8 (b) Amount of bid or proposal security.--Bid security shall 9 be at least in the minimum amount or percentage of the amount of 10 the bid as shall be specified in the advertisement, the 11 invitation for bids or the request for proposals. 12 (c) Rejection of bids or proposals.--When the invitation for 13 bids or the request for proposals requires security, 14 noncompliance with the instructions in the invitation for bids 15 or the request for proposals requires that the bid or proposal 16 be rejected unless it is determined that the bid or proposal 17 fails to comply with the security requirements in a 18 nonsubstantial manner. 19 (d) Withdrawal of bids.--After the bids are opened, they 20 shall be irrevocable for the period specified in the invitation 21 for bids except as provided in section 512(f) (relating to 22 competitive sealed bidding). If a bidder is permitted to 23 withdraw its bid before award, no action shall be had against 24 the bidder or the bid security. 25 § 903. Contract performance security and payment bonds. 26 (a) When required and amounts.--For construction contracts 27 awarded for amounts between $25,000 and $100,000, the purchasing 28 agency shall require contract performance security, in an amount 29 equal to at least 50% of the contract price, as the purchasing 30 agency, in its discretion, determines necessary to protect the 19970S0005B1890 - 63 -
1 interests of the Commonwealth. When a construction contract is 2 awarded in excess of $100,000, the following bonds shall be 3 delivered to the purchasing agency and shall be binding on the 4 parties upon the execution of the contract: 5 (1) A performance bond, executed by a surety company 6 authorized to do business in this Commonwealth and made 7 payable to the Commonwealth, in an amount equal to 100% of 8 the price specified in the contract and conditioned upon the 9 faithful performance of the contract in accordance with the 10 plans, specifications and conditions of the contract. 11 (2) A payment bond, executed by a surety company 12 authorized to do business in this Commonwealth and made 13 payable to the Commonwealth, in an amount equal to 100% of 14 the price specified in the contract and conditioned upon the 15 prompt payment for all materials furnished or labor supplied 16 or performed in the prosecution of the work. Labor or 17 materials include public utility services and reasonable 18 rentals of equipment for the periods when the equipment is 19 actually used at the site. 20 (b) Protection.--A performance bond shall be solely for the 21 protection of the purchasing agency which awarded the contract. 22 A payment bond shall be solely for the protection of claimants 23 supplying labor or materials to the prime contractor to whom the 24 contract was awarded or to any of its subcontractors in the 25 prosecution of the work provided for in the contract, whether or 26 not the labor or materials constitute a component part of the 27 construction. 28 (c) Authority to require additional bonds.--Nothing in this 29 section shall be construed to limit the authority of the 30 Commonwealth agency to require a performance bond, payment bond 19970S0005B1890 - 64 -
1 or other security in addition to those bonds or in circumstances 2 other than specified in subsection (a). 3 (d) Actions on payment bonds.-- 4 (1) Subject to paragraph (2), any claimant who has 5 performed labor or furnished material in the prosecution of 6 the work provided for in any contract for which a payment 7 bond has been given under subsection (a) and who has not been 8 paid in full before the expiration of 90 days after the day 9 on which the claimant performed the last of the labor or 10 furnished the last of the materials for which it claims 11 payments may bring an action on the payment bond in its own 12 name, in assumpsit, to recover any amount due it for the 13 labor or material and may prosecute the action to final 14 judgment and have execution on the judgment. 15 (2) Any claimant who has a direct contractual 16 relationship with any subcontractor of the prime contractor 17 who gave the payment bond but has no contractual 18 relationship, express or implied, with the prime contractor 19 may bring an action on the payment bond only if it has given 20 written notice to the contractor within 90 days from the date 21 on which the claimant performed the last of the labor or 22 furnished the last of the materials for which it claims 23 payment, stating with substantial accuracy the amount and the 24 name of the person for whom the work was performed or to whom 25 the material was furnished. 26 (3) Notice shall be served by registered mail in an 27 envelope addressed to the contractor at any place where its 28 office is regularly maintained for the transaction of 29 business or served in any manner in which legal process may 30 be served in the manner provided by law for the service of a 19970S0005B1890 - 65 -
1 summons except that the service need not be made by a public 2 officer. 3 (e) Adjustment of threshold amount.--The dollar thresholds 4 set forth in subsection (a) shall be adjusted annually by the 5 department to reflect the annual percentage change in the 6 Composition Construction Cost Index of the United States 7 Department of Commerce occurring in the one-year period ending 8 on December 31 of each year. 9 § 904. Copies of bonds. 10 (a) Copies of bonds.--The purchasing agency shall furnish a 11 copy of any payment bond and the contract for which the bond was 12 given to any person who makes an application for the copy. 13 (b) Fee for copies.--Each applicant shall pay for each copy 14 of any payment bond a fee fixed by the purchasing agency to 15 cover the actual cost of the preparation of the copy. 16 (c) Evidence.--A copy of any payment bond and of the 17 contract for which the bond was given constitutes prima facie 18 evidence of the contents, execution and delivery of the original 19 of the bond and contract. 20 § 905. Procurement of design professional services. 21 (a) Applicability.--Design professional services shall be 22 procured as provided in this section except as authorized by 23 sections 514 (relating to small procurements), 515 (relating to 24 sole source procurement) and 516 (relating to emergency 25 procurement). 26 (b) Policy.--It is the policy of this Commonwealth to 27 publicly announce all requirements for design professional 28 services and to award contracts for design professional services 29 on the basis of demonstrated competence and qualification for 30 the types of services required. There shall be a committee to 19970S0005B1890 - 66 -
1 review the qualifications, experience and work of design 2 professionals seeking contracts with purchasing agencies. 3 (c) Selection committees for Department of Transportation, 4 Department of Environmental Protection, Department of 5 Conservation and Natural Resources and State-affiliated 6 entities.--Where they are authorized by law to act as purchasing 7 agency for design professional services, the Department of 8 Transportation, the Department of Environmental Protection, the 9 Department of Conservation and Natural Resources and State- 10 affiliated entities shall each establish as many selection 11 committees as the department deems appropriate and a procedure 12 for the selection of committee members. 13 (d) Selection committee for all other Commonwealth 14 agencies.--Except as provided for in subsection (c), all 15 purchasing agencies shall use the selection committee appointed 16 by the Governor which shall be composed of five members, none of 17 whom shall be employees of the Commonwealth or hold any elective 18 office or office in any political party. The members shall be 19 architects, engineers or other persons knowledgeable in 20 construction. The members shall serve for terms of two years and 21 shall not be removed except for cause. Of the original members, 22 three shall serve for terms of two years and two for terms of 23 one year. Thereafter, all terms shall be for two years. Each 24 member shall be reimbursed for reasonable travel and other 25 expenses incurred incident to attendance at meetings and to 26 assigned duties and also a per diem allowance in accordance with 27 Commonwealth travel policies. 28 (e) Procedure for selection committees.--The selection 29 committees shall use the procedure set forth in this subsection: 30 (1) The committee shall give public notice of projects 19970S0005B1890 - 67 -
1 requiring design services and publicly recommend to the 2 purchasing agency three qualified design professionals for 3 each project. 4 (2) If desired, the committee may conduct discussions 5 with three or more professionals regarding anticipated design 6 concepts and proposed methods of approach to the assignment. 7 The committee shall select, based upon criteria established 8 by the head of the purchasing agency, no less than three 9 design professionals deemed to be the most highly qualified 10 to provide the services required. In exercising its 11 responsibility, the committee shall consider the following 12 factors: 13 (i) An equitable distribution of contracts to design 14 professionals. 15 (ii) Particular capability to perform the design or 16 construction services for the contract being considered. 17 (iii) Geographic proximity of the design 18 professional to the proposed facility. 19 (iv) The design professional selected has the 20 necessary available personnel to perform the services 21 required by the project. 22 (v) Any other relevant circumstances peculiar to the 23 proposed contract. 24 (f) Design professionals.--Except as provided for in 25 subsection (g), the head of the purchasing agency shall select 26 design professionals as follows: 27 (1) Where the amount of the base construction allocation 28 is less than $20,000,000, the head of the purchasing agency 29 shall choose one of the three firms approved by the selection 30 committee. The fee to be paid to the appointed design 19970S0005B1890 - 68 -
1 professional may be established by the selection committee or 2 may be negotiated at the discretion of the head of the 3 purchasing agency. The $20,000,000 threshold shall be 4 adjusted by the department to reflect the annual percentage 5 change in the Composite Construction Cost Index of the United 6 States Department of Commerce occurring in the one-year 7 period ending December 31 each year. 8 (2) Where the amount of base construction allocation is 9 in excess of or equal to $20,000,000, as annually adjusted, 10 the head of the purchasing agency shall choose one of the 11 three firms approved by the selection committee to begin 12 contract negotiations. The fee to be paid to the design 13 professional and the terms of the contract between the design 14 professional and the department shall be negotiated by the 15 head of the purchasing agency. In negotiating the contract 16 and the fee, the head of the purchasing agency shall take 17 into account the estimated value, scope, complexity, 18 uniqueness and the professional nature of the services to be 19 rendered. In the event the head of the purchasing agency is 20 unable to negotiate a satisfactory contract or fee with the 21 appointed design professional, negotiations with that design 22 professional shall be terminated and the head of the 23 purchasing agency shall commence negotiations with one of the 24 other firms chosen by the selection committee. In the event 25 the head of the purchasing agency is unable to negotiate a 26 satisfactory contract or fee with the second firm, the head 27 of the purchasing agency shall terminate negotiations with 28 the second design professional and commence negotiation with 29 the third firm. In the event the head of the purchasing 30 agency is unable to negotiate a satisfactory contract with 19970S0005B1890 - 69 -
1 any of the selected firms, the selection committee shall 2 choose additional qualified firms and the head of the 3 purchasing agency shall continue negotiations in accordance 4 with this subsection until an agreement is reached. 5 (g) Selection method for Department of Transportation, 6 Department of Conservation and Natural Resources, Department of 7 Environmental Protection and State-affiliated entities.--In the 8 event the Department of Transportation, the Department of 9 Conservation and Natural Resources, the Department of 10 Environmental Protection or a State-affiliated entity otherwise 11 authorized by law to use its own selection committee requires 12 the services of a design professional, the head of the 13 purchasing agency or a State-affiliated entity shall choose one 14 of the three firms approved by the selection committee. The head 15 of the purchasing agency or a State-affiliated entity shall 16 negotiate with the firm determined to be the highest qualified 17 firm for design professional services at a fee which is 18 determined to be fair and reasonable to the Commonwealth. In 19 making this decision, the head of the purchasing agency shall 20 take into account the estimated value, scope, complexity and 21 professional nature of the services to be rendered. Should the 22 head of the purchasing agency be unable to negotiate a 23 satisfactory contract with the firm considered to be the most 24 qualified at a fee he determines to be fair and reasonable to 25 the Commonwealth, negotiations with that firm shall be formally 26 terminated. The head of the purchasing agency shall then 27 undertake negotiations with the firm he determines to be the 28 second highest qualified firm. Failing accord with the second 29 most qualified firm, the head of the purchasing agency shall 30 formally terminate negotiations and then undertake negotiations 19970S0005B1890 - 70 -
1 with the third highest qualified firm. Should the head of the 2 purchasing agency be unable to negotiate a satisfactory contract 3 with any of the selected firms, the committee shall select 4 additional qualified firms, and the head of the purchasing 5 agency shall continue negotiations in accordance with this 6 section until an agreement is reached. 7 CHAPTER 11 8 (RESERVED) 9 CHAPTER 13 10 (Reserved) 11 CHAPTER 15 12 SUPPLY MANAGEMENT 13 Sec. 14 1501. Definitions. 15 1502. Supply management regulations. 16 1503. Proceeds from sale or disposal of surplus supplies. 17 1504. Exception. 18 § 1501. Definitions. 19 The following words and phrases when used in this chapter 20 shall have the meanings given to them in this section unless the 21 context clearly indicates otherwise: 22 "Excess supplies." All nonexpendable supplies having a 23 remaining useful life but which are no longer required by the 24 using agency in possession of the supplies. 25 "Expendable supplies." All tangible supplies other than 26 nonexpendable supplies. 27 "Nonexpendable supplies." All tangible supplies having an 28 original acquisition cost of over $100 per unit and a probable 29 useful life of more than one year. 30 "Supplies." Supplies owned by Commonwealth agencies. 19970S0005B1890 - 71 -
1 "Surplus supplies." Nonexpendable supplies no longer having 2 any use to any Commonwealth agency. The term includes obsolete 3 supplies, scrap materials and nonexpendable supplies that have 4 completed their useful life cycle. The term does not include 5 road or bridge materials or equipment that have been declared 6 surplus by the Department of Transportation under section 510 of 7 the act of April 9, 1929 (P.L.177, No.175), known as The 8 Administrative Code of 1929. 9 § 1502. Supply management regulations. 10 For executive and independent agencies, the department shall 11 establish policy and may promulgate regulations governing: 12 (1) The management of supplies during their entire life 13 cycle. 14 (2) The sale, lease or disposal of surplus supplies by 15 public auction, competitive sealed bidding or other 16 appropriate method designated by the department. However, no 17 employee of the owning or disposing agency shall be entitled 18 to purchase any of these supplies except when the sale price 19 of the surplus supply is less than the amount established by 20 the department for permissible purchases by such employees. 21 (3) Transfer of excess supplies. 22 § 1503. Proceeds from sale or disposal of surplus supplies. 23 The proceeds from the sale, lease or disposal of surplus 24 supplies by an executive or independent agency shall be paid 25 into the State Treasury and deposited in the fund out of which 26 the supplies sold was originally purchased by the appropriate 27 credit to the then-current appropriation. The costs incurred by 28 the department in advertising or selling the supplies shall be 29 deducted from the purchase price, and that amount shall be an 30 executively authorized augmentation to the appropriation from 19970S0005B1890 - 72 -
1 which the costs were paid by the department. 2 § 1504. Exception. 3 This chapter shall not apply to actions taken by the Office 4 of Attorney General under 42 Pa.C.S. Ch. 68 (relating to 5 controlled substances forfeitures). 6 CHAPTER 17 7 LEGAL AND CONTRACTUAL REMEDIES 8 Subchapter 9 A. General Provisions 10 B. Prelitigation Resolution of Controversies 11 C. Board of Claims 12 D. Solicitations or Awards in Violation of Law 13 E. Interest 14 SUBCHAPTER A 15 GENERAL PROVISIONS 16 Sec. 17 1701. Definitions. 18 1702. Sovereign immunity. 19 § 1701. Definitions. 20 The following words and phrases when used in this chapter 21 shall have the meanings given to them in this section unless the 22 context clearly indicates otherwise: 23 "Claimant." A person filing a claim with the Board of 24 Claims. 25 § 1702. Sovereign immunity. 26 (a) General rule.--The General Assembly under section 11 of 27 Article I of the Constitution of Pennsylvania reaffirms 28 sovereign immunity, and, except as otherwise provided in this 29 chapter, no provision of this part shall constitute a waiver of 30 sovereign immunity for the purpose of 1 Pa.C.S. § 2310 (relating 19970S0005B1890 - 73 -
1 to sovereign immunity reaffirmed; specific waiver) or otherwise. 2 (b) Exception.--The General Assembly under section 11 of 3 Article I of the Constitution of Pennsylvania does hereby waive 4 sovereign immunity as a bar to claims against Commonwealth 5 agencies arising under this chapter but only to the extent set 6 forth in this chapter. 7 SUBCHAPTER B 8 PRELITIGATION RESOLUTION OF CONTROVERSIES 9 Sec. 10 1711. Authority to resolve protests of solicitations or 11 awards. 12 1712. Authority to resolve contract and breach of contract 13 controversies. 14 § 1711. Authority to resolve protests of solicitations or 15 awards. 16 (a) Right to protest.--An actual or prospective bidder, 17 offeror or contractor who is aggrieved in connection with the 18 solicitation or award of a contract may protest to the head of 19 the purchasing agency in writing. All protests under this 20 subsection must be made within seven days after the protestant 21 knows or should have known of the facts giving rise to the 22 protest. If a protest is submitted by a protestant who did not 23 submit a bid, the protest must be received by the head of the 24 purchasing agency prior to the bid opening time or the proposal 25 receipt date or it shall be considered untimely and can be 26 disregarded by the purchasing agency. 27 (b) Authority to resolve protests.--The head of the 28 purchasing agency shall have the authority to settle and resolve 29 a protest of an aggrieved bidder, offeror or contractor, actual 30 or prospective, concerning the solicitation or award of a 19970S0005B1890 - 74 -
1 contract. 2 (c) Decision.--If the protest is not resolved by mutual 3 agreement, the head of the purchasing agency shall promptly, but 4 in no event later than 120 days from the filing of the protest, 5 issue a decision in writing. The decision shall: 6 (1) State the reasons for the action taken. 7 (2) Inform the protestant of his right to file an action 8 in Commonwealth Court as provided in subsection (e). 9 (d) Notice of decision.--A copy of the decision under 10 subsection (c) shall be delivered by registered mail to the 11 protestant and any other person determined by the head of the 12 purchasing agency to be affected by the decision. 13 (e) Finality of decision.--A decision under subsection (c) 14 shall be final and conclusive unless a person adversely affected 15 by the decision files an action based on subsection (a) in 16 Commonwealth Court within 14 days of receipt of the decision. No 17 action may be commenced in Commonwealth Court under this 18 subsection until the protestant has exhausted the administrative 19 remedies provided for in this section. 20 (f) Stay of procurements during protests.--In the event of a 21 timely protest under subsection (a) and until the time has 22 elapsed for the protestant to file an action in Commonwealth 23 Court, the purchasing agency shall not proceed further with the 24 solicitation or with the award of the contract unless and until 25 the head of the purchasing agency, after consultation with the 26 head of the using agency, makes a written determination that the 27 protest is clearly without merit or that award of the contract 28 without delay is necessary to protect substantial interests of 29 the Commonwealth. 30 § 1712. Authority to resolve contract and breach of contract 19970S0005B1890 - 75 -
1 controversies. 2 (a) Applicability.--This section applies to controversies 3 between a Commonwealth agency and a contractor which arise under 4 or by virtue of a contract between them, including controversies 5 based upon breach of contract, mistake, misrepresentation or 6 other cause for contract modification or rescission. Prior to 7 filing a claim under this section with the Board of Claims under 8 the exclusive jurisdiction provided in the act of May 20, 1937 9 (P.L.728, No.193), referred to as the Board of Claims Act, the 10 claim must first be filed in writing with the contracting 11 officer within six months after it accrues and not thereafter. 12 (b) Authority.--The contracting officer is authorized to 13 settle and resolve a controversy described in subsection (a). 14 (c) Decision.--If the controversy is not resolved by mutual 15 agreement, the head of the purchasing agency shall promptly 16 issue a decision in writing. The decision shall: 17 (1) State the reasons for the action taken. 18 (2) Inform the contractor of its right to administrative 19 and judicial review as provided in this chapter. 20 (d) Notice of decision.--A copy of the decision under 21 subsection (c) shall be delivered by registered mail to the 22 contractor. 23 (e) Finality of decision.--The decision under subsection (c) 24 shall be final and conclusive unless the contractor files a 25 claim with the Board of Claims within 30 days of receipt of the 26 decision. 27 (f) Failure to render timely decision.--If the contracting 28 officer does not issue the written decision required under 29 subsection (c) within 120 days after written request for a final 30 decision or within a longer period as may be agreed upon by the 19970S0005B1890 - 76 -
1 parties, then the contractor may proceed as if an adverse 2 decision had been received. 3 SUBCHAPTER C 4 BOARD OF CLAIMS 5 Sec. 6 1721. Function of Board of Claims. 7 1722. (Reserved). 8 1723. (Reserved). 9 1724. (Reserved). 10 1725. Hearings, decisions and awards. 11 1726. Appeals. 12 § 1721. Function of Board of Claims. 13 The Board of Claims created under the act of May 20, 1937 14 (P.L.728, No.193), referred to as the Board of Claims Act, shall 15 be constituted and administered as provided in that act. 16 § 1722. (Reserved). 17 § 1723. (Reserved). 18 § 1724. (Reserved). 19 § 1725. Hearings, decisions and awards. 20 (a) General rule.--All hearings before the Board of Claims 21 under this part shall be in accordance with the procedure set 22 forth in the act of May 20, 1937 (P.L.728, No.193), referred to 23 as the Board of Claims Act. 24 (b) Hearing and decision.--All hearings before the Board of 25 Claims or hearings before a hearing panel shall be public and 26 the proceedings shall be de novo. Any prior determinations by 27 administrative officials shall not be final or conclusive except 28 as provided in section 561 (relating to finality of 29 determinations). The board or hearing panel shall make a 30 decision within a reasonable time from the date of the hearing. 19970S0005B1890 - 77 -
1 The board shall promptly decide the contract or breach of 2 contract controversy and, if appropriate, make an award of a sum 3 that it determines the claimant is entitled to receive. 4 (c) Certification of award.--The Board of Claims shall 5 certify an award for the purpose of entering the same as a 6 judgment in any court of record. 7 (d) Public records.--All papers filed under this subchapter 8 shall be a public record to the extent provided in the act of 9 June 21, 1957 (P.L.390, No.212), referred to as the Right-to- 10 Know Law, and shall be available to the public as provided in 11 that act. 12 § 1726. Appeals. 13 Any person, including a Commonwealth agency, aggrieved by a 14 decision of the Board of Claims may appeal to the Commonwealth 15 Court under 42 Pa.C.S. § 763(a)(1) (relating to direct appeals 16 from government agencies) within 30 days after certification of 17 the decision. 18 SUBCHAPTER D 19 SOLICITATIONS OR AWARDS IN VIOLATION OF LAW 20 Sec. 21 1741. Applicability. 22 1742. Remedies prior to execution of contract. 23 1743. Remedies after execution of contract. 24 § 1741. Applicability. 25 The provisions of this subchapter apply where it is 26 determined by the contracting officer or the court that a 27 solicitation or award of a contract is in violation of law. 28 § 1742. Remedies prior to execution of contract. 29 If prior to execution of a contract it is determined that a 30 solicitation or proposed award of a contract is in violation of 19970S0005B1890 - 78 -
1 law, then the remedies are limited to cancellation of the 2 solicitation or proposed award or revision of the solicitation 3 or proposed award to comply with the law. 4 § 1743. Remedies after execution of contract. 5 If after the execution of a contract it is determined that a 6 solicitation or award of a contract is in violation of law, 7 then: 8 (1) If the person awarded the contract has not acted 9 fraudulently or in bad faith: 10 (i) the contract may be ratified and affirmed 11 provided it is determined by the purchasing agency that 12 doing so is in the best interest of the Commonwealth; 13 (ii) the contract, with the consent of all parties, 14 may be modified to comply with the law; or 15 (iii) the contract may be terminated and the person 16 awarded the contract shall be compensated for the actual 17 expenses reasonably incurred under the contract prior to 18 the termination. Such compensation shall not include loss 19 of anticipated profit, loss of use of money or 20 administrative or overhead costs. 21 (2) If the person awarded the contract has acted 22 fraudulently or in bad faith: 23 (i) the contract may be declared void; 24 (ii) the contract, with the consent of all parties, 25 may be modified to comply with the law; or 26 (iii) the contract may be ratified and affirmed, 27 provided it is determined by the purchasing agency, if 28 that action is in the best interest of the Commonwealth 29 and without prejudice to the right of the Commonwealth 30 agency to damages as may be appropriate. 19970S0005B1890 - 79 -
1 SUBCHAPTER E 2 INTEREST 3 Sec. 4 1751. Interest. 5 § 1751. Interest. 6 Interest on amounts ultimately determined to be due shall be 7 payable at the statutory rate applicable to judgments from the 8 date the claim was filed with the contracting officer. Interest 9 on claims arising out of the provisions of section 1507 of the 10 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 11 Code, shall be payable as provided therein. 12 CHAPTER 19 13 INTERGOVERNMENTAL RELATIONS 14 Sec. 15 1901. Definitions. 16 1902. Cooperative purchasing authorized. 17 1903. Sale, acquisition or use of supplies by a public 18 procurement unit. 19 1904. Cooperative use of supplies or services. 20 1905. Joint use of facilities. 21 1906. Supply of personnel, information and technical services. 22 1907. Use of payments received by a supplying public 23 procurement unit. 24 1908. Compliance of public procurement units. 25 1909. Review of procurement requirements. 26 1910. Contract controversies. 27 1911. Immunity. 28 1912. Investment management agreements. 29 § 1901. Definitions. 30 The following words and phrases when used in this chapter 19970S0005B1890 - 80 -
1 shall have the meanings given to them in this section unless the 2 context clearly indicates otherwise: 3 "Cooperative purchasing." Procurement conducted by or on 4 behalf of more than one public procurement unit or by a public 5 procurement unit with an external procurement activity. 6 "External procurement activity." A buying organization not 7 located in this Commonwealth which if located in this 8 Commonwealth would qualify as a public procurement unit. An 9 agency of the United States is an external procurement activity. 10 "Local public procurement unit." A political subdivision, 11 public authority, educational, health or other institution and, 12 to the extent provided by law, any other entity, including a 13 council of governments or an area government, which expends 14 public funds for the procurement of supplies, services and 15 construction, any nonprofit corporation operating a charitable 16 hospital and any nonprofit fire company, nonprofit rescue 17 company and nonprofit ambulance company. 18 "Public procurement unit." A local public procurement unit 19 or a purchasing agency. 20 § 1902. Cooperative purchasing authorized. 21 A public procurement unit may either participate in, sponsor, 22 conduct or administer a cooperative purchasing agreement for the 23 procurement of any supplies, services or construction with one 24 or more public procurement units or external procurement 25 activities in accordance with an agreement entered into between 26 the participants. Cooperative purchasing may include, but is not 27 limited to, joint or multiparty contracts between public 28 procurement units and open-ended purchasing agency contracts 29 which are made available to local public procurement units. 30 § 1903. Sale, acquisition or use of supplies by a public 19970S0005B1890 - 81 -
1 procurement unit. 2 A public procurement unit may sell to, acquire from or use 3 any supplies belonging to another public procurement unit or 4 external procurement activity independent of the requirements of 5 Chapters 5 (relating to source selection and contract formation) 6 and 15 (relating to supply management). 7 § 1904. Cooperative use of supplies or services. 8 A public procurement unit may enter into an agreement, 9 independent of the requirements of Chapters 5 (relating to 10 source selection and contract formation) and 15 (relating to 11 supply management), with any other public procurement unit or 12 external procurement activity for the cooperative use of 13 supplies or services under the terms agreed upon between the 14 parties. 15 § 1905. Joint use of facilities. 16 Any public procurement unit may enter into agreements for the 17 common use or lease of warehousing facilities, capital equipment 18 and other facilities with another public procurement unit or an 19 external procurement activity under the terms agreed upon 20 between the parties. 21 § 1906. Supply of personnel, information and technical 22 services. 23 (a) Supply of personnel.--Upon written request from another 24 public procurement unit or external procurement activity, a 25 public procurement unit may provide personnel to the requesting 26 public procurement unit or external procurement activity. The 27 public procurement unit or external procurement activity making 28 the request shall compensate the public procurement unit 29 providing the personnel the direct and indirect cost of 30 furnishing the personnel in accordance with an agreement between 19970S0005B1890 - 82 -
1 the parties. 2 (b) Supply of services.--The informational, technical and 3 other services of any public procurement unit may be made 4 available to any other public procurement unit or external 5 procurement activity. However, the requirements of the public 6 procurement unit tendering the services shall have precedence 7 over the requesting public procurement unit or external 8 procurement activity. The requesting public procurement unit or 9 external procurement activity shall compensate for the expenses 10 of the services provided in accordance with an agreement between 11 the parties. 12 (c) Information services.--Upon request, the department may 13 make available to public procurement units or external 14 procurement activities the following services, among others: 15 (1) Standard forms. 16 (2) Printed manuals. 17 (3) Product specifications and standards. 18 (4) Quality assurance testing services and methods. 19 (5) Qualified products lists. 20 (6) Source information. 21 (7) Common use commodities listings. 22 (8) Supplier prequalification information. 23 (9) Supplier performance ratings. 24 (10) Debarred and suspended bidders lists. 25 (11) Forms for invitations for bids, requests for 26 proposals, instructions to bidders, general contract 27 provisions and other contract forms. 28 (12) Contracts or published summaries of contracts, 29 including price and time of delivery information. 30 (d) Technical services.--The department may provide the 19970S0005B1890 - 83 -
1 following technical services, among others: 2 (1) Development of products specifications. 3 (2) Development of quality assurance test methods, 4 including receiving, inspection and acceptance procedures. 5 (3) Use of product testing and inspection facilities. 6 (4) Use of personnel training programs. 7 (e) Fees.--The department may enter into contractual 8 arrangements and publish a schedule of fees for the services 9 provided under subsections (c) and (d). 10 § 1907. Use of payments received by a supplying public 11 procurement unit. 12 All payments from any public procurement unit or external 13 procurement activity received by a public procurement unit 14 supplying personnel or services shall be available to the 15 supplying public procurement unit. 16 § 1908. Compliance of public procurement units. 17 Where the public procurement unit or external procurement 18 activity administering a cooperative purchase complies with the 19 requirements of this part, any public procurement unit 20 participating in the purchase shall be deemed to have complied 21 with this part. Public procurement units may not enter into a 22 cooperative purchasing agreement for the purpose of 23 circumventing this part. 24 § 1909. Review of procurement requirements. 25 To the extent possible, the department may collect 26 information concerning the type, cost, quality and quantity of 27 commonly used supplies, services or construction being procured 28 or used by Commonwealth agencies. The department may also 29 collect this information from local procurement units. The 30 department may make this information available to any public 19970S0005B1890 - 84 -
1 procurement unit upon request.
2 § 1910. Contract controversies.
3 (a) Public procurement unit subject to certain legal and
4 contractual remedies.--Under a cooperative purchasing agreement,
5 controversies arising between an administering public
6 procurement unit subject to Chapter 17 (relating to legal and
7 contractual remedies) and its bidders, offerors or contractors
8 shall be resolved in accordance with Chapter 17.
9 (b) Local public procurement unit not subject to certain
10 legal and contractual remedies.--Any local public procurement
11 unit which is not subject to Chapter 17 is authorized to:
12 (1) Enter into an agreement with the Board of Claims to
13 use the board to resolve controversies between the local
14 public procurement unit and its contractors, whether or not
15 the controversy arose from a cooperative purchasing
16 agreement.
17 (2) Enter into an agreement with another local public
18 procurement unit or external procurement activity to
19 establish procedures or use existing procedures of the unit
20 or activity to resolve controversies with contractors,
21 whether or not the controversy arose under a cooperative
22 purchasing agreement.
23 § 1911. Immunity.
24 A public procurement unit which provides personnel, property,
25 supplies or services to another public procurement unit shall be
26 immune from liability for any damages which arise out of the use
27 of such items PERSONNEL, PROPERTY, SUPPLIES OR SERVICES provided <--
28 under this chapter.
29 § 1912. Investment management agreements.
30 This chapter shall not apply to any contract for investment
19970S0005B1890 - 85 -
1 management services, or any proposed contract for such services, 2 between a local public procurement unit and the Treasury 3 Department. 4 CHAPTER 21 5 SMALL AND DISADVANTAGED BUSINESSES 6 Sec. 7 2101. Policy. 8 2102. Definitions. 9 2103. Regulations. 10 2104. Duties of department. 11 2105. Bonding and progress payments. 12 2106. Business assistance offices. 13 2107. Report to General Assembly. 14 2108. Compliance with Federal requirements. 15 § 2101. Policy. 16 The policy of this Commonwealth is to assist small and 17 disadvantaged businesses in learning how to do business with 18 Commonwealth agencies. The department shall implement this 19 policy in accordance with regulations promulgated by the 20 department. 21 § 2102. Definitions. 22 Subject to section 2103 (relating to regulations), the 23 following words and phrases when used in this chapter shall have 24 the meanings given to them in this section unless the context 25 clearly indicates otherwise: 26 "Disadvantaged business." A small business which is owned or 27 controlled by a majority of persons, not limited to members of 28 minority groups, who have been deprived of the opportunity to 29 develop and maintain a competitive position in the economy 30 because of social disadvantages. 19970S0005B1890 - 86 -
1 "Small business." A business in the United States which is 2 independently owned, is not dominant in its field of operation 3 and meets the criteria established by the Department of General 4 Services, by regulation, for qualification as a small business. 5 The department, through regulation, shall have the authority to 6 establish the maximum number of persons a company may employ to 7 qualify as a small business, which number shall not exceed 50 8 persons. 9 § 2103. Regulations. 10 The department shall establish policy for executive and those 11 independent agencies for which the department acts as purchasing 12 agency and may promulgate regulations establishing detailed 13 definitions of the words and phrases defined in section 2102 14 (relating to definitions) using, in addition to the criteria set 15 forth in section 2102, other criteria as it deems appropriate, 16 including the number of employees and the dollar volume of 17 business. State-affiliated entities shall implement the policy 18 for their procurement programs. 19 § 2104. Duties of department. 20 The department shall have the following duties: 21 (1) Where feasible, provide appropriate staff who shall 22 be responsible to the department and who shall serve within 23 designated Commonwealth agencies to assist small and 24 disadvantaged businesses in this Commonwealth in learning how 25 to do business with Commonwealth agencies. 26 (2) Give special publicity to procurement procedures and 27 issue special publications designed to assist small and 28 disadvantaged businesses in learning how to do business with 29 Commonwealth agencies. 30 (3) Compile, maintain and make available source lists of 19970S0005B1890 - 87 -
1 small and disadvantaged businesses for the purpose of 2 encouraging procurement from small and disadvantaged 3 businesses. 4 (4) Include small and disadvantaged businesses on 5 solicitation mailing lists. 6 (5) Assure that small and disadvantaged businesses are 7 solicited on each procurement for which the businesses may be 8 suited. 9 (6) Develop special training programs to assist small 10 and disadvantaged businesses in learning how to do business 11 with Commonwealth agencies. 12 § 2105. Bonding and progress payments. 13 (a) Bonding.--Notwithstanding other provisions of this part, 14 a purchasing agency may reduce the level or change the types of 15 bonding normally required or accept alternative forms of 16 security to the extent reasonably necessary to encourage 17 procurement from small and disadvantaged businesses. 18 (b) Progress payments.--A purchasing agency may make special 19 provisions for progress payments as it deems reasonably 20 necessary to encourage procurement from small and disadvantaged 21 businesses. 22 § 2106. Business assistance offices. 23 The department shall establish, as it deems appropriate, 24 business assistance offices throughout this Commonwealth to 25 assist and carry out the provisions of this chapter. 26 § 2107. Report to General Assembly. 27 The department shall annually, before October 1, report in 28 writing to the General Assembly concerning the awarding of 29 contracts to small and disadvantaged businesses during the 30 preceding fiscal year. 19970S0005B1890 - 88 -
1 § 2108. Compliance with Federal requirements. 2 If a procurement involves the expenditure of Federal 3 assistance or contract funds, the purchasing agency shall comply 4 with Federal law and authorized regulations which are 5 mandatorily applicable and which are not presently reflected in 6 this part. 7 CHAPTER 23 8 ETHICS IN PUBLIC CONTRACTING 9 Subchapter 10 A. General Policy and Standards 11 B. Specific Standards 12 SUBCHAPTER A 13 GENERAL POLICY AND STANDARDS 14 Sec. 15 2301. Policy. 16 2302. General standards of ethical conduct. 17 2303. Reporting of breaches of ethical standards. 18 § 2301. Policy. 19 Public employment is a public trust. It is the policy of this 20 Commonwealth to promote and balance the objective of protecting 21 government integrity and the objective of facilitating the 22 recruitment and retention of personnel needed by this 23 Commonwealth. Implementation of this policy requires that public 24 employees discharge their duties impartially so as to assure 25 fair competitive access to Commonwealth agency procurement by 26 responsible contractors and that they conduct themselves in a 27 manner that fosters public confidence in the integrity of the 28 Commonwealth procurement process. It is also essential that 29 those doing business with the Commonwealth agencies observe high 30 standards of honesty and integrity. 19970S0005B1890 - 89 -
1 § 2302. General standards of ethical conduct. 2 (a) Employees.--Any attempt to realize personal gain through 3 public employment by conduct inconsistent with the proper 4 discharge of the duties of the employee is a breach of a public 5 trust. In order to fulfill this general prescribed standard, 6 employees must avoid any conflict of interest or improper use of 7 confidential information. 8 (b) Nonemployees.--Any effort to influence any employee to 9 breach the standards of ethical conduct set forth in this 10 section is also a breach of ethical standards. 11 § 2303. Reporting of breaches of ethical standards. 12 When any person has reason to believe that any breach of 13 standards set forth in this chapter has occurred, that person 14 shall report all relevant facts to the State Ethics Commission 15 and to the Attorney General for any appropriate action. 16 SUBCHAPTER B 17 SPECIFIC STANDARDS 18 Sec. 19 2311. Bonds. 20 § 2311. Bonds. 21 It is a breach of ethical standards and unlawful for any 22 employee in issuing an invitation for bids or requests for 23 proposals to require that any bond required by this part be 24 furnished by a particular surety company or through a particular 25 agent or broker. Any employee who violates this section commits 26 a misdemeanor of the first degree. 27 PART II 28 GENERAL PROCUREMENT PROVISIONS 29 Chapter 30 31. General Provisions 19970S0005B1890 - 90 -
1 33. Prevention of Environmental Pollution 2 35. (Reserved) 3 37. Contract Clauses and Preference Provisions 4 39. Construction Contracts Over $50,000 5 41. Purchase of Surplus Federal Property 6 43. Public Facilities Concessions 7 45. Antibid-Rigging 8 CHAPTER 31 9 GENERAL PROVISIONS 10 Sec. 11 3101. Application of part. 12 3102. Definitions. 13 § 3101. Application of part. 14 This part applies to government agencies. In the case of 15 Commonwealth agencies, this part shall be read in pari materia 16 with Part I (relating to Commonwealth Procurement Code). 17 § 3102. Definitions. 18 Subject to additional definitions contained in subsequent 19 provisions of this part which are applicable to specific 20 provisions of this part, the following words and phrases when 21 used in this part shall have the meanings given to them in this 22 section unless the context clearly indicates otherwise: 23 "Commonwealth agency." A Commonwealth agency as defined in 24 section 103 (relating to definitions). 25 "Government agency." Any Commonwealth agency, any 26 transportation authority or agency created by statute or any 27 political subdivision or municipal or other local authority, or 28 agency of any political subdivision or local authority. 29 CHAPTER 33 30 PREVENTION OF ENVIRONMENTAL POLLUTION 19970S0005B1890 - 91 -
1 Sec. 2 3301. Invitations for bids and requests for proposals. 3 3302. Additional work. 4 § 3301. Invitations for bids and requests for proposals. 5 All invitations for bids and requests for proposals for 6 construction projects issued by any government agency shall set 7 forth any provision of Federal and State statutes, rules and 8 regulations dealing with the prevention of environmental 9 pollution and the preservation of public natural resources that 10 affect the projects. 11 § 3302. Additional work. 12 If the successful bidder or offeror must undertake additional 13 work due to the enactment of new or the amendment of existing 14 statutes, rules or regulations occurring after the submission of 15 the successful bid or proposal, the government agency shall 16 issue a change order setting forth the additional work that must 17 be undertaken, which shall not invalidate the contract. The cost 18 of a change order to the government agency shall be determined 19 in accordance with the provisions of the contract for change 20 orders or force accounts, or, if there is not a provision set 21 forth in the contract, then the cost to the government agency 22 shall be the costs to the contractor for wages, labor costs 23 other than wages, wage taxes, materials, equipment rentals, 24 insurance and subcontracts attributable to the additional 25 activity plus a reasonable sum for overhead and profit. 26 Additional costs to undertake work not specified in the 27 invitation for bids or requests for proposals shall not be 28 approved unless written authorization is given the successful 29 bidder or offeror prior to its undertaking the additional 30 activity. 19970S0005B1890 - 92 -
1 CHAPTER 35 2 (RESERVED) 3 CHAPTER 37 4 CONTRACT CLAUSES AND PREFERENCE PROVISIONS 5 Subchapter 6 A. Labor 7 B. Motor Vehicles 8 C. Used Oil Products 9 D. Guaranteed Energy Savings Contracts 10 SUBCHAPTER A 11 LABOR 12 Sec. 13 3701. Contract provisions prohibiting discrimination. 14 § 3701. Contract provisions prohibiting discrimination. 15 Each contract entered into by a government agency for the 16 construction, alteration or repair of any public building or 17 public work shall contain the following provisions by which the 18 contractor agrees that: 19 (1) In the hiring of employees for the performance of 20 work under the contract or any subcontract, no contractor, 21 subcontractor or any person acting on behalf of the 22 contractor or subcontractor shall by reason of gender, race, 23 creed or color discriminate against any citizen of this 24 Commonwealth who is qualified and available to perform the 25 work to which the employment relates. 26 (2) No contractor or subcontractor or any person on 27 their behalf shall in any manner discriminate against or 28 intimidate any employee hired for the performance of work 29 under the contract on account of gender, race, creed or 30 color. 19970S0005B1890 - 93 -
1 (3) The contract may be canceled or terminated by the 2 government agency, and all money due or to become due under 3 the contract may be forfeited for a violation of the terms or 4 conditions of that portion of the contract. 5 SUBCHAPTER B 6 MOTOR VEHICLES 7 Sec. 8 3731. Short title of subchapter and general provisions. 9 3732. Definitions. 10 3733. Police power. 11 3734. Contract provisions. 12 3735. Payment under contract and action to recover 13 unauthorized payments. 14 3736. Penalty. 15 § 3731. Short title of subchapter and general provisions. 16 (a) Short title.--This subchapter shall be known and may be 17 cited as the Motor Vehicle Procurement Act. 18 (b) Legislative findings.--It is hereby determined by the 19 General Assembly to reaffirm the legislative findings contained 20 in the act of April 4, 1984 (P.L.193, No.40), known as the Motor 21 Vehicle Procurement Act, and codified in this chapter: 22 (1) The production of motor vehicles and component parts 23 constitutes a major industry of this Commonwealth. It 24 provides employment for and incomes of hundreds of thousands 25 of the people of this Commonwealth and, in turn, millions of 26 persons in the United States. 27 (2) The taxes paid to the Commonwealth and its political 28 subdivisions by employers and employees engaged in the 29 production and sale of motor vehicles is one of the largest 30 single sources of public revenues in this Commonwealth. 19970S0005B1890 - 94 -
1 (3) It has for many years been the policy of this 2 Commonwealth to aid and support the development and expansion 3 of industry here to foster the economic well-being of this 4 Commonwealth and its people. 5 (4) The economy and general welfare of this Commonwealth 6 and its citizens, as well as the economy, general welfare and 7 national security of the United States, are inseparably 8 related in the preservation and development of the motor 9 vehicle industry in this Commonwealth and in other states of 10 the United States. 11 (5) The production of motor vehicles and motor vehicle 12 components in Canada involves the use of a substantial amount 13 of resources from the United States, including labor and 14 materials. The General Assembly declares it to be the policy 15 of the Commonwealth of Pennsylvania that public officers and 16 agencies should aid and promote the development of the motor 17 vehicle industry of North America to stimulate and improve 18 the economic well-being of this Commonwealth and its 19 citizens. 20 (c) Purpose of subchapter.--This subchapter is intended as 21 remedial legislation designed to promote the general welfare and 22 stimulate the economy of this Commonwealth and its people. Each 23 provision shall receive a liberal construction to effectuate 24 that intention. None of the provisions of this subchapter shall 25 receive a strict or limited construction. 26 § 3732. Definitions. 27 The following words and phrases when used in this subchapter 28 shall have the meanings given to them in this section unless the 29 context clearly indicates otherwise: 30 "Motor vehicle." A vehicle which is self-propelled except 19970S0005B1890 - 95 -
1 one which is propelled solely by human or animal power. The term 2 includes those vehicles designed primarily for use in 3 construction or agriculture or road maintenance such as tractors 4 and earth-moving equipment. THE TERM DOES NOT INCLUDE VEHICLES <-- 5 USED PRIMARILY FOR GRASS CUTTING. 6 "North America." The United States and Canada. The United 7 States includes all territory, continental or insular, subject 8 to the jurisdiction of the United States. 9 "Procure." To acquire by purchase, lease or rent. The term 10 does not include any rentals or leases where the term thereof is 11 less than one month. 12 § 3733. Police power. 13 This subchapter shall be deemed to be an exercise of the 14 police power of this Commonwealth for the protection of the 15 health, safety and general welfare of its citizens. 16 § 3734. Contract provisions. 17 (a) Motor vehicles to be manufactured in North America.--All 18 government agencies shall procure only motor vehicles which are 19 manufactured in North America. A motor vehicle is manufactured 20 in North America if a substantial majority of the principal 21 components are assembled into the final product in an assembly 22 plant in North America. Contract documents for the procurement 23 of motor vehicles shall contain a provision that the vehicles 24 procured by the government agency shall be manufactured in North 25 America. 26 (b) Exception.--This section shall not apply where the head 27 of the government agency states in writing that it is 28 inconsistent with the public interest or that the cost is 29 unreasonable. 30 § 3735. Payment under contract and action to recover 19970S0005B1890 - 96 -
1 unauthorized payments.
2 A government agency shall not authorize, provide for or make
3 a payment to a person under a contract containing the provision
4 required by section 3734 (relating to contract provisions)
5 unless the government agency is satisfied that the person has
6 complied with the provision. The payment made to a person by a
7 government agency which should not have been made shall be
8 recoverable directly from the supplier of the motor vehicle who
9 did not comply with section 3734 by the government agency or the
10 Attorney General by appropriate legal action. Nothing in this
11 section shall authorize any government agency to initiate a
12 legal action independently of the Attorney General unless
13 otherwise authorized under the act of October 15, 1980 (P.L.950,
14 No.164), known as the Commonwealth Attorneys Act.
15 § 3736. Penalty.
16 In addition to the withholding of payments, any person who
17 willfully violates any of the provisions of this subchapter may
18 be prohibited by any government agency from participation in
19 contracts awarded by the government agency for a period of five
20 years from the date of the determination that a violation has
21 occurred.
22 SUBCHAPTER C <--
23 SUBCHAPTER C <--
24 MASS TRANSPORTATION VEHICLES
25 SEC.
26 3741. PROCUREMENT OF MASS TRANSPORTATION VEHICLES.
27 § 3741. PROCUREMENT OF MASS TRANSPORTATION VEHICLES.
28 (A) GENERAL RULE.--NOTWITHSTANDING ANY OTHER PROVISION OF
29 LAW TO THE CONTRARY, WHENEVER A LOCAL, REGIONAL OR METROPOLITAN
30 TRANSPORTATION AUTHORITY DETERMINES IN WRITING THAT IT IS NOT
19970S0005B1890 - 97 -
1 PRACTICABLE OR ADVANTAGEOUS TO THE AUTHORITY TO ENTER INTO A 2 CONTRACT FOR THE PURCHASE OF MASS TRANSPORTATION OR RAILWAY 3 VEHICLES THROUGH COMPETITIVE SEALED BIDDING, THE AUTHORITY MAY 4 UTILIZE THE COMPETITIVE SEALED PROPOSAL METHOD OF PROCUREMENT IN 5 ACCORDANCE WITH SECTION 513 (RELATING TO COMPETITIVE SEALED 6 PROPOSALS). 7 (B) DEFINITION.--AS USED IN THIS SECTION, THE TERM "MASS 8 TRANSPORTATION OR RAILWAY VEHICLES" INCLUDES BUSES, RAILCARS, 9 LOCOMOTIVES, TROLLEY CARS, FERRY BOATS AND OTHER VEHICLES USED 10 TO PROVIDE FOR THE MASS TRANSIT OF PEOPLE, AS WELL AS ANY 11 REPLACEMENT PARTS FOR THE VEHICLES. 12 SUBCHAPTER D 13 USED OIL PRODUCTS 14 Sec. 15 3741. Preference. <-- 16 § 3741. Preference. 17 3746. PREFERENCE. <-- 18 § 3746. PREFERENCE. 19 As provided for in the act of April 9, 1982 (P.L.314, No.89), 20 known as the Pennsylvania Used Oil Recycling Act, government 21 agencies and persons holding contracts with government agencies 22 shall encourage and, to the extent possible, require the 23 procurement and purchase of recycled oil products as 24 substantially equivalent to products made from new oil. 25 SUBCHAPTER D E <-- 26 GUARANTEED ENERGY SAVINGS CONTRACTS 27 Sec. 28 3751. Short title of subchapter. 29 3752. Definitions. 30 3753. Contracting procedures. 19970S0005B1890 - 98 -
1 3754. Contract provisions. 2 3755. Funding. 3 3756. Commonwealth contracts. 4 3757. Construction. 5 § 3751. Short title of subchapter. 6 This subchapter shall be known and may be cited as the 7 Guaranteed Energy Savings Act. 8 § 3752. Definitions. 9 The following words and phrases when used in this subchapter 10 shall have the meanings given to them in this section unless the 11 context clearly indicates otherwise: 12 "Energy conservation measure." A training program or 13 facility alteration designed to reduce energy consumption or 14 operating costs. The term may include, without limitation: 15 (1) Insulation of the building structure or systems 16 within the building. 17 (2) Storm windows or doors, caulking or weather 18 stripping, multiglazed windows or doors, heat-absorbing or 19 heat-reflective glazed and coated window or door systems, 20 additional glazing, reductions in glass area or other window 21 and door system modifications that reduce energy consumption. 22 (3) Automated or computerized energy control systems. 23 (4) Heating, ventilating or air-conditioning system 24 modifications or replacements. 25 (5) Replacement or modification of lighting fixtures to 26 increase the energy efficiency of the lighting system without 27 increasing the overall illumination of a facility, unless an 28 increase in illumination is necessary to conform to 29 applicable State or local building codes for the lighting 30 system after the proposed modifications are made. 19970S0005B1890 - 99 -
1 (6) Energy recovery systems. 2 (7) Systems that produce steam or forms of energy such 3 as heat, as well as electricity, for use within a building or 4 complex of buildings. 5 (8) Energy conservation measures that provide operating 6 cost reductions based on life-cycle cost analysis. 7 "Guaranteed energy savings contract." A contract for the 8 evaluation and recommendation of energy conservation measures 9 and for implementation of one or more such measures. 10 "Governmental unit." Any contracting body as defined in <-- 11 section 2 of the act of December 20, 1967 (P.L.869, No.385), 12 known as the Public Works Contractors' Bond Law of 1967. 13 "GOVERNMENTAL UNIT." ANY OFFICER, EMPLOYEE, AUTHORITY, <-- 14 BOARD, BUREAU, COMMISSION, DEPARTMENT, AGENCY OR INSTITUTION OF 15 A GOVERNMENT AGENCY, INCLUDING, BUT NOT LIMITED TO, ANY 16 COMMONWEALTH AGENCY, STATE-AIDED INSTITUTION OR ANY COUNTY, 17 CITY, DISTRICT, MUNICIPAL CORPORATION, MUNICIPALITY, MUNICIPAL 18 AUTHORITY, POLITICAL SUBDIVISION, SCHOOL DISTRICT, EDUCATIONAL 19 INSTITUTION, BOROUGH, INCORPORATED TOWN, TOWNSHIP, POOR 20 DISTRICT, COUNTY INSTITUTION DISTRICT, OTHER INCORPORATED 21 DISTRICT OR OTHER PUBLIC INSTRUMENTALITY WHICH HAS THE AUTHORITY 22 TO CONTRACT FOR THE CONSTRUCTION, RECONSTRUCTION, ALTERATION OR 23 REPAIR OF ANY PUBLIC BUILDING OR OTHER PUBLIC WORK OR PUBLIC 24 IMPROVEMENT, INCLUDING, BUT NOT LIMITED TO, HIGHWAY WORK. 25 "Qualified provider." A person or business which is 26 responsible and capable of evaluating, recommending, designing, 27 implementing and installing energy conservation measures as 28 determined by the governmental unit. 29 "Request for proposals (RFP)." A type of competitive <-- 30 procurement. 19970S0005B1890 - 100 -
1 § 3753. Contracting procedures. 2 (a) General rule.--Notwithstanding any other contrary or 3 inconsistent provision of law, a governmental unit may enter 4 into a guaranteed energy savings contract with a qualified 5 provider in accordance with the provisions of this subchapter or 6 in accordance with another statutorily authorized competitive <-- 7 PROCUREMENT process. <-- 8 (b) Guaranteed ENERGY SAVINGS contract.--If in accordance <-- 9 with applicable law the award of a contract by a governmental 10 unit requires action at a public meeting, a governmental unit 11 may award a guaranteed energy savings contract at a public 12 meeting if it has provided public notice in the manner 13 prescribed by the act of July 3, 1986 (P.L.388, No.84), known as 14 the Sunshine Act, the notice including the names of the parties 15 to the contract and the purpose of the contract. For 16 governmental units that are not required to take actions on 17 contracts at public meetings, the governmental unit may award a 18 guaranteed energy savings contract in accordance with the 19 protocol for action on contracts PROCEDURES adopted by the <-- 20 governmental unit and the requirements of this subchapter ALL <-- 21 APPLICABLE LAWS. 22 (c) Request for proposals.--Before entering into a <-- 23 guaranteed energy savings contract under this section, a 24 governmental unit shall issue a request for proposals. The 25 (C) COMPETITIVE SEALED PROPOSALS.--FOR THE PURPOSE OF <-- 26 ENTERING INTO A GUARANTEED ENERGY SAVINGS CONTRACT, ALL 27 GOVERNMENTAL UNITS ARE AUTHORIZED TO UTILIZE THE COMPETITIVE 28 SEALED PROPOSAL METHOD OF PROCUREMENT. THE governmental unit 29 shall evaluate any proposal that meets the requirements of the 30 governmental unit and is timely submitted by a qualified 19970S0005B1890 - 101 -
1 provider. The RFP REQUEST FOR PROPOSALS shall be announced <-- 2 through a public notice from the governmental unit which will 3 administer the program. The request for proposal shall include <-- 4 all of the following: 5 (1) The name and address of the governmental unit. 6 (2) The name, address, title and telephone number of a 7 contact person. 8 (3) Notice indicating that the governmental unit is 9 requesting qualified providers to propose energy conservation 10 measures through a guaranteed energy savings contract. 11 (4) The date, time and place where proposals must be 12 received. 13 (5) The information to be included in the proposal. 14 (6) Any other stipulations and clarifications the 15 governmental unit may require. PROVIDE ALL INTERESTED PARTIES <-- 16 WITH SUFFICIENT INFORMATION NECESSARY TO SUBMIT A TIMELY AND 17 RESPONSIVE PROPOSAL. 18 (d) Selection and notice.--The governmental unit shall 19 select the qualified provider that best meets the needs of the 20 governmental unit in accordance with criteria established by the 21 governmental unit. For governmental units that are not required 22 to take actions on contracts at public meetings, the 23 governmental unit shall provide public notice of the award of 24 the guaranteed energy savings contract within 30 days in the 25 Pennsylvania Bulletin. The notice shall include the names of the 26 parties to the contract and the purpose of the contract. For 27 governmental units that are required to take actions on 28 contracts at public meetings, the public notice shall be made at 29 least ten days prior to the meeting. After reviewing the 30 proposals pursuant to subsection (e), a governmental unit may 19970S0005B1890 - 102 -
1 enter into a guaranteed energy savings contract with a qualified
2 provider if it finds that the amount it would spend on the
3 energy conservation measures recommended in the proposal would
4 not exceed the amount to be saved in both energy and operational
5 costs within a ten-year period from the date of installation, if
6 the recommendations in the proposal were followed and the
7 qualified provider provides a written guarantee that the energy
8 or operating cost savings will meet or exceed the cost of the
9 contract.
10 (e) Report.--
11 (1) Before the award of a guaranteed energy savings
12 contract, the qualified provider shall provide a report as
13 part of its proposal which shall be available for public
14 inspection summarizing estimates of all costs of
15 installation, maintenance, repairs and debt service, and
16 estimates of the amounts by which energy or operating costs
17 will be reduced.
18 (2) The report shall contain a listing of contractors
19 and subcontractors to be used by the qualified provider with
20 respect to the energy conservation measures.
21 (f) Bond.--A qualified provider to whom a contract is
22 awarded shall give a sufficient bond to the governmental unit
23 for its faithful performance in accordance with the act of FOR <--
24 ITS FAITHFUL PERFORMANCE. COMMONWEALTH AGENCIES SHALL OBTAIN
25 SUCH BONDS IN ACCORDANCE WITH THE PROVISIONS OF SECTION 533
26 (RELATING TO SECURITY AND PERFORMANCE BONDS). ALL OTHER
27 GOVERNMENTAL UNITS SHALL OBTAIN SUCH BONDS IN ACCORDANCE WITH
28 THE ACT OF December 20, 1967 (P.L.869, No.385), known as the
29 Public Works Contractors' Bond Law of 1967.
30 (g) Award of contract.--Notwithstanding any other provision
19970S0005B1890 - 103 -
1 of law governing the letting of public contracts, a governmental 2 unit may enter into a single guaranteed energy savings contract 3 with each responsible provider selected through the request for <-- 4 proposals process in accordance with the provisions of this 5 subchapter. 6 § 3754. Contract provisions. 7 (a) General rule.--A guaranteed energy savings contract may 8 provide that all payments, except obligations on termination of 9 the contract before its scheduled expiration, shall be made over 10 a period of time. Every guaranteed energy savings contract shall 11 provide that the savings in any year are guaranteed to the 12 extent necessary to make payments under the contract during that 13 year. 14 (b) Written guarantee.--A guaranteed energy savings contract 15 shall include a written guarantee that savings will meet or 16 exceed the cost of the energy conservation measures to be 17 evaluated, recommended, designed, implemented or installed under 18 the contract. 19 (c) Payments.--A guaranteed energy savings contract may 20 provide for payments over a period of time, not to exceed ten 21 years, and for the evaluation, recommendation, design, 22 implementation and installation of energy conservation measures 23 on an installment payment or lease purchase basis. 24 § 3755. Funding. 25 (a) General rule.--Guaranteed energy savings contracts which 26 have terms which extend beyond one fiscal year of the 27 governmental unit must include a provision which allows the 28 governmental unit to terminate the contract if in any fiscal 29 year during the term of the contract the governmental unit does 30 not receive sufficient funds in its annual appropriations to 19970S0005B1890 - 104 -
1 make the payments required under the contract. 2 (b) Funds.--A governmental unit may use funds designated for 3 operating, utilities or capital expenditures for any guaranteed 4 energy savings contract, including, without limitation, for 5 purchases on an installment payment or lease purchase basis. 6 (c) Grants, subsidies or other payments.--Grants, subsidies 7 or other payments from the Commonwealth to a governmental unit 8 shall not be reduced as a result of energy savings obtained as a 9 result of a guaranteed energy savings contract during the life 10 of the contract. 11 § 3756. Commonwealth contracts. 12 In connection with the letting of any guaranteed energy 13 savings contract for a governmental unit under this subchapter, 14 the department shall have the power to waive the process for 15 selection of architects or engineers otherwise prescribed under 16 section 2401.1(19) of the act of April 9, 1929 (P.L.177, <-- 17 No.175), known as The Administrative Code of 1929 905 (RELATING <-- 18 TO PROCUREMENT OF DESIGN PROFESSIONAL SERVICES). In exercising 19 its discretion under this section, the department shall consider 20 the best interests of this Commonwealth and any relevant 21 circumstances peculiar to the proposed contract. 22 § 3757. Construction. 23 This subchapter shall not be construed to abrogate any duty 24 to comply with prevailing wage or residency requirements 25 contained in any other act or part thereof. 26 CHAPTER 39 27 CONSTRUCTION CONTRACTS OVER $50,000 <-- 28 CONTRACTS FOR PUBLIC WORKS <-- 29 Subchapter 30 A. Preliminary Provisions 19970S0005B1890 - 105 -
1 B. General Provisions 2 C. Retainage 3 D. Prompt Payment Schedules 4 E. Substantial/final Payment 5 SUBCHAPTER A 6 PRELIMINARY PROVISIONS 7 Sec. 8 3901. Application and purpose of chapter. 9 3902. Definitions. 10 § 3901. Application and purpose of chapter. 11 (a) Application.--Except as otherwise specifically provided 12 in this chapter, this chapter applies to contracts entered into 13 by a government agency through competitive sealed bidding or 14 competitive sealed proposals. 15 (b) Purpose of chapter.--The purpose of this chapter is to 16 establish a uniform and mandatory system governing public 17 contracts to the extent of the requirements set forth in this 18 chapter and shall be construed to effectuate such purpose. The 19 provisions of this chapter shall in no way affect the provisions 20 of the act of August 15, 1961 (P.L.987, No.442), known as the 21 Pennsylvania Prevailing Wage Act, nor the regulations 22 promulgated under that act, nor shall any requirements of this 23 chapter affect any provisions of a contract to be awarded 24 pursuant to any Federal law or regulations containing specific 25 provisions which are different from the public contract 26 requirements of this chapter. 27 § 3902. Definitions. 28 The following words and phrases when used in this chapter 29 shall have the meanings given to them in this section unless the 30 context clearly indicates otherwise: 19970S0005B1890 - 106 -
1 "Contract." A contract exceeding $50,000 for construction as 2 defined in section 103 (relating to definitions), including 3 heating or plumbing contracts but excluding Department of 4 Transportation contracts under section 301(c)(1) (relating to 5 procurement responsibility). 6 "Contractor." A person who enters into a contract with a 7 government agency. 8 "Deficiency item." Work performed but which the design 9 professional, the contractor or the inspector will not certify 10 as being completed according to the contract. 11 "Design professional." Persons performing professional 12 services as defined in section 901 (relating to definitions). 13 "Government agency." Includes any State-aided institutions. 14 "Inspector." The person authorized or engaged by the 15 government agency to inspect the work performed and materials 16 furnished pursuant to a contract to determine whether the work 17 completed is in compliance with the contract. 18 "Local government unit." Any county, city, borough, 19 incorporated town, township, school district, vocational school 20 district, county institution, local authority or any joint or 21 cooperative body of local government units or any 22 instrumentality, authority or corporation thereof which has 23 authority to enter into a contract. 24 "State-aided institution." Any institution which receives 25 State funds for construction AS DEFINED IN SECTION 103 (RELATING <-- 26 TO DEFINITIONS). 27 "Subcontractor." A person who has contracted to furnish 28 labor or materials to or has performed labor for a contractor or 29 another subcontractor in connection with a contract. 30 "Substantial completion." Construction that is sufficiently 19970S0005B1890 - 107 -
1 completed in accordance with the contract and certified by the
2 architect or engineer of the government agency, as modified by
3 change orders agreed to by the parties, so that the project can
4 be used, occupied or operated for its intended use. In no event
5 shall a project CONTRACT PROJECT be certified as substantially <--
6 complete until at least 90% of the work on the project is
7 completed.
8 SUBCHAPTER B
9 GENERAL PROVISIONS
10 Sec.
11 3911. Time for awarding contract.
12 3912. Time for executing contract.
13 3913. Release of successful bidder.
14 § 3911. Time for awarding contract.
15 (a) General rule.--In the case of a contract to be entered
16 into by a government agency through competitive sealed bidding,
17 the contract shall be awarded to the lowest responsible and
18 responsive bidder within 60 days of the bid opening, or all bids
19 shall be rejected except as otherwise provided in this section.
20 (b) Delay.--If the award is delayed by the required approval
21 of another government agency, the sale of bonds or the award of
22 a grant, the contract shall be awarded to the lowest responsible
23 and responsive bidder within 120 days of the bid opening, or all
24 bids shall be rejected.
25 (c) Extensions.--Extensions of the date for the award may be
26 made by the mutual written consent of the government agency and
27 the lowest responsible and responsive bidder.
28 (d) List of bidders.--All government agencies shall be
29 required to provide a list of the bidders and their bid amount
30 on each contract within ten working days of the bid opening to
19970S0005B1890 - 108 -
1 interested parties for a fee to be determined by the government 2 agency to cover the cost of developing such list. This 3 requirement shall not apply to the contracting bodies of any 4 political subdivision or local authority which has the authority 5 to enter into a contract. 6 § 3912. Time for executing contract. 7 In the case of a contract entered into by a government agency 8 through competitive sealed bidding, the contract shall be 9 executed by the government agency within 60 days of the date 10 that the contract is awarded. 11 § 3913. Release of successful bidder. 12 Failure of the government agency to comply with the 13 requirements of sections 3911 (relating to time for awarding 14 contract) and 3912 (relating to time for executing contract) 15 shall, unless the successful bidder waives the noncompliance by 16 written notice to the government agency, release the successful 17 bidder from any liability in respect to its bid or contract and 18 entitle all bidders to the immediate return of any bonds or 19 security deposits posted in connection with the bid or contract. 20 SUBCHAPTER C 21 RETAINAGE 22 Sec. 23 3921. Retainage. 24 3922. Payment of retainage to subcontractors. 25 § 3921. Retainage. 26 (a) Contract provision.--A contract may include a provision 27 for the retainage of a portion of the amount due the contractor 28 to insure the proper performance of the contract except that the 29 sum withheld by the government agency from the contractor shall 30 not exceed 10% of the amount due the contractor until 50% of the 19970S0005B1890 - 109 -
1 contract is completed. When the contract is 50% completed, one- 2 half of the amount retained by the government agency shall be 3 returned to the contractor. However, the architect or engineer 4 must approve the application for payment. The contractor must be 5 making satisfactory progress, and there must be no specific 6 cause for greater withholding. The sum withheld by the 7 government agency from the contractor after the contract is 50% 8 completed shall not exceed 5% of the value of completed work 9 based on monthly progress payment requests. In the event a 10 dispute arises between the government agency and any prime 11 contractor, which dispute is based upon increased costs claimed 12 by one prime contractor occasioned by delays or other actions of 13 another prime contractor, additional retainage in the sum of one 14 and one-half times the amount of any possible liability may be 15 withheld until such time as a final resolution is agreed to by 16 all parties directly or indirectly involved unless the 17 contractor causing the additional claim furnishes a bond 18 satisfactory to the government agency to indemnify the agency 19 against the claim. All money retained by the government agency 20 may be withheld from the contractor until substantial completion 21 of the contract. 22 (b) Department of General Services.--Notwithstanding 23 subsection (a), when the Department of General Services is the 24 government agency, the contract may include a provision for the 25 retainage of a portion of the amount due the contractor to 26 insure the proper performance of the contract except that the 27 sum withheld by the department for the contractor shall not 28 exceed 6% of the then total estimates until 50% of the contract 29 is satisfactorily completed. The sum withheld by the department 30 from the contractor after the contract is 50% satisfactorily 19970S0005B1890 - 110 -
1 completed shall not exceed 3% of the original contract amount. 2 § 3922. Payment of retainage to subcontractors. 3 In the absence of sufficient reason, within 20 days of the 4 receipt of payment by the contractor, the contractor shall pay 5 all subcontractors with which it has contracted their earned 6 share of the payment the contractor received. 7 SUBCHAPTER D 8 PROMPT PAYMENT SCHEDULES 9 Sec. 10 3931. Performance by contractor or subcontractor. 11 3932. Government agency's progress payment obligations. 12 3933. Contractors' and subcontractors' payment obligations. 13 3934. Withholding of payment for good faith claims. 14 3935. Penalty and attorney fees. 15 3936. Contracts involving Federal aid. 16 3937. Certain provisions unenforceable. 17 3938. Applicability. 18 3939. Claims by innocent parties. 19 § 3931. Performance by contractor or subcontractor. 20 (a) Entitlement of contractor to payment.--Performance by a 21 contractor in accordance with the provisions of a contract shall 22 entitle the contractor to payment by the government agency. 23 (b) Entitlement of subcontractor to payment.--Performance by 24 a subcontractor in accordance with the provisions of a contract 25 shall entitle the subcontractor to payment from the contractor 26 with whom the subcontractor has contracted. 27 § 3932. Government agency's progress payment obligations. 28 (a) Payments in accordance with contract.--The government 29 agency shall pay the contractor or design professional strictly 30 in accordance with the contract. 19970S0005B1890 - 111 -
1 (b) Application for progress payments.--If the contract does 2 not contain a term governing the time for payment, the 3 contractor or design professional shall be entitled to make 4 application for payment from the government agency for progress 5 payments, and the government agency shall make payment less the 6 applicable retainage amount as authorized in section 3921 7 (relating to retainage) to the contractor or design professional 8 within 45 calendar days of the date the application for payment 9 is received. 10 (c) Interest on progress payments not timely made.--Except 11 as otherwise agreed by the parties, if any progress payment less 12 the applicable retainage amount as authorized in section 3921 is 13 not made to a contractor or design professional by the due date 14 established in the contract or in subsection (b), the government 15 agency shall pay to the contractor or design professional, in 16 addition to the amount due, interest on the amount due, and the 17 interest shall be computed at the rate determined by the 18 Secretary of Revenue for interest payments on overdue taxes or 19 the refund of taxes as provided in sections 806 and 806.1 of the 20 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 21 Code. 22 (d) When interest payment not required.--In the event that 23 the contract does not contain a grace period and if a contractor 24 or design professional is not paid by the payment date required 25 by subsection (b), no interest penalty payment required under 26 this section shall be paid if payment is made on or before the 27 15th calendar day after the payment date required under this 28 subchapter. 29 § 3933. Contractors' and subcontractors' payment obligations. 30 (a) Performance by subcontractor entitles subcontractor to 19970S0005B1890 - 112 -
1 payment.--Performance by a subcontractor in accordance with the 2 provisions of the contract shall entitle the subcontractor to 3 payment from the party with whom the subcontractor has 4 contracted. For purposes of this section, the contract between 5 the contractor and subcontractor is presumed to incorporate the 6 terms of the contract between the contractor and the government 7 agency. 8 (b) Disclosure of progress payment due dates.--A contractor 9 or subcontractor shall disclose to a subcontractor, before a 10 subcontract is executed, the due date for receipt of progress 11 payments from the government agency. Notwithstanding any other 12 provisions of this subchapter, if a contractor or a 13 subcontractor fails to accurately disclose the due date to a 14 subcontractor, the contractor or subcontractor shall be 15 obligated to pay the subcontractor as though the due dates 16 established in subsection (c) were met by the government agency. 17 This subsection shall not apply to a change in due dates because 18 of conditions outside of the contractor's control, including, 19 but not limited to, design changes, change orders or delays in 20 construction due to weather conditions. 21 (c) Payment.--When a subcontractor has performed in 22 accordance with the provisions of the contract, a contractor 23 shall pay to the subcontractor, and each subcontractor shall in 24 turn pay to its subcontractors, the full or proportional amount 25 received for each such subcontractor's work and material, based 26 on work completed or services provided under the subcontract, 14 27 days after receipt of a progress payment. Payment shall be made 28 under this section unless it is being withheld under section 29 3934 (relating to withholding of payment for good faith claims). 30 (d) Interest due when progress payment not timely.--If any 19970S0005B1890 - 113 -
1 progress payment is not made to a subcontractor by the due date 2 established in the contract or in subsection (c), the contractor 3 shall pay to the subcontractor, in addition to the amount due, 4 interest as computed in section 3932(c) (relating to government 5 agency's progress payment obligations). 6 (e) When interest payment not required.--In the event that 7 the contract does not contain a grace period and if a 8 subcontractor is not paid by the payment date required by 9 subsection (c), no interest penalty payment required under this 10 section shall be paid if payment is made on or before the 15th 11 calendar day after the payment date required under this 12 subchapter. 13 § 3934. Withholding of payment for good faith claims. 14 (a) When government agency may withhold payment.--The 15 government agency may withhold payment for deficiency items 16 according to terms of the contract. The government agency shall 17 pay the contractor according to the provisions of this 18 subchapter for all other items which appear on the application 19 for payment and have been satisfactorily completed. The 20 contractor may withhold payment from any subcontractor 21 responsible for a deficiency item. The contractor shall pay any 22 subcontractor according to the provisions of this subchapter for 23 any item which appears on the application for payment and has 24 been satisfactorily completed. 25 (b) Notification when payment withheld for deficiency 26 item.--If a government agency withholds payment from a 27 contractor for a deficiency item, it shall notify the contractor 28 of the deficiency item within the time period specified in the 29 contract or 15 calendar days of the date that the application 30 for payment is received. If a contractor withholds payment from 19970S0005B1890 - 114 -
1 a subcontractor for a deficiency item, it must notify the 2 subcontractor or supplier and the government agency of the 3 reason within 15 calendar days of the date after receipt of the 4 notice of the deficiency item from the government agency. 5 § 3935. Penalty and attorney fees. 6 (a) Penalty.--If arbitration or a claim with the Board of 7 Claims or a court of competent jurisdiction is commenced to 8 recover payment due under this subchapter and it is determined 9 that the government agency, contractor or subcontractor has 10 failed to comply with the payment terms of this subchapter, the 11 arbitrator, the Board of Claims or the court may award, in 12 addition to all other damages due, a penalty equal to 1% per 13 month of the amount that was withheld in bad faith. An amount 14 shall be deemed to have been withheld in bad faith to the extent 15 that the withholding was arbitrary or vexatious. An amount shall 16 not be deemed to have been withheld in bad faith to the extent 17 it was withheld pursuant to section 3934 (relating to 18 withholding of payment for good faith claims). 19 (b) Attorney fees.--Notwithstanding any agreement to the 20 contrary, the prevailing party in any proceeding to recover any 21 payment under this subchapter may be awarded a reasonable 22 attorney fee in an amount to be determined by the Board of 23 Claims, court or arbitrator, together with expenses, if it is 24 determined that the government agency, contractor or 25 subcontractor acted in bad faith. An amount shall be deemed to 26 have been withheld in bad faith to the extent that the 27 withholding was arbitrary or vexatious. 28 § 3936. Contracts involving Federal aid. 29 If any provision of this chapter conflicts with a Federal 30 statute or regulation or with conditions attached to the receipt 19970S0005B1890 - 115 -
1 of Federal aid, this chapter shall not operate to prevent 2 receipt of the Federal aid in accordance with any Federal 3 statute or regulation. 4 § 3937. Certain provisions unenforceable. 5 A provision in the contract making it subject to the laws of 6 another state or requiring that any litigation, arbitration or 7 other dispute resolution process on the contract occurs in 8 another state shall be unenforceable. 9 § 3938. Applicability. 10 (a) Not applicable in certain situations.--This subchapter 11 shall not apply in the following situations: 12 (1) Section 3932 (relating to government agency's 13 progress payment obligations) shall not apply when the 14 Commonwealth agency's nonpayment on a particular project is 15 caused by the failure of the General Assembly to enact a 16 budget for the fiscal year of payment. 17 (2) Section 3932 shall not apply when a local government 18 unit's nonpayment on a particular project is caused by 19 failure of the Federal or State Government to pay funds due 20 and payable to the local government unit. 21 (3) Section 3932 shall not apply when government 22 agency's nonpayment on a particular project is caused by the 23 failure of the General Assembly to enact an operating budget 24 for the fiscal year of payment or a capital budget for the 25 capital project or by failure of the Federal, State or local 26 government to pay funds designated or to be designated for 27 the specific project. 28 (4) Nothing in this subchapter shall be construed to 29 require payment of interest penalties by the Federal or State 30 Government if the local government unit is liable for the 19970S0005B1890 - 116 -
1 interest. 2 (b) Not applicable to following entities.--This chapter 3 shall not apply to any of the following: 4 (1) A municipality determined to be distressed under the 5 act of July 10, 1987 (P.L.246, No.47), known as the 6 Municipalities Financial Recovery Act. 7 (2) A school district which has been determined to be a 8 distressed school district under section 691 of the act of 9 March 10, 1949 (P.L.30, No.14), known as the Public School 10 Code of 1949. 11 (3) A city of the first class that has entered into an 12 intergovernmental cooperation agreement under the act of June 13 5, 1991 (P.L.9, No.6), known as the Pennsylvania 14 Intergovernmental Cooperation Authority Act for Cities of the 15 First Class, for so long as any deficit-reducing bonds issued 16 by the authority pursuant to section 301(b)(1) of that act 17 are outstanding and payable. 18 (4) A corporate entity or school district as defined in 19 the Pennsylvania Intergovernmental Cooperation Authority Act 20 for Cities of the First Class. 21 (5) A transportation authority organized or operating 22 under 74 Pa.C.S. Ch. 17 (relating to metropolitan 23 transportation authorities). 24 § 3939. Claims by innocent parties. 25 (a) No obligation to third parties.--The government agency 26 shall have no obligation to any third parties for any claim. 27 (b) Barred claims.--Once a contractor has made payment to 28 the subcontractor according to the provisions of this 29 subchapter, future claims for payment against the contractor or 30 the contractor's surety by parties owed payment from the 19970S0005B1890 - 117 -
1 subcontractor which has been paid shall be barred. 2 SUBCHAPTER E 3 SUBSTANTIAL/FINAL PAYMENT 4 Sec. 5 3941. Substantial/final payment under contract. 6 3942. Arbitration. 7 § 3941. Substantial/final payment under contract. 8 (a) Contract containing provision for retainage.--A contract 9 containing a provision for retainage as provided in section 3921 10 (relating to retainage) shall contain a provision requiring the 11 architect or engineer to make final inspection within 30 days of 12 receipt of the request of the contractor for final inspection 13 and application for final payment. If the work is substantially 14 completed, the architect or engineer shall issue a certificate 15 of completion and a final certificate for payment, and the 16 government agency shall make payment in full within 45 days 17 except as provided in section 3921, less only one and one-half 18 times the amount required to complete any then-remaining 19 uncompleted minor items, which amount shall be certified by the 20 architect or engineer and, upon receipt by the government agency 21 of any guarantee bonds which may be required, in accordance with 22 the contract, to insure proper workmanship for a designated 23 period of time. The certificate given by the architect or 24 engineer shall list in detail each uncompleted item and a 25 reasonable cost of completion. Final payment of any amount 26 withheld for the completion of the minor items shall be paid 27 upon completion of the items in the certificate of the engineer 28 or architect. 29 (b) Interest.--The final payment due the contractor from the 30 government agency after substantial completion of the contract 19970S0005B1890 - 118 -
1 shall bear interest at a rate of 6% per annum for all contracts 2 without provisions for retainage and at a rate of 10% per annum 3 for all contracts with provisions for retainage, the interest to 4 begin after the date that such payment becomes due and payable 5 to the contractor. However, where the government agency has 6 issued bonds to finance the project, interest shall be payable 7 to the contractor at the rate of interest of the bond issue or 8 at the rate of 10% per annum, whichever is less, but in no event 9 shall the interest payable to the contractor be at a rate of 10 interest less than the legal rate of interest. 11 § 3942. Arbitration. 12 If a dispute should arise between the contractor and the 13 government agency over the payment of retainages and final 14 payment, then the dispute shall be arbitrated under the 15 applicable terms of the contract. If the contract contains no 16 provision for arbitration, then both parties may mutually agree 17 to arbitrate the dispute under the rules of the American 18 Arbitration Association or in accordance with 42 Pa.C.S. Ch. 73 19 (relating to arbitration). In any event, either party shall have 20 the right of appeal from any decision and award as provided by 21 law. 22 CHAPTER 41 23 PURCHASE OF SURPLUS FEDERAL PROPERTY 24 Sec. 25 4101. Contracts with United States. 26 4102. Bids and down payments. 27 § 4101. Contracts with United States. 28 Any government agency may enter into a contract with the 29 Federal Government for the purchase, lease or other acquisition, 30 including the warehousing and distribution, of any surplus real 19970S0005B1890 - 119 -
1 or personal Federal property without complying with any 2 requirement of law as to specifications, advertising, award of 3 contract or approval by another government agency. However, an 4 executive or independent agency may only enter into a contract 5 authorized by this section through the Department of General 6 Services. 7 § 4102. Bids and down payments. 8 Any government agency authorized to enter into a contract 9 under section 4101 (relating to contracts with United States) 10 may designate by appropriate order an officeholder or employee 11 of its own to enter a bid in its behalf at any sale of any 12 surplus real or personal Federal property and may authorize the 13 designee to make any down payment or payment in full required in 14 connection with the bidding. 15 CHAPTER 43 16 PUBLIC FACILITIES CONCESSIONS 17 Sec. 18 4301. Short title of chapter and general provisions. 19 4302. Definitions. 20 4303. Terms of contracts. 21 § 4301. Short title of chapter and general provisions. 22 (a) Short title.--This chapter shall be known and may be 23 cited as the Public Facilities Concession Regulation Act. 24 (b) Legislative findings.--It is hereby determined by the 25 General Assembly to reaffirm the legislative findings contained 26 in the act of November 26, 1978 (P.L.1303, No.315), known as the 27 Public Facilities Concession Regulation Act, and codified in 28 this chapter: 29 (1) It is and has been the policy of this Commonwealth 30 to require and encourage public agencies to own and operate a 19970S0005B1890 - 120 -
1 variety of public facilities for the conduct of public 2 business and for the health, education, protection, 3 transportation, recreation, entertainment and cultural 4 advancement of the people of this Commonwealth. 5 (2) It is and has been the policy of this Commonwealth 6 to promote the public welfare by permitting the operation, 7 within these public facilities, of various concessions to 8 provide goods and services to the public. 9 (3) Due to the nature, configuration and location of 10 many public facilities, members of the public utilizing the 11 facilities must either patronize the concessionaires 12 operating therein or undergo great expense, inconvenience and 13 hardship. 14 (4) The general welfare of the people of this 15 Commonwealth requires that concessionaires operating in 16 public facilities offer to the public goods and services of 17 good quality at reasonable prices. The General Assembly 18 therefore declares it to be the policy of this Commonwealth 19 that all public officers and agencies should, at all times, 20 make efforts to see that concessionaires in public facilities 21 provide goods and services of high quality, at reasonable 22 prices, in order to protect the public and encourage use of 23 public facilities. 24 (c) Police power.--This chapter shall be deemed to be an 25 exercise of the police powers of this Commonwealth for the 26 protection of the health, safety and general welfare of the 27 people of this Commonwealth. 28 (d) Purpose of chapter.--This chapter is intended as 29 remedial legislation designed to promote the general welfare, 30 protect the public and encourage full and proper use of public 19970S0005B1890 - 121 -
1 facilities. Each provision of this chapter is intended to 2 receive a liberal construction as will best effectuate those 3 purposes, and no provision is intended to receive a strict or 4 limited construction. 5 (e) Certain rights preserved.--This chapter is not intended 6 to limit or deny any other rights previously enjoyed by any 7 government agency. 8 § 4302. Definitions. 9 The following words and phrases when used in this chapter 10 shall have the meanings given to them in this section unless the 11 context clearly indicates otherwise: 12 "Public facility." Any building, airport, school, park, 13 hospital or other structure, grounds or place owned or operated 14 by a government agency, whether for governmental or proprietary 15 use. 16 § 4303. Terms of contracts. 17 (a) General rule.--Each government agency shall require that 18 every contract granting any concession, license, permit or right 19 to sell, lease, contract for or otherwise make available for 20 consideration goods or services to the public in any public 21 facility contains provisions giving the government agency the 22 right to regulate the kinds, quality and prices of the goods and 23 services, upon terms and conditions as may be appropriate. 24 (b) Exceptions.--This section is not intended to apply in 25 any of the following cases: 26 (1) Where the right to regulate price or quality is 27 vested exclusively in or has been preempted by the United 28 States or any of its agencies or another government agency. 29 (2) Where the head of the government agency determines 30 in writing that the retention of the right to regulate is not 19970S0005B1890 - 122 -
1 necessary to protect the general welfare. 2 CHAPTER 45 3 ANTIBID-RIGGING 4 Sec. 5 4501. Short title of chapter. 6 4502. Definitions. 7 4503. Prohibited activities. 8 4504. Civil action and damages. 9 4505. Suspension or debarment. 10 4506. Liability for increased costs. 11 4507. Noncollusion affidavits. 12 4508. Responsibility for enforcement. 13 4509. Investigation. 14 § 4501. Short title of chapter. 15 This chapter shall be known and may be cited as the Antibid- 16 Rigging Act. 17 § 4502. Definitions. 18 The following words and phrases when used in this chapter 19 shall have the meanings given to them in this section unless the 20 context clearly indicates otherwise: 21 "Bid-rigging." The concerted activity of two or more persons 22 to determine in advance the winning bidder of a contract let or 23 to be let for competitive bidding by a government agency. The 24 term includes, but is not limited to, any one or more of the 25 following: 26 (1) Agreeing to sell items or services at the same 27 price. 28 (2) Agreeing to submit identical bids. 29 (3) Agreeing to rotate bids. 30 (4) Agreeing to share profits with a contractor who does 19970S0005B1890 - 123 -
1 not submit the low bid. 2 (5) Submitting prearranged bids, agreed-upon higher or 3 lower bids or other complementary bids. 4 (6) Agreeing to set up territories to restrict 5 competition. 6 (7) Agreeing not to submit bids. 7 "Government agency." The Commonwealth and any of its 8 departments, boards, agencies, authorities and commissions, any 9 political subdivision, municipal or other local authority or any 10 officer or agency of any political subdivision or local 11 authority. 12 "Person." An individual, corporation or partnership or any 13 other entity capable of submitting a bid to the Commonwealth. 14 § 4503. Prohibited activities. 15 (a) Bid-rigging unlawful.--It is unlawful for any person to 16 conspire, collude or combine with another in order to commit or 17 attempt to commit bid-rigging involving: 18 (1) A contract for the purchase of equipment, goods, 19 services or materials or for construction or repair let or to 20 be let by a government agency. 21 (2) A subcontract for the purchase of equipment, goods, 22 services or materials or for construction or repair with a 23 prime contractor or proposed prime contractor for a 24 government agency. 25 (b) Simultaneous bids.--Notwithstanding other provisions of 26 this chapter, it is not unlawful for the same person to 27 simultaneously submit bids for the same work, or a portion 28 thereof, as a proposed prime contractor and subcontractor. 29 (c) Fines and imprisonment.--Any person who violates this 30 section commits a felony of the third degree and shall, upon 19970S0005B1890 - 124 -
1 conviction, be sentenced to pay a fine of not more than 2 $1,000,000, if an entity other than an individual, or a fine of 3 not more than $50,000, if an individual, or to serve a term of 4 imprisonment for not more than three years, or both. 5 (d) Alternative civil penalty.--In lieu of criminal 6 prosecution for violation of this section, the Attorney General 7 may bring an action for a civil penalty. In this action, a 8 person found by a court to have violated this section shall be 9 liable for a civil penalty of not more than $100,000. 10 (e) Disposition of fines and penalties.--Criminal fines and 11 civil penalties collected under subsections (c) and (d) shall be 12 paid into the State Treasury and deposited in the appropriate 13 fund. 14 (f) Factors to be considered in determining fines, 15 imprisonment or civil penalties.--In determining the appropriate 16 sanctions to be imposed for a violation of this section, the 17 court shall consider at least the following three factors: 18 (1) The prior record and the number of previous 19 violations. 20 (2) The net worth of the person. 21 (3) The size and amount of the contract involved. 22 (g) Civil action not barred.--A conviction or civil penalty 23 imposed under this section shall not bar a government agency 24 from pursuing additional civil action and administrative 25 sanctions. 26 (h) Limitation on prosecution.--No criminal prosecution 27 under this section shall be brought against a person who has 28 been previously charged by information or indictment with a 29 criminal violation of the Federal antitrust laws, based upon the 30 same allegedly unlawful conduct upon which a criminal 19970S0005B1890 - 125 -
1 prosecution under this chapter could be based, where jeopardy 2 has attached under the Federal prosecution. 3 § 4504. Civil action and damages. 4 (a) Government agency to have right of action.--Any 5 government agency entering into a contract which is or has been 6 the subject of activities prohibited by section 4503 (relating 7 to prohibited activities) shall have a right of action against 8 the participants in the prohibited activities to recover 9 damages. 10 (b) Options.--The government agency shall have the option to 11 proceed jointly and severally in a civil action against any one 12 or more of the participants for recovery of the full amount of 13 the damages. There shall be no right to contribution among 14 participants not named defendants by the government agency. 15 (c) Measure of damages.--The measure of damages recoverable 16 under this section shall be the actual damages, which damages 17 shall be trebled plus the cost of suit, including reasonable 18 attorney fees. 19 (d) When cause of action arises.--The cause of action shall 20 arise at the time the government agency which entered into the 21 contract discovered, or should have discovered, the conduct 22 amounting to the unlawful offense. The action shall be brought 23 within four years of the date that the cause of action arose. No 24 civil action shall be maintained after the expiration of ten 25 years from the date the contract was signed by the parties. 26 (e) Conviction to be dispositive of liability.--Any 27 conviction under section 4503 shall be dispositive of the 28 liability of the participants with the only issues for trial 29 being the fact and amount of damages. 30 § 4505. Suspension or debarment. 19970S0005B1890 - 126 -
1 (a) Maximum suspension or debarment.--A government agency 2 proceeding under its rules and regulations to exclude or render 3 ineligible a person from participation in contracts or 4 subcontracts based upon conduct prohibited by section 4503 5 (relating to prohibited activities) shall limit the exclusion or 6 ineligibility to a period not to exceed the following: 7 (1) Three years in the case of a person found for the 8 first time to have engaged in this conduct. 9 (2) Five years in the case of a person found to have 10 engaged in this conduct for a second or subsequent time. 11 (b) Lists of persons excluded.--A government agency that 12 lets a contract by competitive bidding shall maintain a current 13 list of persons excluded or ineligible by reason of suspension 14 or debarment for participation in contracts or subcontracts with 15 that agency and shall furnish a copy of the list upon request to 16 a person considering the submission of a bid as a prime 17 contractor or as a subcontractor. 18 § 4506. Liability for increased costs. 19 A person who enters into a contract with a government agency, 20 either directly as a contractor or indirectly as a 21 subcontractor, during a period of suspension or debarment 22 imposed upon that person by that agency under its rules and 23 regulations shall be liable to the government agency and to an 24 eligible contractor for increased costs incurred as a result of 25 replacing the excluded or ineligible person. 26 § 4507. Noncollusion affidavits. 27 Noncollusion affidavits may be required by rule or regulation 28 of any government agency for all persons. Any requirement for 29 noncollusion affidavits shall be set forth in the invitation to 30 bid. Failure of any person to provide a required affidavit to 19970S0005B1890 - 127 -
1 the government agency may be grounds for disqualification of his 2 bid. Any required noncollusion affidavit shall state whether or 3 not the person has been convicted or found liable for any act 4 prohibited by Federal or State law in any jurisdiction involving 5 conspiracy or collusion with respect to bidding on any public 6 contract within the last three years. The form for any required 7 noncollusion affidavit shall provide that the person's statement 8 on the affidavit that he has been convicted or found liable for 9 any act prohibited by Federal or State law in any jurisdiction 10 involving conspiracy or collusion with respect to bidding on any 11 public contract within the last three years does not prohibit a 12 government agency from accepting a bid from or awarding a 13 contract to that person, but it may be grounds for 14 administrative suspension or debarment in the discretion of the 15 government agency under the rules and regulations of that agency 16 or, in the case of a government agency with no administrative 17 suspension or debarment regulations or procedures, may be 18 grounds for consideration on the question of whether the agency 19 should decline to award a contract to that person on the basis 20 of lack of responsibility. The provisions of this section are in 21 addition to and not in derogation of any other powers and 22 authority of any government agency. 23 § 4508. Responsibility for enforcement. 24 (a) Criminal prosecution.--The Office of Attorney General 25 and the district attorneys of the several counties shall have 26 concurrent jurisdiction for the investigation and prosecution of 27 violations of section 4503 (relating to prohibited activities). 28 (b) Civil action.--The Office of Attorney General shall have 29 the authority to bring civil action under section 4504 (relating 30 to civil action and damages) on behalf of the Commonwealth and 19970S0005B1890 - 128 -
1 any of its departments, boards, agencies, authorities and 2 commissions. Political subdivisions or municipal or other local 3 authorities or any officer or agency of any such political 4 subdivision or local authority shall have the right to bring a 5 civil action under section 4504. Upon the filing of a complaint, 6 a copy shall be served on the Attorney General. The plaintiff, 7 at any time, may request the Attorney General to act on its 8 behalf. The Attorney General, upon determining that it is in the 9 best interest of the Commonwealth, shall have the authority to 10 intervene on behalf of the Commonwealth in these actions. 11 § 4509. Investigation. 12 (a) Required attendance.--Whenever the Office of Attorney 13 General believes that a person may be in possession, custody or 14 control of documentary material or may have information relevant 15 to the subject matter of a civil investigation for the purpose 16 of ascertaining whether a person is or has been engaged in a 17 violation of this chapter, the Attorney General may require the 18 attendance and testimony of witnesses and the production of 19 books, accounts, papers, records, documents and files relating 20 to the civil investigation. For this purpose, the Attorney 21 General or his representatives may sign subpoenas, administer 22 oaths or affirmations, examine witnesses and receive evidence 23 during the investigation. A request for information shall state 24 the subject matter of the investigation, the conduct 25 constituting the alleged violation which is under investigation 26 and the provisions of this chapter applicable to the alleged 27 violation. A request for documentary material shall describe the 28 material to be produced with reasonable particularity so as to 29 fairly identify the documents demanded, provide a return date 30 within which the material is to be produced and identify the 19970S0005B1890 - 129 -
1 member of the Attorney General's staff to whom the material 2 shall be given. In case of disobedience of a subpoena or the 3 contumacy of a witness appearing before the Attorney General or 4 his representative, the Attorney General or his representative 5 may invoke the aid of a court of record of this Commonwealth, 6 and the court may issue an order requiring the person subpoenaed 7 to obey the subpoena or to give evidence or to produce books, 8 accounts, papers, records, documents and files relative to the 9 matter in question. Failure to obey an order of the court may be 10 punished by the court as a contempt. 11 (b) Confidentiality.--No information or documentary material 12 produced under a demand under this section shall, unless 13 otherwise ordered by a court for good cause shown, be produced 14 for inspection or copying by, nor shall the contents be 15 disclosed to, a person other than the Attorney General or his 16 representative without the consent of the person who produced 17 the information or material. However, the Attorney General or 18 his representative shall disclose information or documentary 19 material produced under this section or information derived 20 therefrom to officials of a government agency affected by the 21 alleged violation, for use by that agency in connection with an 22 investigation or proceeding within its jurisdiction and 23 authority, upon the prior certification of an appropriate 24 official of the agency that the information shall be maintained 25 in confidence other than use for official purposes. Under 26 reasonable terms and conditions as the Attorney General or his 27 representative shall prescribe, the documentary material shall 28 be available for inspection and copying by the person who 29 produced the material or a duly authorized representative of 30 that person. The Attorney General or his representative may use 19970S0005B1890 - 130 -
1 the documentary material or information or copies as he
2 determines necessary in the civil enforcement of this chapter,
3 including presentation before any court. Material which contains
4 trade secrets or other highly confidential matter shall not be
5 presented except with the approval of the court in which a
6 proceeding is pending after adequate notice to the person
7 furnishing the material.
8 (c) Limitation on use.--No criminal prosecution under
9 section 4503 (relating to prohibited activities) may be brought
10 by either the Attorney General or a district attorney based
11 solely upon information or documents obtained in a civil
12 investigation under this section.
13 Section 2. Section 2310 of Title 1 is amended to read:
14 § 2310. Sovereign immunity reaffirmed; specific waiver.
15 Pursuant to section 11 of Article 1 of the Constitution of
16 Pennsylvania, it is hereby declared to be the intent of the
17 General Assembly that the Commonwealth, and its officials and
18 employees acting within the scope of their duties, shall
19 continue to enjoy sovereign immunity and official immunity and
20 remain immune from suit except as the General Assembly shall
21 specifically waive the immunity. When the General Assembly
22 specifically waives sovereign immunity, a claim against the
23 Commonwealth and its officials and employees shall be brought
24 only in such manner and in such courts and in such cases as
25 directed by the provisions of Title 42 (relating to judiciary
26 and judicial procedure) or 62 (relating to procurement), unless
27 otherwise specifically authorized by statute.
28 Section 3. Section 763(a) of Title 42 is amended to read:
29 § 763. Direct appeals from government agencies.
30 (a) General rule.--Except as provided in subsection (c), the
19970S0005B1890 - 131 -
1 Commonwealth Court shall have exclusive jurisdiction of appeals
2 from final orders of government agencies in the following cases:
3 (1) All appeals from Commonwealth agencies under
4 Subchapter A of Chapter 7 of Title 2 (relating to judicial
5 review of Commonwealth agency action) or otherwise and
6 including appeals from the Board of Claims, the Environmental
7 Hearing Board, the Pennsylvania Public Utility Commission,
8 the Unemployment Compensation Board of Review and from any
9 other Commonwealth agency having Statewide jurisdiction.
10 (2) All appeals jurisdiction of which is vested in the
11 Commonwealth Court by any statute hereafter enacted.
12 * * *
13 Section 4. Except as otherwise provided, this act is
14 intended to provide a complete and exclusive procedure to govern
15 the procurement by Commonwealth agencies of supplies, services
16 and construction, including the disposal of surplus supplies.
17 Section 5. The terms of office of the present members of the
18 selection committee appointed pursuant to section 2401.1(19) of
19 the act of April 9, 1929 (P.L.177, No.175), known as The
20 Administrative Code of 1929, repealed by this act, shall not be
21 affected by 62 Pa.C.S. § 905(d).
22 Section 6. (a) The following acts and parts of acts are
23 repealed:
24 Act of May 4, 1876 (P.L.99, No.68), entitled "A supplement to
25 an act, entitled 'An act to carry out the provisions of section
26 twelve, article three of the constitution, relative to contracts
27 for supplies for the legislature and various departments of the
28 state government.'"
29 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to
30 carry out the provisions of section twelve, article three, of
19970S0005B1890 - 132 -
1 the constitution, relative to contracts for supplies for the 2 legislature and the various departments of the state 3 government." 4 Act of June 25, 1895 (P.L.269, No.182), entitled "An act 5 providing that none but citizens of the United States shall be 6 employed in any capacity in the erection, enlargement or 7 improvement of any public building or public work within this 8 Commonwealth." 9 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 10 regulating the time for advertising for and receiving proposals 11 for furnishing paper, cardboard, cuts, plates, and other 12 supplies for the use of the Commonwealth for executing the 13 public printing, and the time contracts for furnishing such 14 supplies shall run." 15 Act of May 1, 1919 (P.L.103, No.79), referred to as the State 16 Art Commission Law. 17 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 18 providing for and regulating the public printing and binding, 19 the editing for publication and the distribution of all 20 documents, reports, bulletins, and other publications for the 21 use of the Commonwealth, the several departments, boards, 22 commissions, and other agencies engaged in the legislative, 23 judicial, and administrative work of the State Government; the 24 sale of waste paper; the appointment of a director and other 25 employes; and repealing inconsistent and conflicting 26 legislation." 27 Sections 478, 2401.1(19), 2403(a), (b), (c) and (g), 2405, 28 2406(g), 2408, 2409, 2409.1, 2410, 2412, 2413 and 2414 of the 29 act of April 9, 1929 (P.L.177, No.175), known as The 30 Administrative Code of 1929. 19970S0005B1890 - 133 -
1 Section 1809 of the act of June 24, 1931 (P.L.1206, No.331), 2 known as The First Class Township Code. 3 Act of January 2, 1934 (Sp.Sess., 1933 P.L.200, No.41), 4 entitled "An act authorizing officers, departments, boards and 5 commissions of any political subdivision of the Commonwealth, 6 and cities, counties, boroughs, incorporated towns, townships, 7 school districts, to make adjustments with certain supply 8 contractors to reimburse losses sustained in performance of 9 contracts under certain circumstances." 10 Act of July 18, 1935 (P.L.1173, No.382), entitled "An act to 11 prohibit discrimination on account of race, creed or color in 12 employment under contracts for public buildings or public 13 works." 14 Act of July 19, 1935 (P.L.1321, No.414), entitled "An act 15 requiring specifications for the construction, alteration, or 16 repair of public works of the Commonwealth, county, 17 municipality, or other subdivisions of the Commonwealth, to 18 contain a provision that the laborers or mechanics employed 19 thereon shall have been residents of this Commonwealth for at 20 least ninety days prior to their employment; and prescribing 21 penalties." 22 Act of April 12, 1945 (P.L.220, No.99), entitled "An act 23 authorizing the Commonwealth and any administrative department, 24 boards, and commissions thereof acting through the Department of 25 Property and Supplies, and political subdivisions of the 26 Commonwealth, including municipal authorities, to enter into 27 contracts with the United States of America, or any agency 28 thereof, for the purchase, lease, or other acquisition of 29 property, real or personal, offered for sale pursuant to the 30 Surplus Property Act of one thousand nine hundred forty-four, 19970S0005B1890 - 134 -
1 without complying with any requirement of existing law as to 2 specifications, advertising, award of contract, and approval of 3 purchases by a State agency receiving competitive bids, or the 4 delivery of property purchased before payment therefor." 5 Sections 404, 405 and 405.1 of the act of June 1, 1945 6 (P.L.1242, No.428), known as the State Highway Law. 7 Act of June 10, 1947 (P.L.493, No.223), entitled "An act 8 further prescribing the bonds required of foreign corporations 9 contracting for public buildings, public works or projects." 10 Sections 754 and 755 of the act of March 10, 1949 (P.L.30, 11 No.14), known as the Public School Code of 1949. 12 Section 11 of the act of March 31, 1949 (P.L.372, No.34), 13 known as The General State Authority Act of one thousand nine 14 hundred forty-nine. 15 Section 1408 of the act of February 1, 1966 (1965 P.L.1656, 16 No.581), known as The Borough Code. 17 Act of October 26, 1972 (P.L.1017, No.247), entitled "An act 18 relating to the prevention of environment pollution and the 19 preservation of public natural resources in construction 20 projects." 21 Act of November 26, 1978 (P.L.1303, No.315), known as the 22 Public Facilities Concession Regulation Act. 23 Act of November 26, 1978 (P.L.1309, No.317), entitled "An act 24 regulating the awarding and execution of certain public 25 contracts; providing for contract provisions relating to the 26 retention, interest, and payment of funds payable under the 27 contracts; and repealing inconsistent acts." 28 Act of October 28, 1983 (P.L.176, No.45), known as the 29 Antibid-Rigging Act. 30 Act of April 4, 1984 (P.L.193, No.40), known as the Motor 19970S0005B1890 - 135 -
1 Vehicle Procurement Act. 2 Act of November 28, 1986 (P.L.1465, No.146), known as the 3 Reciprocal Limitations Act. 4 (b) The following acts and parts of acts are repealed 5 insofar as they relate to Commonwealth agencies as defined in 62 6 Pa.C.S. § 103: 7 Act of December 20, 1967 (P.L.869, No.385), known as the 8 Public Works Contractors' Bond Law of 1967. 9 Act of January 23, 1974 (P.L.9, No.4), entitled "An act 10 prescribing the procedure, after the opening of bids, for the 11 withdrawal of bids on certain public contracts, setting forth 12 the rights of the parties involved and providing penalties," 13 except insofar as the act applies to the leases of real 14 property. 15 Act of May 10, 1996 (P.L.153 No.29), known as the Guaranteed 16 Energy Savings Act. 17 (c) The following acts and parts of acts are repealed 18 insofar as they are inconsistent with this act: 19 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to 20 carry out the provisions of section twelve, article three, of 21 the constitution, relative to contracts for supplies for the 22 legislature and the various departments of the state 23 government." 24 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 25 regulating the time for advertising for and receiving proposals 26 for furnishing paper, cardboard, cuts, plates, and other 27 supplies for the use of the Commonwealth for executing the 28 public printing, and the time contracts for furnishing such 29 supplies shall run." 30 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 19970S0005B1890 - 136 -
1 providing for and regulating the public printing and binding, 2 the editing for publication and the distribution of all 3 documents, reports, bulletins, and other publications for the 4 use of the Commonwealth, the several departments, boards, 5 commissions, and other agencies engaged in the legislative, 6 judicial, and administrative work of the State Government; the 7 sale of waste paper; the appointment of a director and other 8 employes; and repealing inconsistent and conflicting 9 legislation." 10 Sections 507, 508, 510 and 511 of the act of April 9, 1929 11 (P.L.177, No.175), known as The Administrative Code of 1929. 12 Act of June 23, 1931 (P.L.1181, No.321), entitled "An act 13 authorizing persons, co-partnerships, associations, and 14 corporations, who, whether as sub-contractor or otherwise, have 15 furnished material or supplied or performed labor in connection 16 with any public work or improvement, to intervene in or 17 institute actions on certain bonds given to the Commonwealth or 18 to municipal corporations in connection with the performance of 19 public contracts; fixing the time within which such actions must 20 be brought, and the amounts recoverable therein; and providing 21 for distribution of amounts recovered; and prescribing 22 procedure." 23 Section 6 of the act of May 20, 1937 (P.L.728, No.193), 24 referred to as the Board of Claims Act only insofar as it is 25 inconsistent with the procedure provided for in 62 Pa.C.S. § 26 1712 regarding the resolution of a contract controversy by the 27 head of a purchasing agency. 28 Section 10 of the act of July 5, 1947 (P.L.1217, No.498), 29 known as the State Public School Building Authority Act. 30 Section 12 of the act of December 6, 1967 (P.L.678, No.318), 19970S0005B1890 - 137 -
1 known as The Pennsylvania Higher Educational Facilities 2 Authority Act of 1967. 3 Section 4 of the act of November 20, 1968 (P.L.1075, No.329), 4 entitled "An act providing for the growth and development of 5 noncommercial educational television; creating the Pennsylvania 6 Public Television Network Commission as an independent 7 commission and defining its powers and duties." 8 (d) Nothing in this act shall repeal, modify or supplant the 9 following acts and parts of acts: 10 Except as explicitly stated in the addition of 62 Pa.C.S. § 11 322(6), section 1 of the act of May 1, 1913 (P.L.155, No.104), 12 entitled "An act regulating the letting of certain contracts for 13 the erection, construction, and alteration of public buildings." 14 Section 516 of the act of April 9, 1929 (P.L.177, No.175), 15 known as The Administrative Code of 1929. 16 Section 303 of the act of April 9, 1929 (P.L.343, No.176), 17 known as The Fiscal Code. 18 Act of July 19, 1957 (P.L.1017, No.451), known as the State 19 Adverse Interest Act. 20 Act of February 11, 1976 (P.L.14, No.10), known as the 21 Pennsylvania Rural and Intercity Common Carrier Surface 22 Transportation Assistance Act. 23 Act of April 3, 1992 (P.L.28, No.11), known as the Tuition 24 Account Program and College Savings Bond Act. 25 (e) All other acts and parts of acts are repealed insofar as 26 they are inconsistent with this act. 27 Section 7. This act shall apply to contracts solicited or 28 entered into on or after the effective date of this act unless 29 the parties agree to its application to a contract solicited or 30 entered into prior to the effective date of this act. 19970S0005B1890 - 138 -
1 Section 8. This act shall take effect in 180 days. L11L62JLW/19970S0005B1890 - 139 -