PRINTER'S NO. 228
No. 5 Session of 1997
INTRODUCED BY THOMPSON, LOEPER, GERLACH, TOMLINSON, SALVATORE, MUSTO, O'PAKE, ARMSTRONG, ROBBINS, WENGER, HART, RHOADES, MOWERY, WOZNIAK, HECKLER, MURPHY, MADIGAN, DELP, EARLL AND CORMAN, JANUARY 29, 1997
REFERRED TO STATE GOVERNMENT, JANUARY 29, 1997
AN ACT 1 Amending Titles 62 (Procurement), 1 (General Provisions) and 42 2 (Judiciary and Judicial Procedure) of the Pennsylvania 3 Consolidated Statutes, adding provisions relating to 4 procurement; and making repeals. 5 TABLE OF CONTENTS 6 TITLE 62 7 PROCUREMENT 8 PART I. COMMONWEALTH PROCUREMENT CODE 9 Chapter 1. General Provisions 10 § 101. Short title of part. 11 § 102. Application of part. 12 § 103. Definitions. 13 § 104. General principles of law otherwise applicable. 14 § 105. Determinations. 15 § 106. Public access to procurement information. 16 § 107. Reciprocal limitations. 17 § 108. Recycled materials. 18 Chapter 3. Procurement Organization
1 Subchapter A. Organization of Public Procurement 2 § 301. Procurement responsibility. 3 Subchapter B. Procurement Policy 4 § 311. Powers and duties. 5 § 312. Procurement regulations. 6 Subchapter C. Powers and Duties of Department 7 § 321. Powers and duties. 8 § 322. Specific construction powers, duties and procedures. 9 Subchapter D. Powers and Duties of the Board 10 of Commissioners of Public Grounds and 11 Buildings and the Office of the Budget 12 § 326. Board of Commissioners of Public Grounds and Buildings. 13 § 327. Office of the Budget. 14 Subchapter E. Coordination, Training and Education 15 § 331. Collection of data concerning public procurement. 16 § 332. Advisory groups. 17 Chapter 5. Source Selection and Contract Formation 18 Subchapter A. Definitions 19 § 501. Definitions. 20 Subchapter B. Methods of Source Selection 21 § 511. Methods of source selection. 22 § 512. Competitive sealed bidding. 23 § 513. Competitive sealed proposals. 24 § 514. Small purchases. 25 § 515. Sole source procurement. 26 § 516. Emergency procurement. 27 § 517. Multiple awards. 28 § 518. Competitive selection procedures for certain services. 29 § 519. Selection procedure for insurance and bonds. 30 § 520. Supplies and services furnished by persons with 19970S0005B0228 - 2 -
1 disabilities. 2 Subchapter C. Cancellation of Invitations for Bids or 3 Requests for Proposals 4 § 521. Cancellation of invitations for bids or requests for 5 proposals. 6 Subchapter D. Qualifications and Duties 7 § 531. Debarment or suspension. 8 § 532. Prequalification of bidders and offerors. 9 § 533. Responsibility of bidders and offerors. 10 § 534. Security and performance bonds. 11 § 535. Cost or pricing data. 12 Subchapter E. Types of Contracts 13 § 541. Approval of accounting system. 14 § 542. Multiterm contracts. 15 § 543. Effective contracts. 16 Subchapter F. Inspection of Plant and Audit of Records 17 § 551. Right to inspect plant. 18 § 552. Right to audit records. 19 Subchapter G. Determinations and Reports 20 § 561. Finality of determinations. 21 § 562. Anticompetitive practices. 22 § 563. Retention of procurement records. 23 § 564. Record of certain actions. 24 Chapter 7. (Reserved) 25 Chapter 9. Procurement of Construction, Architect and Engineer 26 Services 27 § 901. Definitions. 28 § 902. Bid or proposal security. 29 § 903. Contract performance and payment bonds. 30 § 904. Copies of bonds. 19970S0005B0228 - 3 -
1 § 905. Procurement of design professional services. 2 Chapter 11. (Reserved) 3 Chapter 13. (Reserved) 4 Chapter 15. Supply Management 5 § 1501. Definitions. 6 § 1502. Supply management regulations. 7 § 1503. Proceeds from sale or disposal of surplus supplies. 8 Chapter 17. Legal and Contractual Remedies 9 Subchapter A. General Provisions 10 § 1701. Definitions. 11 § 1702. Sovereign immunity. 12 Subchapter B. Prelitigation Resolution of Controversies 13 § 1711. Authority to resolve protests of solicitations or 14 awards. 15 § 1712. Authority to resolve contract and breach of contract 16 controversies. 17 Subchapter C. Board of Claims 18 § 1721. Function of Board of Claims. 19 § 1722. (Reserved). 20 § 1723. (Reserved). 21 § 1724. (Reserved). 22 § 1725. Hearings, decisions and awards. 23 § 1726. Appeals. 24 Subchapter D. Solicitations or Awards in Violation of Law 25 § 1741. Applicability. 26 § 1742. Remedies prior to award. 27 § 1743. Remedies after award. 28 Subchapter E. Interest 29 § 1751. Interest. 30 Chapter 19. Intergovernmental Relations 19970S0005B0228 - 4 -
1 § 1901. Definitions. 2 § 1902. Cooperative purchasing authorized. 3 § 1903. Sale, acquisition or use of supplies by a public 4 procurement unit. 5 § 1904. Cooperative use of supplies or services. 6 § 1905. Joint use of facilities. 7 § 1906. Supply of personnel, information and technical 8 services. 9 § 1907. Use of payments received by a supplying public 10 procurement unit. 11 § 1908. Compliance of public procurement units. 12 § 1909. Review of procurement requirements. 13 § 1910. Contract controversies. 14 Chapter 21. Small and Disadvantaged Businesses 15 § 2101. Policy. 16 § 2102. Definitions. 17 § 2103. Regulations. 18 § 2104. Duties of department. 19 § 2105. Bonding and progress payments. 20 § 2106. Business assistance offices. 21 § 2107. Report to General Assembly. 22 § 2108. Compliance with Federal requirements. 23 Chapter 23. Ethics in Public Contracting 24 Subchapter A. General Policy and Standards 25 § 2301. Policy. 26 § 2302. General standards of ethical conduct. 27 § 2303. Reporting of breaches of ethical standards. 28 Subchapter B. Specific Standards 29 § 2311. Bonds. 30 PART II. GENERAL PROCUREMENT PROVISIONS 19970S0005B0228 - 5 -
1 Chapter 31. General Provisions 2 § 3101. Application of part. 3 § 3102. Definitions. 4 Chapter 33. Prevention of Environmental Pollution 5 § 3301. Invitations for bids and requests for proposals. 6 § 3302. Additional work. 7 Chapter 35. (Reserved) 8 Chapter 37. Contract Clauses and Preference Provisions 9 Subchapter A. Labor 10 § 3701. Contract provisions prohibiting discrimination. 11 § 3702. Contract provision requiring residents to be employed. 12 Subchapter B. Steel Products 13 § 3711. Short title of subchapter and general provisions. 14 § 3712. Definitions. 15 § 3713. Requirement of contract provision. 16 § 3714. Payments under contracts. 17 Subchapter C. Trade Practices 18 § 3721. Short title of subchapter and general provisions. 19 § 3722. Definitions. 20 § 3723. Unlawful acts. 21 § 3724. Preference for aluminum and steel products made in 22 United States. 23 § 3725. Requirement to list discriminating countries. 24 § 3726. Procedure to determine discrimination. 25 § 3727. Foreign registry docket. 26 § 3728. Aluminum or steel products from a country listed on 27 foreign registry docket. 28 Subchapter D. Motor Vehicles 29 § 3731. Short title of subchapter and general provisions. 30 § 3732. Definitions. 19970S0005B0228 - 6 -
1 § 3733. Police power. 2 § 3734. Contract provisions. 3 § 3735. Payment under contract and action to recover 4 unauthorized payments. 5 § 3736. Penalty. 6 Subchapter E. Used Oil Products 7 § 3741. Preference. 8 Subchapter F. Guaranteed Energy Savings Contracts 9 § 3751. Definitions. 10 § 3752. Selection process. 11 § 3753. Award of single contract. 12 Chapter 39. Construction Contracts Over $50,000 13 Subchapter A. Preliminary Provisions 14 § 3901. Application and purpose of chapter. 15 § 3902. Definitions. 16 Subchapter B. General Provisions 17 § 3911. Time for awarding contract. 18 § 3912. Time for executing contract. 19 § 3913. Release of successful bidder. 20 Subchapter C. Retainage. 21 § 3921. Retainage. 22 § 3922. Payment of retainage to subcontractors. 23 Subchapter D. Prompt Payment Schedules 24 § 3931. Performance by contractor or subcontractor. 25 § 3932. Government agency's progress payment obligations. 26 § 3933. Contractors' and subcontractors' payment obligations. 27 § 3934. Withholding of payment for good faith claims. 28 § 3935. Penalty and attorney fees. 29 § 3936. Contracts involving Federal aid. 30 § 3937. Certain provisions unenforceable. 19970S0005B0228 - 7 -
1 § 3938. Applicability. 2 § 3939. Claims by innocent parties. 3 Subchapter E. Final Payment 4 § 3941. Final payment under contract. 5 § 3942. Arbitration. 6 Chapter 41. Purchase of Surplus Federal Property 7 § 4101. Contracts with United States. 8 § 4102. Bids and down payments. 9 Chapter 43. Public Facilities Concessions 10 § 4301. Short title of chapter and general provisions. 11 § 4302. Definitions. 12 § 4303. Terms of contracts. 13 Chapter 45. Antibid-Rigging 14 § 4501. Short title of chapter. 15 § 4502. Definitions. 16 § 4503. Prohibited activities. 17 § 4504. Civil action and damages. 18 § 4505. Suspension or debarment. 19 § 4506. Liability for increased costs. 20 § 4507. Noncollusion affidavits. 21 § 4508. Responsibility for enforcement. 22 § 4509. Investigation. 23 TITLE 62 24 PROCUREMENT 25 Part 26 I. Commonwealth Procurement Code 27 II. General Procurement Provisions 28 PART I 29 COMMONWEALTH PROCUREMENT CODE 30 Chapter 19970S0005B0228 - 8 -
1 1. General Provisions 2 3. Procurement Organization 3 5. Source Selection and Contract Formation 4 7. (Reserved) 5 9. Procurement of Construction, Architect and Engineer 6 Services 7 11. (Reserved) 8 13. (Reserved) 9 15. Supply Management 10 17. Legal and Contractual Remedies 11 19. Intergovernmental Relations 12 21. Small and Disadvantaged Businesses 13 23. Ethics in Public Contracting 14 The General Assembly of the Commonwealth of Pennsylvania 15 hereby enacts as follows: 16 Section 1. Title 62 of the Pennsylvania Consolidated 17 Statutes is amended by adding parts to read: 18 CHAPTER 1 19 GENERAL PROVISIONS 20 Sec. 21 101. Short title of part. 22 102. Application of part. 23 103. Definitions. 24 104. General principles of law otherwise applicable. 25 105. Determinations. 26 106. Public access to procurement information. 27 107. Reciprocal limitations. 28 108. Recycled materials. 29 § 101. Short title of part. 30 This part shall be known and may be cited as the Commonwealth 19970S0005B0228 - 9 -
1 Procurement Code. 2 § 102. Application of part. 3 (a) Application to Commonwealth procurement.--This part 4 applies to every expenditure of funds other than the investment 5 of funds by Commonwealth agencies under any contract, 6 irrespective of their source, including Federal assistance 7 moneys except as specified in section 2108 (relating to 8 compliance with Federal requirements). This part does not apply 9 to grants or contracts between Commonwealth agencies or between 10 the Commonwealth and its political subdivisions or other 11 governments except as provided in Chapter 19 (relating to 12 intergovernmental relations). Nothing in this part or in 13 accompanying regulations shall prevent any Commonwealth agency 14 or political subdivision from complying with the terms and 15 conditions of any grant, gift, bequest or cooperative agreement. 16 (b) Application to disposal of Commonwealth supplies.--This 17 part applies to the disposal of supplies of Commonwealth 18 agencies. 19 (c) Application to local agencies.--Any political 20 subdivision or other local public agency may specifically or by 21 reference adopt all or any part of this part and its 22 accompanying regulations. 23 (d) Application to General Assembly and unified judicial 24 system.--The General Assembly and its agencies and the unified 25 judicial system and its agencies may use the department as its 26 purchasing agency for the purchase of supplies under this part 27 and may use the department to dispose of surplus supplies under 28 Chapter 15 (relating to supply management). 29 § 103. Definitions. 30 Subject to additional definitions contained in subsequent 19970S0005B0228 - 10 -
1 provisions of this part which are applicable to specific 2 provisions of this part, the following words and phrases when 3 used in this part shall have the meanings given to them in this 4 section unless the context clearly indicates otherwise: 5 "Change order." A written order signed by the contracting 6 officer directing the contractor to make changes which the 7 changes clause of the contract authorizes the contracting 8 officer to order. The change order may be either with the 9 consent of the contractor or a unilateral order by the 10 contracting officer. 11 "Commonwealth agency." An executive or independent agency. 12 "Construction." The process of building, altering, 13 repairing, improving or demolishing any public structure or 14 building or other public improvements of any kind to any public 15 real property. The term does not include the routine operation, 16 repair or maintenance of existing structures, buildings or real 17 property. 18 "Contract." A type of written agreement, regardless of what 19 it may be called, for the procurement or disposal of supplies, 20 services or construction. 21 "Contract modification." A written alteration in 22 specifications, delivery point, rate of delivery, period of 23 performance, price, quantity or other provisions of any contract 24 accomplished by mutual action of the parties to the contract. 25 "Contracting officer." A person authorized to enter into and 26 administer contracts and make written determinations with 27 respect to contracts. 28 "Department." The Department of General Services of the 29 Commonwealth. 30 "Employee." An individual drawing a salary from a 19970S0005B0228 - 11 -
1 Commonwealth agency, whether elected or not, and any 2 noncompensated individual performing personal services for any 3 Commonwealth agency. 4 "Executive agency." The Governor and the departments, 5 boards, commissions, authorities and other officers and agencies 6 of the Commonwealth. The term does not include any court or 7 other officer or agency of the unified judicial system, the 8 General Assembly and its officers and agencies or any 9 independent agency. 10 "Grant." The furnishing of assistance by the Federal 11 Government, Commonwealth or any person, whether financial or 12 otherwise, to any person to support a program authorized by law. 13 The term does not include an award whose primary purpose is to 14 procure an end product, whether in the form of supplies, 15 services or construction. A contract resulting from such an 16 award is not a grant but a procurement contract. 17 "Independent agency." Boards, commissions, authorities and 18 other agencies and officers of the Commonwealth which are not 19 subject to the policy supervision and control of the Governor. 20 The term does not include any court or other officer or agency 21 of the unified judicial system or the General Assembly and its 22 officers and agencies. 23 "Policy statement." Any document, except an adjudication or 24 a regulation, promulgated by a Commonwealth agency which sets 25 forth substantive or procedural personal or property rights, 26 privileges, immunities, duties, liabilities or obligations of 27 the public or any person, including any document interpreting or 28 implementing any statute enforced or administered by the agency. 29 "Procurement." Buying, purchasing, renting, leasing or 30 otherwise acquiring any supplies, services or construction. The 19970S0005B0228 - 12 -
1 term also includes all functions that pertain to the obtaining 2 of any supply, service or construction, including description of 3 requirements, selection and solicitation of sources, preparation 4 and award of contract and all phases of contract administration. 5 "Purchasing agency." A Commonwealth agency authorized by 6 this part to enter into contracts. 7 "Regulation." A regulation as defined in 45 Pa.C.S. § 501 8 (relating to definitions). 9 "Services." The furnishing of labor, time or effort by a 10 contractor not involving the delivery of a specific end product 11 other than reports which are merely incidental to the required 12 performance. The term does not include employment agreements, 13 collective bargaining agreements or agreements with litigation 14 consultants. 15 "Specification." A description of the physical or functional 16 characteristics or the nature of a supply, service or 17 construction item, including a description of any requirement 18 for inspecting, testing or preparing a supply, service or 19 construction item for delivery. 20 "Supplies." Any property, including, but not limited to, 21 equipment, materials, printing, insurance and leases of and 22 installment purchases of personal property. The term does not 23 include real property or leases of real property. 24 "Using agency." A Commonwealth agency which utilizes any 25 supplies, services or construction procured under this part. 26 § 104. General principles of law otherwise applicable. 27 Unless displaced by the particular provisions of this part, 28 existing Pennsylvania law, including Title 13 (relating to 29 commercial code), shall supplement the provisions of this part. 30 § 105. Determinations. 19970S0005B0228 - 13 -
1 Written determinations required by this part shall be 2 retained in the appropriate official contract file. 3 § 106. Public access to procurement information. 4 Procurement information shall be a public record to the 5 extent provided in the act of June 21, 1957 (P.L.390, No.212), 6 referred to as the Right-to-Know Law, and shall be available to 7 the public as provided in that act. 8 § 107. Reciprocal limitations. 9 (a) Short title of section.--This section shall be known and 10 may be cited as the Reciprocal Limitations Act. 11 (b) Legislative findings.--It is hereby determined by the 12 General Assembly to reaffirm the legislative findings contained 13 in the act of November 28, 1986 (P.L.1465, No.146), known as the 14 Reciprocal Limitations Act, and codified in this section: 15 (1) The award of contracts to the lowest responsible 16 bidder generally provides for the most economical procurement 17 of supplies and construction. 18 (2) In some cases, award to the lowest responsible 19 bidder may not be the most economical and practicable when 20 the best interests of the Commonwealth are concerned. 21 (3) Some states apply a preference favoring in-state 22 supplies or bidders or they apply a prohibition against the 23 use of out-of-State supplies or bidders. 24 (4) The application of this preference or prohibition by 25 other states diminishes or eliminates opportunities for 26 bidders and manufacturers who reside in this Commonwealth to 27 obtain construction contracts from or to sell supplies to 28 states that have this preference, thereby resulting in the 29 loss of business for resident bidders and manufacturers. 30 Therefore, in order to offset or counteract the 19970S0005B0228 - 14 -
1 discriminatory practices of other states, discourage other 2 states from applying a preference and ultimately to aid 3 employment, help business and industry located in this 4 Commonwealth, attract new business and industry to this 5 Commonwealth and provide additional tax revenue both from 6 those receiving contracts and those employed by contractors, 7 the General Assembly hereby declares that it is the policy of 8 this Commonwealth to respond in like manner against those 9 states that apply preferences or prohibitions by giving a 10 similar offsetting preference to residents in this 11 Commonwealth and bidders offering supplies manufactured in 12 this Commonwealth and by prohibiting the purchase or use of 13 certain supplies, in accordance with the provisions of this 14 section. 15 (c) Preference for supplies.--In all procurements of 16 supplies exceeding the amount established by the department for 17 small purchases under section 514 (relating to small purchases), 18 all purchasing agencies shall give preference to those bidders 19 or offerors offering supplies produced, manufactured, mined, 20 grown or performed in this Commonwealth as against those bidders 21 or offerors offering supplies produced, manufactured, mined, 22 grown or performed in any state that gives or requires a 23 preference to supplies produced, manufactured, mined, grown or 24 performed in that state. The amount of the preference shall be 25 equal to the amount of the preference applied by the other state 26 for that particular supply. 27 (d) Preference for resident bidders or offerors.--When a 28 public contract exceeding the amount established by the 29 department for small purchases under section 514 is to be 30 awarded, a resident bidder or offeror shall be granted a 19970S0005B0228 - 15 -
1 preference as against a nonresident bidder or offeror from any 2 state that gives or requires a preference to bidders or offerors 3 from that state. The amount of the preference shall be equal to 4 the amount of the preference applied by the state of the 5 nonresident bidder or offeror. 6 (e) Prohibition.--In the construction of any public building 7 or other public work at the expense of the Commonwealth or any 8 authority or instrumentality thereof, the following prohibition 9 shall be recognized and applied. No purchasing agency shall 10 specify for, use or procure any supplies which are produced, 11 manufactured, mined, grown or performed in any state that 12 prohibits the specification for, use or procurement of these 13 supplies in or on its public buildings or other works when these 14 supplies are not produced, manufactured, mined, grown or 15 performed in that state. 16 (f) Listing discriminating states.--The department shall 17 prepare a list of the states which apply a preference favoring 18 in-State supplies or bidders or offerors or a prohibition 19 against the use of out-of-State supplies or bidders or offerors 20 and shall publish the list in the Pennsylvania Bulletin. When a 21 state applies a new preference or prohibition, the department 22 shall publish that information in the Pennsylvania Bulletin as 23 an addition to the original list. 24 (g) Inclusion in invitation for bids or request for 25 proposals.--In all invitations for bids and requests for 26 proposals for the procurement of supplies exceeding the amount 27 established by the department for small purchases under section 28 514 all purchasing agencies shall include a list of all the 29 states that have been found by the department to have applied a 30 preference and the amount of the preference. All invitations for 19970S0005B0228 - 16 -
1 bids, requests for proposals and notices issued for the purpose 2 of securing bids or proposals for public contracts as issued by 3 any purchasing agency exceeding the amount established by the 4 department for small purchases under section 514 shall include a 5 list of all states that apply a prohibition against certain 6 supplies and shall inform potential bidders or offerors that 7 they are prohibited from using supplies from those states. If a 8 bid or proposal discloses that the bidder or offeror is offering 9 supplies from a state which prohibits the use of out-of-State 10 supplies, the bid or proposal shall be rejected. 11 (h) Federal funds.--The provisions of this section shall not 12 be applicable when the application of this section may 13 jeopardize the receipt of Federal funds. 14 (i) Waiver.--The provisions of this section may be waived 15 when the head of the purchasing agency determines in writing 16 that it is in the best interests of the Commonwealth. 17 (j) Definitions.--As used in this section, the following 18 words and phrases shall have the meanings given to them in this 19 subsection: 20 "Public contract." A contract for the construction of any 21 public building or other public work constructed at the expense 22 of the Commonwealth or any authority or instrumentality thereof, 23 or the purchase or lease of any supplies by any Commonwealth 24 agency. 25 "Resident bidder or offeror." A person, partnership, 26 corporation or other business entity authorized to transact 27 business in this Commonwealth and having a bona fide 28 establishment for transacting business in this Commonwealth at 29 which it was transacting business on the date when bids or 30 proposals for the public contract were first solicited. 19970S0005B0228 - 17 -
1 § 108. Recycled materials. 2 (a) Commonwealth agency review.--All Commonwealth agencies 3 shall review their procurement procedures and specifications in 4 accordance with section 1504 of the act of July 28, 1988 5 (P.L.556, No.101), known as the Municipal Waste Planning, 6 Recycling and Waste Reduction Act. 7 (b) Preference for recycled content.--The contracting 8 officer shall comply with section 1505 of the Municipal Waste 9 Planning, Recycling and Waste Reduction Act regarding a 10 preference for bids containing a minimum percentage of recycled 11 content for the supply subject to the bid. 12 CHAPTER 3 13 PROCUREMENT ORGANIZATION 14 Subchapter 15 A. Organization of Public Procurement 16 B. Procurement Policy 17 C. Powers and Duties of Department 18 D. Powers and Duties of the Board of 19 Commissioners of Public Grounds and Buildings 20 and the Office of the Budget 21 E. Coordination, Training and Education 22 SUBCHAPTER A 23 ORGANIZATION OF PUBLIC PROCUREMENT 24 Sec. 25 301. Procurement responsibility. 26 § 301. Procurement responsibility. 27 (a) General organization.--Formulation of procurement policy 28 governing the procurement, management, control and disposal of 29 supplies, services and construction for Commonwealth agencies 30 shall be the responsibility of the department as provided for in 19970S0005B0228 - 18 -
1 Subchapter B (relating to procurement policy). The procurement 2 and supervision of the procurement of supplies, services and 3 construction for executive agencies and those independent 4 agencies for which the department acts as purchasing agency 5 shall be the responsibility of the department as provided for in 6 Subchapter C (relating to powers and duties of department). 7 (b) Application to independent agencies.--Except as 8 otherwise specifically provided by law and this section, an 9 independent agency shall use the department as its purchasing 10 agency for the procurement of supplies or construction. However, 11 any independent agency that acts as its own purchasing agency 12 shall use the procedures provided in this part for any 13 procurement of supplies or construction. 14 (c) Exceptions.--The following supplies, services and 15 construction need not be procured through the department but 16 shall nevertheless be procured by the appropriate purchasing 17 agency, subject to the requirements of this part: 18 (1) Bridge, highway, dam, airport, railroad or other 19 heavy or specialized construction. 20 (2) Works of art for museum and public display. 21 (3) Published books, maps, periodicals and technical 22 pamphlets. 23 (4) Architect and engineer services as defined in 24 section 901 (relating to definitions). 25 (5) Perishable food stuffs. 26 SUBCHAPTER B 27 PROCUREMENT POLICY 28 Sec. 29 311. Powers and duties. 30 312. Procurement regulations. 19970S0005B0228 - 19 -
1 § 311. Powers and duties. 2 Except as otherwise provided in this part, the department may 3 promulgate regulations governing the procurement, management, 4 control and disposal of any and all supplies, services and 5 construction to be procured by Commonwealth agencies. The 6 department shall consider and decide matters of policy within 7 the provisions of this part. The department may audit and 8 monitor the implementation of its regulations and the 9 requirements of this part. 10 § 312. Procurement regulations. 11 Regulations shall be promulgated by the department as 12 provided in 45 Pa.C.S. Part II (relating to publication and 13 effectiveness of Commonwealth documents). The department may not 14 delegate its power to promulgate regulations. No regulation may 15 change any commitment, right or obligation of any Commonwealth 16 agency or of a contractor under a contract in existence on the 17 effective date of the regulation. 18 SUBCHAPTER C 19 POWERS AND DUTIES OF DEPARTMENT 20 Sec. 21 321. Powers and duties. 22 322. Specific construction powers, duties and procedures. 23 § 321. Powers and duties. 24 Except as otherwise specifically provided in this part, the 25 department shall have the following powers and duties: 26 (1) Procure or supervise the procurement of all 27 supplies, services and construction needed by executive 28 agencies and those independent agencies for which the 29 department acts as purchasing agency. Procurement authority 30 may be delegated in writing to Commonwealth agencies by the 19970S0005B0228 - 20 -
1 Secretary of General Services. 2 (2) Exercise general supervision and control over all 3 inventories of supplies belonging to executive agencies. 4 (3) Sell, trade or otherwise dispose of surplus supplies 5 belonging to Commonwealth agencies. 6 (4) Establish and maintain programs for the inspection, 7 testing and acceptance of supplies and construction. 8 (5) Establish and maintain a central office where 9 businesses operating in this Commonwealth may obtain 10 information pertaining to the procurement needs of 11 Commonwealth agencies. 12 (6) Establish and maintain a contractor responsibility 13 program in coordination with the Office of the Budget. 14 § 322. Specific construction powers, duties and procedures. 15 Whenever the General Assembly has made an appropriation or 16 authorized borrowing under Article XVI-B of the act of April 9, 17 1929 (P.L.343, No.176), known as The Fiscal Code, in any budget 18 to the department or to any Commonwealth agency or any State- 19 supported institution for the construction of a capital 20 improvement or for the repair or alteration of a capital 21 improvement to be completed by the department to cost more than 22 the amount established by the department in section 514 23 (relating to small purchases) for small construction purchases, 24 the construction of that capital improvement shall be carried 25 out by the department unless the work is to be done by State 26 employees or by inmates or patients of a State institution or 27 State institutions or unless the Commonwealth agency or State- 28 supported institution to which the General Assembly has 29 appropriated money for the foregoing purposes is, by law or by 30 the act making the appropriation, authorized to erect, alter or 19970S0005B0228 - 21 -
1 enlarge buildings independently of the department. 2 (1) (i) If the appropriation for a maintenance project 3 is to a Commonwealth agency or State-supported 4 institution other than the department, the Commonwealth 5 agency or State-supported institution shall notify the 6 department to have plans and specifications for the 7 project prepared. 8 (ii) Upon enactment of appropriations for capital 9 projects, all Commonwealth agencies and State-supported 10 institutions shall, with the approval of the Governor, 11 notify the department to have plans and specifications 12 for the projects prepared. 13 (2) Promptly after the notice, in such cases, or 14 promptly after any appropriation made to it becomes 15 available, the department shall, if necessary, select an 16 architect and/or an engineer, in accordance with the 17 selection procedures of section 905 (relating to procurement 18 of design professional services) to design the work and 19 prepare the specifications therefor. 20 (3) The department shall enter into a contract with the 21 architect or engineer, which shall provide all of the 22 following: 23 (i) A date for the completion of the plans and 24 specifications. 25 (ii) That the plans and specifications must meet 26 with the approval of the Commonwealth agency or State- 27 supported institution for which the building is being 28 erected, altered or enlarged and, in the case of an 29 administrative board or commission of the Commonwealth 30 agency with which the board or commission is respectively 19970S0005B0228 - 22 -
1 connected, to the extent of the type and general 2 character of the building, design of the floor layouts, 3 medical equipment or other equipment of a nature peculiar 4 to the building for which the plans and specifications 5 are being prepared. 6 (iii) That the plans, drawings and specifications 7 must be approved by the department. 8 (iv) That the plans and specifications must be 9 approved by the Department of Labor and Industry, the 10 Department of Health and the Department of Environmental 11 Protection, to the extent to which those Commonwealth 12 agencies, respectively, have jurisdiction to require the 13 submission to them for approval of certain features of 14 the building. 15 The architect or engineer in preparing plans and 16 specifications shall consult with the Commonwealth agency of 17 State-supported institution for which the building is to be 18 erected, altered or enlarged, but the department shall insist 19 upon the prompt completion of the plans and specifications, 20 within the time prescribed in the architect's or engineer's 21 contracts unless it shall specifically agree in writing to an 22 extension thereof. 23 (4) Every Commonwealth agency or State-supported 24 institution whose approval of plans and specifications is 25 required under this section shall, within 30 days after 26 submission thereof by the architect or engineer, approve or 27 disapprove all sketches, drawings, specifications and other 28 documents, and shall inform the architect or engineer of 29 decisions in a reasonable time so as not to delay him in his 30 work. 19970S0005B0228 - 23 -
1 (5) The enforcement of all contracts provided for by 2 this section shall be under the control and supervision of 3 the department. The department shall have the authority to 4 engage the services of a construction management firm to 5 coordinate the work of the total project. All questions or 6 disputes arising between the department and any contractor 7 with respect to any matter pertaining to a contract entered 8 into with the department or any part thereto or any breach of 9 contract arising thereunder shall be submitted to final and 10 binding arbitration as provided by the terms of the contract 11 which finding shall be final and not subject to further 12 appeal or, if not so provided, shall be referred to the Board 13 of Claims as set forth in the act of May 20, 1937 (P.L.728, 14 No.193), referred to as the Board of Claims Act, whose 15 decision and award shall be final and binding and conclusive 16 upon all parties thereto, except that either party shall have 17 the right to appeal from the decision and award as provided 18 by law. 19 (6) The department shall examine all bills on account of 20 the contracts entered into under the provisions of this 21 section, and, if they are correct, the department shall 22 certify that the materials have been furnished, or that the 23 work or labor has been performed in a workmanlike manner, and 24 in accordance with the contract, approve the bills and issue 25 its requisition therefor, or forward its certificate to the 26 proper Commonwealth agency or State-supported institution, as 27 the case may be. Progress payments and final payments shall 28 not estop the department from pursuing its lawful remedies 29 for defects in workmanship or materials or both and other 30 damages. 19970S0005B0228 - 24 -
1 (7) Whenever the department enters into a single 2 contract for a project, in the absence of good and sufficient 3 reasons, the contractor shall pay each subcontractor within 4 15 days of receipt of payment from the department, an amount 5 equal to the percentage of completion allowed to the 6 contractor on the account of the subcontractor's work. The 7 contractor shall also require the subcontractor to make 8 similar payments to his subcontractors. 9 (8) The department shall have the right to engage the 10 services of any consulting or supervising engineer or 11 engineers, whom it may deem necessary for the proper 12 designing of or inspection or supervision of projects 13 constructed, altered or enlarged by the department under this 14 section in accordance with the selection procedures of 15 section 905. 16 (9) Changes in scope in the plans or specifications, or 17 both, may be made after their approval only with the consent 18 of the Governor and all of the Commonwealth agencies and 19 State-supported institutions whose approval of the original 20 plans or specifications, or both, was necessary under this 21 section. 22 (10) If the appropriation is to a Commonwealth agency, 23 other than the department or State-supported institution, the 24 department shall award and enter into the contract as agent 25 for the Commonwealth agency or State-supported institution to 26 which the appropriation was made. 27 SUBCHAPTER D 28 POWERS AND DUTIES OF THE BOARD OF COMMISSIONERS OF 29 PUBLIC GROUNDS AND BUILDINGS AND THE OFFICE OF THE BUDGET 30 Sec. 19970S0005B0228 - 25 -
1 326. Board of Commissioners of Public Grounds and Buildings. 2 327. Office of the Budget. 3 § 326. Board of Commissioners of Public Grounds and Buildings. 4 No sole source procurement for supplies or leases of real 5 estate when a Commonwealth agency is the lessee shall be valid 6 or effective unless, upon review, it is approved by the Board of 7 Commissioners of Public Grounds and Buildings as provided in 8 section 515 (relating to sole source procurement). 9 § 327. Office of the Budget. 10 (a) Encumbrance of funds.--The Office of the Budget shall 11 encumber sufficient funds for the payment of all invoices for 12 the procurement of supplies, services and construction. 13 (b) Contractor responsibility program.--The Office of the 14 Budget shall assist the department in the establishment and 15 maintenance of a contractor responsibility program. 16 (c) Contracts for services.--Except for contracts awarded 17 pursuant to section 514 (relating to small purchases), the 18 Office of the Budget shall review and approve all contracts for 19 services for: 20 (1) Fiscal responsibility and budgetary appropriateness. 21 (2) Availability of funds. 22 (d) Agency comptrollers.--An agency comptroller may at his 23 option serve as a nonvoting member of an evaluation committee 24 for requests for proposals or a similar contract bidding or 25 selection committee for the acquisition of services. 26 SUBCHAPTER E 27 COORDINATION, TRAINING AND EDUCATION 28 Sec. 29 331. Collection of data concerning public procurement. 30 332. Advisory groups. 19970S0005B0228 - 26 -
1 § 331. Collection of data concerning public procurement. 2 All using agencies shall furnish such reports as the 3 department may require concerning usage, needs and stock on 4 hand, and the department may prescribe the format and forms to 5 be used by the using agencies in requisitioning, ordering and 6 reporting supplies, services and construction. 7 § 332. Advisory groups. 8 (a) Procurement Advisory Council.--The department may 9 establish a Procurement Advisory Council and allocate funds for 10 it that may be available. If created, the council, upon adequate 11 public notice, shall meet at least once a year for the 12 discussion of problems and recommendations for improvement of 13 the procurement process. When requested by the department, the 14 council may conduct studies, research and analyses and make 15 reports and recommendations with respect to subjects or matters 16 within the jurisdiction of the department. The council may 17 consist of any qualified persons the department deems desirable. 18 (b) Other advisory groups.--The department may appoint 19 advisory groups to assist with respect to specifications or 20 procurement in specific areas and with respect to any other 21 matters within the authority of the department. 22 (c) Reimbursement of expenses.--Members of the council and 23 other advisory groups may be reimbursed for expenses incurred in 24 the performance of their duties, subject to expenditure 25 limitations prescribed by the department. 26 CHAPTER 5 27 SOURCE SELECTION AND CONTRACT FORMATION 28 Subchapter 29 A. Definitions 30 B. Methods of Source Selection 19970S0005B0228 - 27 -
1 C. Cancellation of Invitations for Bids or Requests for 2 Proposals 3 D. Qualifications and Duties 4 E. Types of Contracts 5 F. Inspection of Plant and Audit of Records 6 G. Determinations and Reports 7 SUBCHAPTER A 8 DEFINITIONS 9 Sec. 10 501. Definitions. 11 § 501. Definitions. 12 The following words and phrases when used in this chapter 13 shall have the meanings given to them in this section unless the 14 context clearly indicates otherwise: 15 "Established catalog price." The price included in a 16 catalog, price list, schedule or other form that: 17 (1) is regularly maintained by a manufacturer or 18 contractor; 19 (2) is either published or otherwise available for 20 inspection by customers; and 21 (3) states prices at which sales are currently or were 22 last made to a significant number of any category of buyers 23 or buyers constituting the general buying public for the 24 supplies or services involved. 25 "Invitation for bids." All documents, whether attached or 26 incorporated by reference, used for soliciting bids. 27 "Life cycle cost." The total cost of the supply in terms of 28 purchase cost, installation cost, maintenance cost, energy cost, 29 supply cost and other costs. 30 "Procurement description." The words used in a solicitation 19970S0005B0228 - 28 -
1 to describe the supplies, services or construction to be 2 procured. The term includes specifications attached to or made a 3 part of the solicitation. 4 "Request for proposals." All documents, whether attached or 5 incorporated by reference, used for soliciting proposals. 6 "Responsible bidder or offeror." A person who has the 7 capability in all respects to fully perform the contract 8 requirements and the integrity and reliability which will assure 9 good faith performance. 10 "Responsive bidder or offeror." A person who has submitted a 11 bid which conforms in all material respects to the invitation 12 for bids. 13 "Sealed bid or proposal." A bid or proposal whose contents 14 is not disclosed until the bid opening time or the proposal 15 receipt date. Bids and proposals are typically submitted in 16 sealed envelopes to meet this requirement, but electronic 17 submission is not prohibited so long as the purchasing agency 18 has the electronic capability to maintain the confidentiality of 19 the bid or proposal until the bid opening time or proposal 20 receipt date. 21 SUBCHAPTER B 22 METHODS OF SOURCE SELECTION 23 Sec. 24 511. Methods of source selection. 25 512. Competitive sealed bidding. 26 513. Competitive sealed proposals. 27 514. Small purchases. 28 515. Sole source procurement. 29 516. Emergency procurement. 30 517. Multiple awards. 19970S0005B0228 - 29 -
1 518. Competitive selection procedures for certain services. 2 519. Selection procedure for insurance and bonds. 3 520. Supplies and services furnished by persons with 4 disabilities. 5 § 511. Methods of source selection. 6 Unless otherwise authorized by law, all Commonwealth agency 7 contracts shall be awarded by competitive sealed bidding under 8 section 512 (relating to competitive sealed bidding) except as 9 provided in: 10 Section 513 (relating to competitive sealed proposals). 11 Section 514 (relating to small purchases). 12 Section 515 (relating to sole source procurement). 13 Section 516 (relating to emergency procurement). 14 Section 517 (relating to multiple awards). 15 Section 518 (relating to competitive selection procedures 16 for certain services). 17 Section 519 (relating to selection procedure for 18 insurance and bonds). 19 Section 520 (relating to supplies and services furnished 20 by persons with disabilities). 21 Section 905 (relating to procurement of design 22 professional services). 23 § 512. Competitive sealed bidding. 24 (a) Conditions for use.--Contracts shall be awarded by 25 competitive sealed bidding except as otherwise provided in 26 section 511 (relating to methods of source selection). 27 (b) Invitation for bids.--An invitation for bids shall be 28 issued and shall include a procurement description and all 29 contractual terms, whenever practical, and conditions applicable 30 to the procurement. 19970S0005B0228 - 30 -
1 (c) Public notice.--Adequate public notice of the invitation 2 for bids shall be given a reasonable time prior to the date set 3 for the opening of bids. The notice may include publication in a 4 newspaper of general circulation a reasonable time before bid 5 opening. The notice may also include advertisement as provided 6 for in 45 Pa.C.S. § 306 (relating to use of trade publications). 7 (d) Bid opening.--Bids shall be opened publicly in the 8 presence of one or more witnesses at the time and place 9 designated in the invitation for bids. The amount of each bid 10 and any other relevant information as may be specified by 11 regulation, together with the name of each bidder, shall be 12 recorded. The record shall be open to public inspection. 13 (e) Bid acceptance and evaluation.--Bids shall be 14 unconditionally accepted without alteration or modification 15 except as authorized in this part or in the invitation for bids. 16 Bids shall be evaluated based on the requirements set forth in 17 the invitation for bids, which may include criteria to determine 18 acceptability such as inspection, testing, quality, workmanship, 19 delivery and suitability for a particular purpose. Those 20 criteria that will affect the bid price and be considered in 21 evaluation for award shall be objectively measurable, such as 22 discounts, transportation costs and total or life cycle costs. 23 The invitation for bids shall set forth the evaluation criteria 24 to be used. No criteria may be used in bid evaluation that are 25 not set forth in the invitation for bids. 26 (f) Modification or withdrawal of bids.-- 27 (1) Bids may be modified or withdrawn by written notice 28 or in person by a bidder or its authorized representative if 29 its identity is made known and a receipt for the bid is 30 signed prior to the exact hour and date set for the opening 19970S0005B0228 - 31 -
1 of bids. Except as otherwise provided in this part, 2 withdrawals and modifications of bids received after the 3 exact hour and date specified for the opening of bids shall 4 not be considered. 5 (2) Withdrawal of erroneous bids after bid opening but 6 before award based on bid mistakes shall be permitted by the 7 written determination of the contracting officer. When the 8 bidder requests relief and presents credible evidence that 9 the reason for the lower bid price was a clerical mistake as 10 opposed to a judgment mistake and was actually due to an 11 unintentional arithmetical error or an unintentional omission 12 of a substantial quantity of work, labor, material or 13 services made directly in the compilation of the bid. The 14 request for relief and the supporting evidence must be 15 received by the contracting officer within a reasonable time 16 period after the bid opening. The time period shall be 17 specified by the department. 18 (3) The contracting officer shall not permit a 19 withdrawal of a bid if the withdrawal of the bid would result 20 in the awarding of the contract on another bid of the same 21 bidder, its partner or a corporation or business venture 22 owned by or in which the bidder has a substantial interest. 23 No bidder who is permitted to withdraw a bid shall supply any 24 material or labor to or perform any subcontract or other work 25 agreement for any person to whom a contract or subcontract is 26 awarded in the performance of the contract for which the 27 withdrawn bid was submitted, without the written approval of 28 the contracting officer. 29 (g) Award.--The contract shall be awarded within 60 days of 30 the bid opening by written notice to the lowest responsible and 19970S0005B0228 - 32 -
1 responsive bidder whose bid meets the requirements and criteria 2 set forth in the invitation for bids. Thirty-day extensions of 3 the date for the award may be made by mutual written consent of 4 the contracting officer and the lowest responsible and 5 responsive bidder. Within 30 days of the bid opening the 6 contracting officer shall, if bid security was required by the 7 invitation for bids, return the bid security to all but the 8 lowest and next-to-lowest responsible and responsive bidders. 9 (h) Multistep sealed bidding.--When it is considered 10 impractical to prepare initially a procurement description to 11 support an award based on price, an invitation for bids may be 12 issued requesting the submission of unpriced offers, to be 13 followed by an invitation for bids limited to those bidders 14 whose offers have been qualified under the criteria set forth in 15 the first solicitation. 16 § 513. Competitive sealed proposals. 17 (a) Conditions for use.--When the contracting officer 18 determines in writing that the use of competitive sealed bidding 19 is either not practicable or advantageous to the Commonwealth, a 20 contract may be entered into by competitive sealed proposals. 21 (b) Request for proposals.--Proposals shall be solicited 22 through a request for proposals. 23 (c) Public notice.--Public notice of the request for 24 proposals shall be given in the same manner as provided in 25 section 512(c) (relating to competitive sealed bidding). 26 (d) Receipt of proposals.--Offerors shall submit their 27 proposal to ensure that their proposals are received prior to 28 the time and date established for receipt to the proposals. 29 Proposals shall be submitted in the format required by the 30 request for proposals. Proposals shall be opened so as to avoid 19970S0005B0228 - 33 -
1 disclosure of their contents to competing offerors. 2 (e) Evaluation.--The relative importance of the evaluation 3 factors shall be fixed prior to opening the proposals. A 4 Commonwealth agency is required to invite its comptroller to 5 participate in the evaluation as a nonvoting member of any 6 evaluation committee. 7 (f) Discussion with responsible offerors and revision of 8 proposals.--As provided in the request for proposals, 9 discussions may be conducted with responsible offerors who 10 submit proposals determined to be reasonably susceptible of 11 being selected for award for the purpose of clarification to 12 assure full understanding of and responsiveness to the 13 solicitation requirements and for the purpose of obtaining best 14 and final offers. Offerors shall be accorded fair and equal 15 treatment with respect to any opportunity for discussion and 16 revision of proposals. In conducting discussions, there shall be 17 no disclosure of any information derived from proposals 18 submitted by competing offerors. 19 (g) Award of contract.--The responsible offeror whose 20 proposal is determined in writing to be the most advantageous to 21 the purchasing agency, taking into consideration price and all 22 evaluation factors, shall be selected for contract negotiation. 23 (h) Contract negotiation.--After selection, the purchasing 24 agency shall proceed to negotiate a contract with the selected 25 offeror. 26 § 514. Small purchases. 27 If the procurement is not the subject of a requirements 28 contract between the purchasing agency and a contractor, the 29 head of the purchasing agency may authorize in writing purchases 30 without formal bid procedures in the field, not exceeding the 19970S0005B0228 - 34 -
1 amount established by the purchasing agency. The department may 2 authorize procurement on a no-bid basis for procurements which 3 do not exceed the amount established by the department for 4 small, no-bid purchases. Procurement requirements shall not be 5 artificially divided so as to constitute a small purchase under 6 this section. Small purchases shall be made in accordance with 7 the requirements of the written authorization and this section. 8 Records of all small purchases shall be transmitted to the 9 purchasing agency. 10 § 515. Sole source procurement. 11 A contract may be awarded for a supply, service or 12 construction item without competition when the contracting 13 officer determines in writing that one of the following 14 conditions exists: 15 (1) Only a single contractor is capable of providing the 16 supply, service or construction. 17 (2) A Federal or State statute or regulation exempts the 18 supply service or construction from the competitive 19 procedure. 20 (3) The total cost of the supply, service or 21 construction is less than the amount established by the 22 department for small, no-bid purchases under section 514 23 (relating to small purchases). 24 (4) It is clearly not feasible to award the contract on 25 a competitive basis. 26 (5) The services are to be provided by attorneys 27 selected by the Office of General Counsel. 28 (6) The services are to be provided by expert witnesses. 29 (7) The services involve the repair of equipment and 30 they are to be performed by the manufacturer of the equipment 19970S0005B0228 - 35 -
1 or by the manufacturer's authorized dealer, provided the 2 contracting officer determines that bidding is not 3 appropriate under the circumstances. 4 (8) The contract is for financial or investment experts 5 selected by the Secretary of the Budget. 6 (9) It is in the best of the Commonwealth. This written 7 determination shall be included in the contract file. With 8 the exception of paragraph (3), if the sole source 9 procurement is for a supply, it must be approved by the Board 10 of Commissioners of Public Grounds and Buildings prior to the 11 award of a contract. 12 § 516. Emergency procurement. 13 The head of a purchasing agency may make or authorize others 14 to make an emergency procurement when there exists a threat to 15 public health, welfare or safety or the urgency of the need does 16 not permit the delay involved in using more formal competitive 17 methods. Whenever practical, in the case of a procurement of a 18 supply, at least two bids shall be solicited. A written 19 determination of the basis for the emergency and for the 20 selection of the particular contractor shall be included in the 21 contract file. 22 § 517. Multiple awards. 23 (a) Conditions for use.--Contracts may be entered into on a 24 multiple award basis when the head of the purchasing agency 25 determines that one or more of the following criteria is 26 applicable: 27 (1) It is administratively or economically impractical 28 to develop or modify specifications for a myriad of related 29 supplies because of rapid technological changes. 30 (2) The subjective nature in the use of certain supplies 19970S0005B0228 - 36 -
1 and the fact that recognizing this need creates a more 2 efficient use of the item. 3 (3) It is administratively or economically impractical 4 to develop or modify specifications because of the 5 heterogeneous nature of the product lines. 6 (4) There is a need for compatibility with existing 7 systems. 8 (5) The agency should select the contractor to furnish 9 the supply, service or construction based upon best value or 10 return on investment. 11 (b) Solicitation process.--Invitations to bid or requests 12 for proposals shall be issued for the supplies, services or 13 construction to be purchased. 14 (c) Public notice.--Public notice of the invitation for bids 15 shall be given in the same manner as provided in section 512(c) 16 (relating to competitive sealed bidding). 17 (d) Receipt of bids or proposals.--Bids shall be opened in 18 the same manner as provided in section 512(d). Proposals shall 19 be received in the same manner as provided in section 513(d) 20 (relating to competitive sealed proposals). 21 (e) Award.--The invitation for bids or request for proposals 22 shall describe the method for selection of the successful 23 bidders or offerors. There are three options: 24 (1) Awards shall be made to the lowest responsible and 25 responsive bidder or offeror for each designated 26 manufacturer. 27 (2) Awards shall be made to the two or three lowest 28 responsible and responsive bidders or offerors for each 29 designated manufacturer. 30 (3) Awards shall be made to all responsible and 19970S0005B0228 - 37 -
1 responsive bidders or offers. The Commonwealth agency shall 2 have the discretion to select the contractor to furnish the 3 supply, service or construction based upon best value or 4 return on investment. 5 § 518. Competitive selection procedures for certain services. 6 (a) Conditions for use.--The services of accountants, 7 clergy, physicians, lawyers, dentists and other personal 8 services which are not performed by other salaried employees 9 shall be procured in accordance with this section except as 10 authorized under section 514 (relating to small purchases), 515 11 (relating to sole source procurement) or 516 (relating to 12 emergency procurement). 13 (b) Statement of qualifications.--Persons engaged in 14 providing the types of services specified in subsection (a) may 15 submit statements of qualifications and expressions of interest 16 in providing these services. The contracting officer may specify 17 a uniform format for statements of qualifications. Persons may 18 amend these statements at any time by filing a new statement. 19 (c) Request for proposals.--Adequate notice of the need for 20 the services specified in subsection (a) shall be given by the 21 purchasing agency through a request for proposals. The request 22 for proposals shall describe the services required, list the 23 type of information and data required of each offeror and state 24 the relative importance of particular qualifications. 25 (d) Discussions.--The contracting officer may conduct 26 discussions with any offeror who has submitted a proposal to 27 determine the offeror's qualifications for further 28 consideration. Discussions shall not disclose any information 29 derived from proposals submitted by other offerors. 30 (e) Award.--Award shall be made to the offeror determined in 19970S0005B0228 - 38 -
1 writing by the contracting officer to be best qualified based on 2 the evaluation factors set forth in the request for proposals. 3 Fair and reasonable compensation shall be determined through 4 negotiation. If compensation cannot be agreed upon with the best 5 qualified offeror, then negotiations will be formally terminated 6 with the selected offeror. If proposals were submitted by one or 7 more other offerors determined to be qualified, negotiations may 8 be conducted with the other offeror or offerors in the order of 9 their respective qualification ranking. The contract may be 10 awarded to the offeror then ranked as best qualified if the 11 amount of compensation is determined to be fair and reasonable. 12 § 519. Selection procedure for insurance and bonds. 13 (a) Conditions for use.--Insurance and bonds shall be 14 procured by the department in accordance with this section 15 except as authorized under section 515 (relating to sole source 16 procurement) or 516 (relating to emergency procurement). 17 (b) Statement of qualifications.--Insurance and bond 18 carriers may submit statements of qualifications and expressions 19 of interest in providing insurance or bonds. The department may 20 specify a uniform format for statements of qualifications. 21 (c) Request for proposals.--Adequate notice of the need for 22 insurance or bond coverage shall be given through a request for 23 proposals. The request for proposals shall describe the type of 24 insurance or bond coverage required and list the type of 25 information and data required of each offeror. 26 (d) Receipt of proposals.--Offerors shall submit their 27 proposals prior to the time and date specified. 28 (e) Discussions with responsible offerors and revision to 29 proposals.--Discussions and negotiations may be conducted with 30 responsible offerors who submit proposals determined to be 19970S0005B0228 - 39 -
1 reasonably susceptible of being selected for award. Offerors 2 shall be accorded fair and equal treatment with respect to any 3 opportunity for discussion, negotiation and revision of 4 proposals. Revisions may be permitted after submissions and 5 prior to award for the purpose of obtaining best and final 6 offers. 7 (f) Award.--Award shall be made to the offeror whose 8 proposal is determined in writing by the department to be the 9 most advantageous to the Commonwealth based on criteria 10 determined by the department, including the coverage offered and 11 the cost of the premium. 12 § 520. Supplies and services furnished by persons with 13 disabilities. 14 (a) General rule.--Supplies and services furnished by 15 persons with disabilities shall be procured by a purchasing 16 agency in accordance with this section. 17 (b) Fair market price.--The department shall determine the 18 fair market price of any supply or service furnished by persons 19 with disabilities and offered for sale to any Commonwealth 20 agency by an agency for persons with disabilities. The 21 department shall also revise the prices in accordance with 22 changing market conditions and promulgate regulations regarding 23 specifications, time of delivery and other relevant matters. 24 (c) Distribution.--At the request of the department, the 25 Department of Public Welfare or a nonprofit agency with the 26 approval of the Department of Public Welfare shall facilitate 27 the distribution of orders for supplies and services among 28 agencies for persons with disabilities. 29 (d) Procurement of supplies and services furnished by 30 persons with disabilities.-- Except as provided in subsection 19970S0005B0228 - 40 -
1 (e), all supplies or services furnished by persons with 2 disabilities shall be procured in accordance with applicable 3 specifications of the department or other Commonwealth agencies 4 from any agency for persons with disabilities whenever the 5 supplies and services are available at a price determined to be 6 the fair market price. The head of a purchasing agency shall 7 annually discuss its needs for supplies or services with 8 agencies for persons with disabilities. 9 (e) Procurement from Commonwealth agency.--If any supply or 10 service furnished by persons with disabilities and offered for 11 sale is available for procurement from any Commonwealth agency 12 and this part or any other statute requires the procurement of 13 the supply or service from the Commonwealth agency, then the 14 procurement of the supply or service shall be made in accordance 15 with the other provisions. 16 (f) Definitions.--As used in this section, the following 17 words and phrases shall have the meanings given to them in this 18 subsection: 19 "Agency for persons with disabilities." Any charitable 20 nonprofit agency incorporated under the laws of this 21 Commonwealth and approved by the Department of General Services 22 through which persons with disabilities manufacture supplies and 23 provide services in this Commonwealth. 24 "Mentally retarded." Subaverage general intellectual 25 functioning which originates during the developmental period and 26 is associated with impairment of maturation, learning or social 27 adjustment. 28 "Person with a disability." A person who is visually 29 impaired, mentally retarded or physically disabled. 30 "Physically disabled." A limitation of most activities and 19970S0005B0228 - 41 -
1 functioning by virtue of a severe impairment of the various 2 bodily systems which cannot be eliminated, modified or 3 substantially reduced by the usual rehabilitation services and 4 which precludes competitive employment. 5 "Supply or service furnished by persons with disabilities." 6 Any supply manufactured or service rendered in this Commonwealth 7 by a person with a disability. The term does not include any 8 service the practice of which is licensed under the laws of this 9 Commonwealth. 10 "Visually impaired." A condition in which central visual 11 acuity does not exceed 20/200 in the better eye with correcting 12 lenses or in which the widest diameter of the visual field 13 subtends an angle no greater than 20 degrees. 14 SUBCHAPTER C 15 CANCELLATION OF INVITATIONS FOR BIDS OR 16 REQUESTS FOR PROPOSALS 17 Sec. 18 521. Cancellation of invitations for bids or requests for 19 proposals. 20 § 521. Cancellation of invitations for bids or requests for 21 proposals. 22 An invitation for bids, a request for proposals or other 23 solicitation may be canceled or any or all bids or proposals may 24 be rejected in whole or in part as may be specified in the 25 solicitation when it is in the best interests of the 26 Commonwealth. The reasons for the cancellation or rejection 27 shall be made part of the contract file. 28 SUBCHAPTER D 29 QUALIFICATIONS AND DUTIES 30 Sec. 19970S0005B0228 - 42 -
1 531. Debarment or suspension. 2 532. Prequalification of bidders and offerors. 3 533. Responsibility of bidders and offerors. 4 534. Security and performance bonds. 5 535. Cost or pricing data. 6 § 531. Debarment or suspension. 7 (a) Authority.--After reasonable notice to the person 8 involved and reasonable opportunity for that person to be heard, 9 the head of a purchasing agency, after consultation with the 10 head of the using agency, shall have authority to debar a person 11 for cause from consideration for award of contracts for a period 12 of not more than three years or to suspend a person from 13 consideration for award of contracts if there is probable cause 14 for debarment for a period of not more than three months. 15 (b) Causes for debarment or suspension.--The causes for 16 debarment or suspension include: 17 (1) Conviction, including a plea of guilty or nolo 18 contendere, for commission of a criminal offense as an 19 incident to obtaining or attempting to obtain a public or 20 private contract or subcontract or in the performance of the 21 contract or subcontract. 22 (2) Conviction, including a plea of guilty or nolo 23 contendere, under Federal or State statutes of embezzlement, 24 theft, forgery, bribery, falsification or destruction of 25 records, receiving stolen property or any other offense 26 indicating a lack of business integrity or business honesty 27 which currently, seriously and directly affects 28 responsibility as a contractor. 29 (3) Conviction, including a plea of guilty or nolo 30 contendere, under Federal or State antitrust statutes arising 19970S0005B0228 - 43 -
1 out of the submission of bids or proposals. 2 (4) Any of the following violations of contract 3 provisions of a character which is regarded by the head of a 4 purchasing agency to be so serious as to justify debarment 5 action: 6 (i) Deliberate failure without good cause to perform 7 in accordance with the specifications or within the time 8 limit provided in the contract. 9 (ii) A recent record of failure to perform or of 10 unsatisfactory performance in accordance with the terms 11 of one or more contracts. 12 Failure to perform or unsatisfactory performance caused by 13 acts beyond the control of the contractor shall not be 14 considered to be a basis for debarment. 15 (5) Any other cause the head of a purchasing agency 16 determines to be so serious and compelling as to affect 17 responsibility as a contractor, including debarment by 18 another governmental entity for any cause listed in the 19 contractor responsibility program established under 20 Subchapters C (relating to powers and duties of department) 21 and D (relating to powers and duties of the Board of 22 Commissioners of Public Grounds and Buildings and the Office 23 of the Budget) of Chapter 3. 24 (6) Violations of the ethical standards set forth in 25 Chapter 23 (relating to ethics in public contracting) or the 26 act of July 19, 1957 (P.L.1017, No.451), known as the State 27 Adverse Interest Act. 28 (c) Decision.--The head of a purchasing agency shall issue a 29 written decision to debar or suspend. The decision shall: 30 (1) State the reasons for the action taken. 19970S0005B0228 - 44 -
1 (2) Inform the debarred or suspended person involved of 2 the right to judicial review as provided in subsection (e). 3 (d) Notice of decision.--A copy of the decision under 4 subsection (c) shall be delivered by registered mail to the 5 debarred or suspended person and any other party intervening. 6 (e) Finality of decision and appeal.--A decision under 7 subsection (c) shall be final and conclusive unless the debarred 8 or suspended person appeals to the Commonwealth Court under 42 9 Pa.C.S. § 763(a)(1) (relating to direct appeals from government 10 agencies) within 30 days after receipt of the decision. 11 § 532. Prequalification of bidders and offerors. 12 Prospective bidders and offerors may be prequalified for 13 particular types of supplies, services and construction. 14 Solicitation mailing lists of potential contractors shall 15 include, but shall not be limited to, prequalified bidders and 16 offerors. 17 § 533. Responsibility of bidders and offerors. 18 (a) Determination of nonresponsibility.--A written 19 determination of nonresponsibility of a bidder or offeror shall 20 be made in accordance with the contractor responsibility program 21 established under section 327(b) (relating to Office of the 22 Budget). The unreasonable failure of a bidder or offeror to 23 promptly supply information in connection with an inquiry with 24 respect to responsibility may be grounds for a determination of 25 nonresponsibility with respect to that bidder or offeror. 26 (b) Right of nondisclosure.--Information furnished by a 27 bidder or offeror under this section shall not be disclosed 28 outside of the purchasing agency without prior written consent 29 by the bidder or offeror except as otherwise provided in section 30 563 (relating to retention of procurement records). 19970S0005B0228 - 45 -
1 § 534. Security and performance bonds. 2 (a) Contract for supplies.-- 3 (1) In the case of competitive sealed bidding or 4 competitive sealed proposals for a contract for supplies or 5 services, bidders or offerors may be required by the 6 contracting officer to provide bid or proposal security. Bid 7 or proposal security shall be in the form of a certified or 8 bank check or a bond provided by a surety company authorized 9 to do business in this Commonwealth or another form of 10 security as specified in the invitation for bids or request 11 for proposals. Bid or proposal security shall be at least in 12 the minimum amount or percentage of the amount of the bid as 13 shall be specified in the advertisement, invitation for bids 14 or request for proposals. 15 (2) When the invitation for bids or the request for 16 proposals requires security, noncompliance by the bidder or 17 offeror with the instructions in the invitation for bids or 18 request for proposals requires that the bid or proposal be 19 rejected unless it is determined that the bid or proposal 20 fails to comply with the security requirements in a 21 nonsubstantial manner. 22 (3) After the bids are opened, they shall be irrevocable 23 for the period specified in the invitation for bids or the 24 request for proposals except as provided in section 512(f) 25 (relating to competitive sealed bidding). If a bidder or 26 offeror is permitted to withdraw its bid before award, no 27 action shall be had against the bidder or offeror or against 28 the bid or proposal security. 29 (4) A contractor may be required by the contracting 30 officer to provide a performance bond executed by a surety 19970S0005B0228 - 46 -
1 company authorized to do business in this Commonwealth. In 2 lieu of a bond, a contractor may provide other security as 3 permitted by the head of the purchasing agency. The 4 performance bond shall be in an amount determined by the head 5 of the purchasing agency, and it shall be conditioned upon 6 the faithful performance of the contract. 7 (b) Contract for construction.--Bid security and performance 8 bonds as required for contracts for construction are provided 9 for in sections 902 (relating to bid or proposal security) and 10 903 (relating to contract performance and payment bonds). 11 § 535. Cost or pricing data. 12 (a) Submission by contractor.--A contractor shall, except as 13 provided in subsection (c), submit cost or pricing data and 14 shall certify that, to the best of its knowledge and belief, the 15 cost or pricing data submitted was accurate, complete and 16 current as of a mutually determined specified date prior to the 17 date of: 18 (1) the pricing of any contract awarded under section 19 513 (relating to competitive sealed proposals) or 515 20 (relating to sole source procurement) where the total 21 contract price is expected to exceed an amount established by 22 the head of the purchasing agency; or 23 (2) the pricing of any change order or contract 24 modification which is expected to exceed an amount 25 established by the head of the purchasing agency. 26 (b) Price adjustment.--Any contract, change order or 27 contract modification under which a certificate is required 28 shall contain a provision that the price to the purchasing 29 agency, including profit or fee, shall be adjusted to exclude 30 any significant sums by which the purchasing agency finds that 19970S0005B0228 - 47 -
1 the price was increased because the cost or pricing data 2 furnished by the contractor was inaccurate, incomplete or not 3 current as of the date agreed upon between the parties. 4 (c) Cost or pricing data not required.--The requirements of 5 this section need not be applied to contracts under any of the 6 following circumstances: 7 (1) The contract price is based on adequate price 8 competition. 9 (2) The contract price is based on established catalog 10 prices or market prices. 11 (3) Contract prices are set by statute or regulation. 12 (4) It is determined in writing by the contracting 13 officer that the requirements of this section may be waived 14 and the reasons for the waivers are stated in writing. 15 SUBCHAPTER E 16 TYPES OF CONTRACTS 17 Sec. 18 541. Approval of accounting system. 19 542. Multiterm contracts. 20 543. Effective contracts. 21 § 541. Approval of accounting system. 22 Except with respect to firm fixed-price contracts, no 23 contract type shall be used unless it has been determined in 24 writing by the head of a purchasing agency that: 25 (1) The proposed contractor's accounting system will 26 permit timely development of all necessary cost data in the 27 form required by the specific contract type contemplated. 28 (2) The proposed contractor's accounting system is 29 adequate to allocate costs in accordance with generally 30 accepted accounting principles. 19970S0005B0228 - 48 -
1 § 542. Multiterm contracts. 2 (a) Specified period.--A contract for supplies, construction 3 or services may be entered into for a period of time deemed to 4 be in the best interests of the Commonwealth. The term of the 5 contract and conditions of renewal or extension, if any, shall 6 be included in the solicitation, and funds shall be available 7 for the first fiscal period at the time of contracting. Payment 8 and performance obligations for succeeding fiscal periods shall 9 be subject to the availability and appropriation of funds. 10 (b) Cancellation for unavailability of funds in succeeding 11 fiscal periods.--When funds are not appropriated or otherwise 12 made available to support continuation of performance in a 13 subsequent fiscal period, the contract shall be canceled, and 14 the contractor shall be reimbursed for the reasonable value of 15 any nonrecurring costs incurred but not amortized in the price 16 of the supplies or services delivered under the contract. The 17 cost of cancellation may be paid from any appropriations 18 available for that purpose. 19 § 543. Effective contracts. 20 Irrespective of the type of contract, no contract shall be 21 effective until executed by all necessary Commonwealth officials 22 as provided by law. 23 SUBCHAPTER F 24 INSPECTION OF PLANT AND AUDIT OF RECORDS 25 Sec. 26 551. Right to inspect plant. 27 552. Right to audit records. 28 § 551. Right to inspect plant. 29 The purchasing agency may, at reasonable times, inspect the 30 part of the plant or place of business of a contractor or any 19970S0005B0228 - 49 -
1 subcontractor which is related to the performance of any 2 contract awarded or to be awarded by the purchasing agency. 3 § 552. Right to audit records. 4 (a) Audit of cost or pricing data.--The purchasing agency or 5 its designee may, at reasonable times and places, audit the 6 books and records of any person who has submitted cost or 7 pricing data under section 535 (relating to cost or pricing 8 data) to the extent that the books and records relate to the 9 cost or pricing data. A person who receives a contract, change 10 order or contract modification for which cost or pricing data is 11 required shall maintain the books and records that relate to the 12 cost or pricing data for three years from the date of final 13 payment under the contract unless a shorter period is otherwise 14 authorized in writing. 15 (b) Contract audit.--The purchasing agency may audit the 16 books and records of a contractor or any subcontractor under any 17 negotiated contract or subcontract other than a firm fixed-price 18 contract to the extent that the books and records relate to the 19 performance of the contract or subcontract. The books and 20 records shall be maintained by the contractor for a period of 21 three years from the date of final payment under the prime 22 contract and by the subcontractor for a period of three years 23 from the date of final payment under the prime contract unless a 24 shorter period is otherwise authorized in writing. 25 SUBCHAPTER G 26 DETERMINATIONS AND REPORTS 27 Sec. 28 561. Finality of determinations. 29 562. Anticompetitive practices. 30 563. Retention of procurement records. 19970S0005B0228 - 50 -
1 564. Record of certain actions. 2 § 561. Finality of determinations. 3 The determinations required by the following sections are 4 final and conclusive unless they are clearly erroneous, 5 arbitrary, capricious or contrary to law: 6 Section 512(f) (relating to competitive sealed bidding). 7 Section 513(a) and (g) (relating to competitive sealed 8 proposals). 9 Section 515 (relating to sole source procurement). 10 Section 516 (relating to emergency procurement). 11 Section 518(e) (relating to competitive selection 12 procedures for certain services). 13 Section 519(f) (relating to selection procedure for 14 insurance and bonds). 15 Section 533(a) (relating to responsibility of bidders and 16 offerors). 17 Section 535(c) (relating to cost or pricing data). 18 Section 541 (relating to approval of accounting system). 19 § 562. Anticompetitive practices. 20 Collusion among bidders is unlawful. Every contract, 21 combination or conspiracy which unreasonably restrains trade 22 among bidders or offerors is unlawful. Contracts so arrived at 23 may be declared void at the option of the Commonwealth. In 24 addition to remedies available to the Commonwealth in the 25 Federal courts, there shall be the same remedies in the courts 26 of this Commonwealth. When any person has reason to believe 27 collusion or other anticompetitive practices have occurred among 28 any bidders or offerors, a notice of the relevant facts shall be 29 transmitted to the Attorney General who shall investigate the 30 reports. 19970S0005B0228 - 51 -
1 § 563. Retention of procurement records. 2 All procurement records shall be retained for a minimum of 3 three years from the date of final payment under the contract 4 and disposed of in accordance with records retention guidelines 5 and schedules as provided by law. All retained documents shall 6 be made available to the State Treasurer, Auditor General, 7 General Counsel and Attorney General upon request. 8 § 564. Record of certain actions. 9 The purchasing agency shall maintain a record listing all 10 contracts made under sections 514 (relating to small purchases), 11 515 (relating to sole source procurement) and 516 (relating to 12 emergency procurement) for a minimum of three years from the 13 date of final payment under the contract. The record shall 14 contain: 15 (1) Each contractor's name. 16 (2) The amount and type of each contract. 17 (3) A listing of the supplies, services or construction 18 procured under each contract. 19 CHAPTER 7 20 (Reserved) 21 CHAPTER 9 22 PROCUREMENT OF CONSTRUCTION, ARCHITECT AND 23 ENGINEER SERVICES 24 Sec. 25 901. Definitions. 26 902. Bid or proposal security. 27 903. Contract performance and payment bonds. 28 904. Copies of bonds. 29 905. Procurement of design professional services. 30 § 901. Definitions. 19970S0005B0228 - 52 -
1 The following words and phrases when used in this chapter 2 shall have the meanings given to them in this section unless the 3 context clearly indicates otherwise: 4 "Design professional services." Those professional services 5 within the scope of the practice of architecture, engineering, 6 landscape architecture or land surveying, including studies, 7 investigations, surveying, mapping, tests, evaluations, 8 consultations, comprehensive planning, program management, 9 conceptual design, plans and specifications, value engineering, 10 maintenance manuals and other related services associated with 11 research, planning, development, design, construction, 12 alteration or repair of real property. 13 § 902. Bid or proposal security. 14 (a) Requirement for bid security.--Bidders or offerors may 15 be required to provide bid or proposal security for construction 16 contracts. Bid or proposal security shall be in the form of a 17 certified or bank check or a bond provided by a surety company 18 authorized to do business in this Commonwealth or another form 19 of security as specified in the invitation for bids or request 20 for proposals. 21 (b) Amount of bid or proposal security.--Bid security shall 22 be at least in the minimum amount or percentage of the amount of 23 the bid as shall be specified in the advertisement, the 24 invitation for bids or the request for proposals. 25 (c) Rejection of bids or proposals.--When the invitation for 26 bids or the request for proposals requires security, 27 noncompliance with the instructions in the invitation for bids 28 or the request for proposals requires that the bid or proposal 29 be rejected unless it is determined that the bid fails to comply 30 with the security requirements in a nonsubstantial manner. 19970S0005B0228 - 53 -
1 (d) Withdrawal of bids.--After the bids are opened, they 2 shall be irrevocable for the period specified in the invitation 3 for bids except as provided in section 512(f) (relating to 4 competitive sealed bidding). If a bidder is permitted to 5 withdraw its bid before award, no action shall be had against 6 the bidder or the bid security. 7 § 903. Contract performance and payment bonds. 8 (a) When required and amounts.--When a construction contract 9 is awarded in excess of $250,000, the following bonds or 10 security shall be delivered to the purchasing agency and shall 11 be binding on the parties upon the execution of the contract: 12 (1) A performance bond, executed by a surety company 13 authorized to do business in this Commonwealth and made 14 payable to the Commonwealth, in an amount equal to 100% of 15 the price specified in the contract and conditioned upon the 16 faithful performance of the contract in accordance with the 17 plans, specifications and conditions of the contract. 18 (2) A payment bond, executed by a surety company 19 authorized to do business in this Commonwealth and made 20 payable to the Commonwealth, in an amount equal to 100% of 21 the price specified in the contract and conditioned upon the 22 prompt payment for all materials furnished or labor supplied 23 or performed in the prosecution of the work. Labor or 24 materials include public utility services and reasonable 25 rentals of equipment for the periods when the equipment is 26 actually used at the site. 27 (b) Protection.--A performance bond shall be solely for the 28 protection of the purchasing agency which awarded the contract. 29 A payment bond shall be solely for the protection of claimants 30 supplying labor or materials to the prime contractor to whom the 19970S0005B0228 - 54 -
1 contract was awarded or to any of its subcontractors in the 2 prosecution of the work provided for in the contract, whether or 3 not the labor or materials constitute a component part of the 4 construction. 5 (c) Authority to require additional bonds.--Nothing in this 6 section shall be construed to limit the authority of the 7 Commonwealth agency to require a performance bond or other 8 security in addition to those bonds or in circumstances other 9 than specified in subsection (a). 10 (d) Actions on payment bonds.-- 11 (1) Subject to paragraph (2), any claimant who has 12 performed labor or furnished material in the prosecution of 13 the work provided for in any contract for which a payment 14 bond has been given under subsection (a) and who has not been 15 paid in full before the expiration of 90 days after the day 16 on which the claimant performed the last of the labor or 17 furnished the last of the materials for which it claims 18 payments may bring an action on the payment bond in its own 19 name, in assumpsit, to recover any amount due it for the 20 labor or material and may prosecute the action to final 21 judgment and have execution on the judgment. 22 (2) Any claimant who has a direct contractual 23 relationship with any subcontractor of the prime contractor 24 who gave the payment bond but has no contractual 25 relationship, express or implied, with the prime contractor 26 may bring an action on the payment bond only if it has given 27 written notice to the contractor within 90 days from the date 28 on which the claimant performed the last of the labor or 29 furnished the last of the materials for which it claims 30 payment, stating with substantial accuracy the amount and the 19970S0005B0228 - 55 -
1 name of the person for whom the work was performed or to whom 2 the material was furnished. 3 (3) Notice shall be served by registered mail in an 4 envelope addressed to the contractor at any place where its 5 office is regularly maintained for the transaction of 6 business or served in any manner in which legal process may 7 be served in the manner provided by law for the service of a 8 summons except that the service need not be made by a public 9 officer. 10 (e) Adjustment of threshold amount.--The dollar threshold of 11 $250,000 set forth in subsection (a) shall be adjusted annually 12 by the department to reflect the annual percentage change in the 13 Composition Construction Cost Index of the United States 14 Department of Commerce occurring in the one-year period ending 15 on December 31 of each year. 16 § 904. Copies of bonds. 17 (a) Copies of bonds.--The purchasing agency shall furnish a 18 copy of any payment bond and the contract for which the bond was 19 given to any person who makes an application for the copy. 20 (b) Fee for copies.--Each applicant shall pay for each copy 21 of any payment bond a fee fixed by the purchasing agency to 22 cover the actual cost of the preparation of the copy. 23 (c) Evidence.--A copy of any payment bond and of the 24 contract for which the bond was given constitutes prima facie 25 evidence of the contents, execution and delivery of the original 26 of the bond and contract. 27 § 905. Procurement of design professional services. 28 (a) Applicability.--Design professional services shall be 29 procured as provided in this section except as authorized by 30 sections 514 (relating to small purchases), 515 (relating to 19970S0005B0228 - 56 -
1 sole source procurement) and 516 (relating to emergency 2 procurement). 3 (b) Policy.--It is the policy of this Commonwealth to 4 publicly announce all requirements for design professional 5 services and to award contracts for design professional services 6 on the basis of demonstrated competence and qualification for 7 the types of services required. There shall be a committee to 8 review the qualifications, experience and work of design 9 professionals seeking contracts with purchasing agencies. 10 (c) Selection committees for the Departments of 11 Transportation and Environmental Protection.--The Department of 12 Transportation and the Department of Environmental Protection 13 shall each establish a selection committee and procedure. The 14 procedure to procure design professional services shall be 15 similar to and consistent with the procedure provided for in 16 subsection (e). None of the members of these committees shall 17 hold any elective office or office in any political party. 18 (d) Selection committee for all other Commonwealth 19 agencies.--Except as provided for in subsection (c), all 20 purchasing agencies shall use the selection committee appointed 21 by the Governor which shall be composed of five members, none of 22 whom shall be employees or hold any elective office or office in 23 any political party. The members shall be architects, engineers 24 or other persons knowledgeable in construction. The members 25 shall serve for terms of two years and shall not be removed 26 except for cause. Of the original members three shall serve for 27 terms of two years and two for terms of one year. Thereafter all 28 terms shall be for two years. Each member shall be reimbursed 29 for reasonable travel and other expenses incurred incident to 30 attendance at meetings and to assigned duties and also a per 19970S0005B0228 - 57 -
1 diem allowance in accordance with Commonwealth travel policies. 2 (e) Procedure for selection committee.--The selection 3 committee established under subsection (d) shall use the 4 procedure set forth in this subsection: 5 (1) The committee shall give public notice of projects 6 requiring design services and publicly recommend to the 7 purchasing agency three qualified design professionals for 8 each project. 9 (2) If desired, the committee may conduct discussions 10 with three or more professionals regarding anticipated design 11 concepts and proposed methods of approach to the assignment. 12 The committee shall select, based upon criteria established 13 by the head of the purchasing agency, no less than three 14 design professionals deemed to be the most highly qualified 15 to provide the services required. In exercising its 16 responsibility, the committee shall consider the following 17 factors: 18 (i) An equitable distribution of contracts to design 19 professionals. 20 (ii) Particular capability to perform the design or 21 construction services for the contract being considered. 22 (iii) Geographic proximity of the design 23 professional to the proposed facility. 24 (iv) The design professional selected has the 25 necessary available personnel to perform the services 26 required by the project. 27 (v) Any other relevant circumstances peculiar to the 28 proposed contract. 29 The fee to be paid to the selected design professional shall 30 be established by the selections committee. 19970S0005B0228 - 58 -
1 (3) Of the three firms selected by the committee, the 2 head of the purchasing agency shall negotiate a contract with 3 the firm he determines to be the highest qualified firm for 4 the design professional services at compensation which he 5 determines to be fair and reasonable to the Commonwealth. In 6 making this decision the head of the purchasing agency shall 7 take into account the estimated value, scope, complexity and 8 professional nature of the services to be rendered. Should 9 the head of the purchasing agency be unable to negotiate a 10 satisfactory contract with the firm considered to be the most 11 qualified at a fee he determines to be fair and reasonable to 12 the Commonwealth, negotiations with that firm shall be 13 formally terminated. The head of the purchasing agency shall 14 then undertake negotiations with the firm he determines to be 15 the second highest qualified firm. Failing accord with the 16 second most qualified firm, the head of the purchasing agency 17 shall formally terminate negotiations and then undertake 18 negotiations with the third highest qualified firm. Should 19 the head of the purchasing agency be unable to negotiate a 20 satisfactory contract with any of the selected firms, the 21 committee shall select additional qualified firms, and the 22 head of the purchasing agency shall continue negotiations in 23 accordance with this section until an agreement is reached. 24 CHAPTER 11 25 (RESERVED) 26 CHAPTER 13 27 (Reserved) 28 CHAPTER 15 29 SUPPLY MANAGEMENT 30 Sec. 19970S0005B0228 - 59 -
1 1501. Definitions. 2 1502. Supply management regulations. 3 1503. Proceeds from sale or disposal of surplus supplies. 4 § 1501. Definitions. 5 The following words and phrases when used in this chapter 6 shall have the meanings given to them in this section unless the 7 context clearly indicates otherwise: 8 "Excess supplies." All supplies other than expendable 9 supplies having a remaining useful life but which are no longer 10 required by the using agency in possession of the supplies. 11 "Expendable supplies." All tangible supplies other than 12 nonexpendable supplies. 13 "Nonexpendable supplies." All tangible supplies having an 14 original acquisition cost of over $100 per unit and a probable 15 useful life of more than one year. 16 "Supplies." Supplies owned by Commonwealth agencies. 17 "Surplus supplies." Supplies other than expendable supplies 18 no longer having any use to any Commonwealth agency. The term 19 includes obsolete supplies, scrap materials and nonexpendable 20 supplies that have completed their useful life cycle. 21 § 1502. Supply management regulations. 22 The department shall establish policy and may promulgate 23 regulations governing: 24 (1) The management of supplies during their entire life 25 cycle. 26 (2) The sale, lease or disposal of surplus supplies by 27 public auction, competitive sealed bidding or other 28 appropriate method designated by the department. However, no 29 employee of the owning or disposing agency shall be entitled 30 to purchase any of these supplies except when the sale price 19970S0005B0228 - 60 -
1 of the surplus supply is less than the amount established by 2 the department for permissible purchases by such employees. 3 (3) Transfer of excess supplies. 4 § 1503. Proceeds from sale or disposal of surplus supplies. 5 The proceeds from the sale, lease or disposal of surplus 6 supplies shall be paid into the State Treasury and deposited in 7 the fund out of which the supplies sold was originally purchased 8 by the appropriate credit to the then-current appropriation. The 9 costs incurred by the department in advertising or selling the 10 supplies shall be deducted from the purchase price, and that 11 amount shall be an executively authorized augmentation to the 12 appropriation from which the costs were paid by the department. 13 CHAPTER 17 14 LEGAL AND CONTRACTUAL REMEDIES 15 Subchapter 16 A. General Provisions 17 B. Prelitigation Resolution of Controversies 18 C. Board of Claims 19 D. Solicitations or Awards in Violation of Law 20 E. Interest 21 SUBCHAPTER A 22 GENERAL PROVISIONS 23 Sec. 24 1701. Definitions. 25 1702. Sovereign immunity. 26 § 1701. Definitions. 27 The following words and phrases when used in this chapter 28 shall have the meanings given to them in this section unless the 29 context clearly indicates otherwise: 30 "Claimant." A person filing a claim with the Board of 19970S0005B0228 - 61 -
1 Claims. 2 § 1702. Sovereign immunity. 3 (a) General rule.--The General Assembly under section 11 of 4 Article I of the Constitution of Pennsylvania reaffirms 5 sovereign immunity, and, except as otherwise provided in this 6 chapter, no provision of this part shall constitute a waiver of 7 sovereign immunity for the purpose of 1 Pa.C.S. § 2310 (relating 8 to sovereign immunity reaffirmed; specific waiver) or otherwise. 9 (b) Exception.--The General Assembly under section 11 of 10 Article I of the Constitution of Pennsylvania does hereby waive 11 sovereign immunity as a bar to claims against Commonwealth 12 agencies arising under this chapter but only to the extent set 13 forth in this chapter. 14 SUBCHAPTER B 15 PRELITIGATION RESOLUTION OF CONTROVERSIES 16 Sec. 17 1711. Authority to resolve protests of solicitations or 18 awards. 19 1712. Authority to resolve contract and breach of contract 20 controversies. 21 § 1711. Authority to resolve protests of solicitations or 22 awards. 23 (a) Right to protest.--An actual or prospective bidder, 24 offeror or contractor who is aggrieved in connection with the 25 solicitation or award of a contract may protest to the head of a 26 purchasing agency in writing. All protests under this subsection 27 must be made within seven days after the protestant knows or 28 should have known of the facts giving rise to the protest. If a 29 protest is submitted by a protestant who did not submit a bid, 30 the protest must be received by the purchasing agency prior to 19970S0005B0228 - 62 -
1 the bid opening time or the proposal receipt date or it shall be 2 considered untimely and can be disregarded by the purchasing 3 agency. 4 (b) Authority to resolve protests.--The head of a purchasing 5 agency shall have the authority to settle and resolve a protest 6 of an aggrieved bidder, offeror or contractor, actual or 7 prospective, concerning the solicitation or award of a contract. 8 (c) Decision.--If the protest is not resolved by mutual 9 agreement, the head of a purchasing agency shall promptly issue 10 a decision in writing. The decision shall: 11 (1) State the reasons for the action taken. 12 (2) Inform the protestant of his right to file an action 13 in Commonwealth Court as provided in subsection (e). 14 (d) Notice of decision.--A copy of the decision under 15 subsection (c) shall be delivered by registered mail to the 16 protestant and any other person determined by the head of the 17 purchasing agency to be affected by the decision. 18 (e) Finality of decision.--A decision under subsection (c) 19 shall be final and conclusive unless a person adversely affected 20 by the decision files an action based on subsection (a) in 21 Commonwealth Court within 14 days of receipt of the decision. No 22 action may be commenced in Commonwealth Court under this 23 subsection until the protestant has exhausted the administrative 24 remedies provided for in this section. 25 (f) Stay of procurements during protests.--In the event of a 26 timely protest under subsection (a) and until the time has 27 elapsed for the protestant to file an action in Commonwealth 28 Court, the purchasing agency shall not proceed further with the 29 solicitation or with the award of the contract unless and until 30 the head of the purchasing agency, after consultation with the 19970S0005B0228 - 63 -
1 head of the using agency, makes a written determination that the 2 protest is clearly without merit or that award of the contract 3 without delay is necessary to protect substantial interests of 4 the Commonwealth. 5 § 1712. Authority to resolve contract and breach of contract 6 controversies. 7 (a) Applicability.--This section applies to controversies 8 between a Commonwealth agency and a contractor which arise under 9 or by virtue of a contract between them, including controversies 10 based upon breach of contract, mistake, misrepresentation or 11 other cause for contract modification or rescission. Prior to 12 filing a claim under this section with the Board of Claims under 13 the exclusive jurisdiction provided in the act of May 20, 1937 14 (P.L.728, No.193), referred to as the Board of Claims Act, the 15 claim must first be filed in writing with the contracting 16 officer within six months after it accrues and not thereafter. 17 (b) Authority.--The contracting officer is authorized to 18 settle and resolve a controversy described in subsection (a). 19 (c) Decision.--If the controversy is not resolved by mutual 20 agreement, the head of a purchasing agency shall promptly issue 21 a decision in writing. The decision shall: 22 (1) State the reasons for the action taken. 23 (2) Inform the contractor of its right to administrative 24 and judicial review as provided in this chapter. 25 (d) Notice of decision.--A copy of the decision under 26 subsection (c) shall be delivered by registered mail to the 27 contractor. 28 (e) Finality of decision.--The decision under subsection (c) 29 shall be final and conclusive unless the contractor files a 30 claim with the Board of Claims within 30 days of receipt of the 19970S0005B0228 - 64 -
1 decision. 2 (f) Failure to render timely decision.--If the contracting 3 officer does not issue the written decision required under 4 subsection (c) within 120 days after written request for a final 5 decision or within a longer period as may be agreed upon by the 6 parties, then the contractor may proceed as if an adverse 7 decision had been received. 8 SUBCHAPTER C 9 BOARD OF CLAIMS 10 Sec. 11 1721. Function of Board of Claims. 12 1722. (Reserved). 13 1723. (Reserved). 14 1724. (Reserved). 15 1725. Hearings, decisions and awards. 16 1726. Appeals. 17 § 1721. Function of Board of Claims. 18 The Board of Claims created under the act of May 20, 1937 19 (P.L.728, No.193), referred to as the Board of Claims Act, shall 20 be constituted and administered as provided in that act. 21 § 1722. (Reserved). 22 § 1723. (Reserved). 23 § 1724. (Reserved). 24 § 1725. Hearings, decisions and awards. 25 (a) General rule.--All hearings before the Board of Claims 26 under this part shall be in accordance with the procedure set 27 forth in the act of May 20, 1937 (P.L.728, No.193), referred to 28 as the Board of Claims Act. 29 (b) Hearing and decision.--All hearings before the Board of 30 Claims or hearings before a hearing panel shall be public and 19970S0005B0228 - 65 -
1 the proceedings shall be de novo. Any prior determinations by 2 administrative officials shall not be final or conclusive except 3 as provided in section 561 (relating to finality of 4 determinations). The board or hearing panel shall make a 5 decision within a reasonable time from the date of the hearing. 6 The board shall promptly decide the contract or breach of 7 contract controversy and, if appropriate, make an award of a sum 8 that it determines the claimant is entitled to receive. 9 (c) Certification of award.--The Board of Claims shall 10 certify an award for the purpose of entering the same as a 11 judgment in any court of record. 12 (d) Public records.--All papers filed under this subchapter 13 shall be a public record to the extent provided in the act of 14 June 21, 1957 (P.L.390, No.212), referred to as the Right-to- 15 Know Law, and shall be available to the public as provided in 16 that act. 17 § 1726. Appeals. 18 Any person, including a Commonwealth agency, aggrieved by a 19 decision of the Board of Claims may appeal to the Commonwealth 20 Court under 42 Pa.C.S. § 763(a)(1) (relating to direct appeals 21 from government agencies) within 30 days after certification of 22 the decision. 23 SUBCHAPTER D 24 SOLICITATIONS OR AWARDS IN VIOLATION OF LAW 25 Sec. 26 1741. Applicability. 27 1742. Remedies prior to award. 28 1743. Remedies after award. 29 § 1741. Applicability. 30 The provisions of this subchapter apply where it is 19970S0005B0228 - 66 -
1 determined by the contracting officer or the court that a 2 solicitation or award of a contract is in violation of law. 3 § 1742. Remedies prior to award. 4 If prior to award it is determined that a solicitation or 5 proposed award of a contract is in violation of law, then the 6 remedies are limited to cancellation of the solicitation or 7 proposed award or revision of the solicitation or proposed award 8 to comply with the law. 9 § 1743. Remedies after award. 10 If after an award it is determined that a solicitation or 11 award of a contract is in violation of law, then: 12 (1) If the person awarded the contract has not acted 13 fraudulently or in bad faith: 14 (i) the contract may be ratified and affirmed 15 provided it is determined that doing so is in the best 16 interest of the Commonwealth; or 17 (ii) the contract may be terminated and the person 18 awarded the contract shall be compensated for the actual 19 expenses reasonably incurred under the contract prior to 20 the termination. 21 (2) If the person awarded the contract has acted 22 fraudulently or in bad faith: 23 (i) the contract may be declared void; or 24 (ii) the contract may be ratified and affirmed if 25 that action is in the best interests of the Commonwealth 26 and without prejudice to the right of the Commonwealth 27 agency to damages as may be appropriate. 28 SUBCHAPTER E 29 INTEREST 30 Sec. 19970S0005B0228 - 67 -
1 1751. Interest. 2 § 1751. Interest. 3 Interest on amounts ultimately determined to be due shall be 4 payable at the statutory rate applicable to judgments from the 5 date the claim was filed with the contracting officer. Interest 6 on claims arising out of the provisions of section 1507 of the 7 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 8 Code, shall be payable as provided therein. 9 CHAPTER 19 10 INTERGOVERNMENTAL RELATIONS 11 Sec. 12 1901. Definitions. 13 1902. Cooperative purchasing authorized. 14 1903. Sale, acquisition or use of supplies by a public 15 procurement unit. 16 1904. Cooperative use of supplies or services. 17 1905. Joint use of facilities. 18 1906. Supply of personnel, information and technical services. 19 1907. Use of payments received by a supplying public 20 procurement unit. 21 1908. Compliance of public procurement units. 22 1909. Review of procurement requirements. 23 1910. Contract controversies. 24 § 1901. Definitions. 25 The following words and phrases when used in this chapter 26 shall have the meanings given to them in this section unless the 27 context clearly indicates otherwise: 28 "Cooperative purchasing." Procurement conducted by or on 29 behalf of more than one public procurement unit or by a public 30 procurement unit with an external procurement activity. 19970S0005B0228 - 68 -
1 "External procurement activity." A buying organization not 2 located in this Commonwealth which if located in this 3 Commonwealth would qualify as a public procurement unit. An 4 agency of the United States is an external procurement activity. 5 "Local public procurement unit." A political subdivision, 6 public authority, educational, health or other institution and, 7 to the extent provided by law, any other entity, including a 8 council of governments or an area government, which expends 9 public funds for the procurement of supplies, services and 10 construction, any nonprofit corporation operating a charitable 11 hospital and any nonprofit fire company, nonprofit rescue 12 company and nonprofit ambulance company. 13 "Public procurement unit." A local public procurement unit 14 or a purchasing agency. 15 § 1902. Cooperative purchasing authorized. 16 A public procurement unit may either participate in, sponsor, 17 conduct or administer a cooperative purchasing agreement for the 18 procurement of any supplies, services or construction with one 19 or more public procurement units or external procurement 20 activities in accordance with an agreement entered into between 21 the participants. Cooperative purchasing may include, but is not 22 limited to, joint or multiparty contracts between public 23 procurement units and open-ended purchasing agency contracts 24 which are made available to local public procurement units. 25 § 1903. Sale, acquisition or use of supplies by a public 26 procurement unit. 27 A public procurement unit may sell to, acquire from or use 28 any supplies belonging to another public procurement unit or 29 external procurement activity independent of the requirements of 30 Chapters 5 (relating to source selection and contract formation) 19970S0005B0228 - 69 -
1 and 15 (relating to supply management). 2 § 1904. Cooperative use of supplies or services. 3 A public procurement unit may enter into an agreement, 4 independent of the requirements of Chapters 5 (relating to 5 source selection and contract formation) and 15 (relating to 6 supply management), with any other public procurement unit or 7 external procurement activity for the cooperative use of 8 supplies or services under the terms agreed upon between the 9 parties. 10 § 1905. Joint use of facilities. 11 Any public procurement unit may enter into agreements for the 12 common use or lease of warehousing facilities, capital equipment 13 and other facilities with another public procurement unit or an 14 external procurement activity under the terms agreed upon 15 between the parties. 16 § 1906. Supply of personnel, information and technical 17 services. 18 (a) Supply of personnel.--Upon written request from another 19 public procurement unit or external procurement activity, a 20 public procurement unit may provide personnel to the requesting 21 public procurement unit or external procurement activity. The 22 public procurement unit or external procurement activity making 23 the request shall pay the public procurement unit providing the 24 personnel the direct and indirect cost of furnishing the 25 personnel in accordance with an agreement between the parties. 26 (b) Supply of services.--The informational, technical and 27 other services of any public procurement unit may be made 28 available to any other public procurement unit or external 29 procurement activity. However, the requirements of the public 30 procurement unit tendering the services shall have precedence 19970S0005B0228 - 70 -
1 over the requesting public procurement unit or external 2 procurement activity. The requesting public procurement unit or 3 external procurement activity shall pay for the expenses of the 4 services provided in accordance with an agreement between the 5 parties. 6 (c) Information services.--Upon request, the department may 7 make available to public procurement units or external 8 procurement activities the following services, among others: 9 (1) Standard forms. 10 (2) Printed manuals. 11 (3) Product specifications and standards. 12 (4) Quality assurance testing services and methods. 13 (5) Qualified products lists. 14 (6) Source information. 15 (7) Common use commodities listings. 16 (8) Supplier prequalification information. 17 (9) Supplier performance ratings. 18 (10) Debarred and suspended bidders lists. 19 (11) Forms for invitations for bids, requests for 20 proposals, instructions to bidders, general contract 21 provisions and other contract forms. 22 (12) Contracts or published summaries of contracts, 23 including price and time of delivery information. 24 (d) Technical services.--The department may provide the 25 following technical services, among others: 26 (1) Development of products specifications. 27 (2) Development of quality assurance test methods, 28 including receiving, inspection and acceptance procedures. 29 (3) Use of product testing and inspection facilities. 30 (4) Use of personnel training programs. 19970S0005B0228 - 71 -
1 (e) Fees.--The department may enter into contractual 2 arrangements and publish a schedule of fees for the services 3 provided under subsections (c) and (d). 4 § 1907. Use of payments received by a supplying public 5 procurement unit. 6 All payments from any public procurement unit or external 7 procurement activity received by a public procurement unit 8 supplying personnel or services shall be available to the 9 supplying public procurement unit. 10 § 1908. Compliance of public procurement units. 11 Where the public procurement unit or external procurement 12 activity administering a cooperative purchase complies with the 13 requirements of this part, any public procurement unit 14 participating in the purchase shall be deemed to have complied 15 with this part. Public procurement units may not enter into a 16 cooperative purchasing agreement for the purpose of 17 circumventing this part. 18 § 1909. Review of procurement requirements. 19 To the extent possible, the department may collect 20 information concerning the type, cost, quality and quantity of 21 commonly used supplies, services or construction being procured 22 or used by Commonwealth agencies. The department may also 23 collect this information from local procurement units. The 24 department may make this information available to any public 25 procurement unit upon request. 26 § 1910. Contract controversies. 27 (a) Public procurement unit subject to certain legal and 28 contractual remedies.--Under a cooperative purchasing agreement, 29 controversies arising between an administering public 30 procurement unit subject to Chapter 17 (relating to legal and 19970S0005B0228 - 72 -
1 contractual remedies) and its bidders, offerors or contractors 2 shall be resolved in accordance with Chapter 17. 3 (b) Local public procurement unit not subject to certain 4 legal and contractual remedies.--Any local public procurement 5 unit which is not subject to Chapter 17 is authorized to: 6 (1) Enter into an agreement with the Board of Claims to 7 use the board to resolve controversies between the local 8 public procurement unit and its contractors, whether or not 9 the controversy arose from a cooperative purchasing 10 agreement. 11 (2) Enter into an agreement with another local public 12 procurement unit or external procurement activity to 13 establish procedures or use existing procedures of the unit 14 or activity to resolve controversies with contractors, 15 whether or not the controversy arose under a cooperative 16 purchasing agreement. 17 CHAPTER 21 18 SMALL AND DISADVANTAGED BUSINESSES 19 Sec. 20 2101. Policy. 21 2102. Definitions. 22 2103. Regulations. 23 2104. Duties of department. 24 2105. Bonding and progress payments. 25 2106. Business assistance offices. 26 2107. Report to General Assembly. 27 2108. Compliance with Federal requirements. 28 § 2101. Policy. 29 The policy of this Commonwealth is to assist small and 30 disadvantaged businesses in learning how to do business with 19970S0005B0228 - 73 -
1 Commonwealth agencies. The department shall implement this 2 policy in accordance with regulations promulgated by the 3 department. 4 § 2102. Definitions. 5 Subject to section 2103 (relating to regulations), the 6 following words and phrases when used in this chapter shall have 7 the meanings given to them in this section unless the context 8 clearly indicates otherwise: 9 "Disadvantaged business." A small business which is owned or 10 controlled by a majority of persons, not limited to members of 11 minority groups, who have been deprived of the opportunity to 12 develop and maintain a competitive position in the economy 13 because of social disadvantages. 14 "Small business." A business in the United States which is 15 independently owned and which is not dominant in its field of 16 operation or an affiliate or subsidiary of a business dominant 17 in its field of operation. 18 § 2103. Regulations. 19 The department shall establish policy and may promulgate 20 regulations establishing detailed definitions of the words and 21 phrases defined in section 2102 (relating to definitions) using, 22 in addition to the criteria set forth in section 2102, other 23 criteria as it deems desirable, including the number of 24 employees and the dollar volume of business. 25 § 2104. Duties of department. 26 The department shall have the following duties: 27 (1) Where feasible, provide appropriate staff who shall 28 be responsible to the department and who shall serve within 29 designated Commonwealth agencies to assist small and 30 disadvantaged businesses in this Commonwealth in learning how 19970S0005B0228 - 74 -
1 to do business with Commonwealth agencies. 2 (2) Give special publicity to procurement procedures and 3 issue special publications designed to assist small and 4 disadvantaged businesses in learning how to do business with 5 Commonwealth agencies. 6 (3) Compile, maintain and make available source lists of 7 small and disadvantaged businesses for the purpose of 8 encouraging procurement from small and disadvantaged 9 businesses. 10 (4) Include small and disadvantaged businesses on 11 solicitation mailing lists. 12 (5) Assure that small and disadvantaged businesses are 13 solicited on each procurement for which the businesses may be 14 suited. 15 (6) Develop special training programs to assist small 16 and disadvantaged businesses in learning how to do business 17 with Commonwealth agencies. 18 § 2105. Bonding and progress payments. 19 (a) Bonding.--Notwithstanding other provisions of this part, 20 a purchasing agency may reduce the level or change the types of 21 bonding normally required or accept alternative forms of 22 security to the extent reasonably necessary to encourage 23 procurement from small and disadvantaged businesses. 24 (b) Progress payments.--A purchasing agency may make special 25 provisions for progress payments as it deems reasonably 26 necessary to encourage procurement from small and disadvantaged 27 businesses. 28 § 2106. Business assistance offices. 29 The department shall establish, as it deems appropriate, 30 business assistance offices throughout this Commonwealth to 19970S0005B0228 - 75 -
1 assist and carry out the provisions of this chapter. 2 § 2107. Report to General Assembly. 3 The department shall annually, before October 1, report in 4 writing to the General Assembly concerning the awarding of 5 contracts to small and disadvantaged businesses during the 6 preceding fiscal year. 7 § 2108. Compliance with Federal requirements. 8 If a procurement involves the expenditure of Federal 9 assistance or contract funds, the purchasing agency shall comply 10 with Federal law and authorized regulations which are 11 mandatorily applicable and which are not presently reflected in 12 this part. 13 CHAPTER 23 14 ETHICS IN PUBLIC CONTRACTING 15 Subchapter 16 A. General Policy and Standards 17 B. Specific Standards 18 SUBCHAPTER A 19 GENERAL POLICY AND STANDARDS 20 Sec. 21 2301. Policy. 22 2302. General standards of ethical conduct. 23 2303. Reporting of breaches of ethical standards. 24 § 2301. Policy. 25 Public employment is a public trust. It is the policy of this 26 Commonwealth to promote and balance the objective of protecting 27 government integrity and the objective of facilitating the 28 recruitment and retention of personnel needed by this 29 Commonwealth. Implementation of this policy requires that public 30 employees discharge their duties impartially so as to assure 19970S0005B0228 - 76 -
1 fair competitive access to Commonwealth agency procurement by 2 responsible contractors and that they conduct themselves in a 3 manner that fosters public confidence in the integrity of the 4 Commonwealth procurement process. It is also essential that 5 those doing business with the Commonwealth agencies observe high 6 standards of honesty and integrity. 7 § 2302. General standards of ethical conduct. 8 (a) Employees.--Any attempt to realize personal gain through 9 public employment by conduct inconsistent with the proper 10 discharge of the duties of the employee is a breach of a public 11 trust. In order to fulfill this general prescribed standard, 12 employees must avoid any conflict of interest or improper use of 13 confidential information. 14 (b) Nonemployees.--Any effort to influence any employee to 15 breach the standards of ethical conduct set forth in this 16 section is also a breach of ethical standards. 17 § 2303. Reporting of breaches of ethical standards. 18 When any person has reason to believe that any breach of 19 standards set forth in this chapter has occurred, that person 20 shall report all relevant facts to the State Ethics Commission 21 and to the Attorney General for any appropriate action. 22 SUBCHAPTER B 23 SPECIFIC STANDARDS 24 Sec. 25 2311. Bonds. 26 § 2311. Bonds. 27 It is a breach of ethical standards and unlawful for any 28 employee in issuing an invitation for bids or requests for 29 proposals to require that any bond required by this part be 30 furnished by a particular surety company or through a particular 19970S0005B0228 - 77 -
1 agent or broker. Any employee who violates this section commits 2 a misdemeanor of the first degree. 3 PART II 4 GENERAL PROCUREMENT PROVISIONS 5 Chapter 6 31. General Provisions 7 33. Prevention of Environmental Pollution 8 35. (Reserved) 9 37. Contract Clauses and Preference Provisions 10 39. Construction Contracts Over $50,000 11 41. Purchase of Surplus Federal Property 12 43. Public Facilities Concessions 13 45. Antibid-Rigging 14 CHAPTER 31 15 GENERAL PROVISIONS 16 Sec. 17 3101. Application of part. 18 3102. Definitions. 19 § 3101. Application of part. 20 This part applies to government agencies. In the case of 21 Commonwealth agencies, this part shall be read in pari materia 22 with Part I (relating to Commonwealth Procurement Code). 23 § 3102. Definitions. 24 Subject to additional definitions contained in subsequent 25 provisions of this part which are applicable to specific 26 provisions of this part, the following words and phrases when 27 used in this part shall have the meanings given to them in this 28 section unless the context clearly indicates otherwise: 29 "Commonwealth agency." A Commonwealth agency as defined in 30 section 103 (relating to definitions). 19970S0005B0228 - 78 -
1 "Government agency." Any Commonwealth agency or any 2 political subdivision or municipal or other local authority, or 3 any officer or agency of any political subdivision or local 4 authority. 5 CHAPTER 33 6 PREVENTION OF ENVIRONMENTAL POLLUTION 7 Sec. 8 3301. Invitations for bids and requests for proposals. 9 3302. Additional work. 10 § 3301. Invitations for bids and requests for proposals. 11 All invitations for bids and requests for proposals for 12 construction projects issued by any government agency shall set 13 forth any provision of Federal and State statutes, rules and 14 regulations dealing with the prevention of environmental 15 pollution and the preservation of public natural resources that 16 affect the projects. 17 § 3302. Additional work. 18 If the successful bidder or offeror must undertake additional 19 work due to the enactment of new or the amendment of existing 20 statutes, rules or regulations occurring after the submission of 21 the successful bid or proposal, the government agency shall 22 issue a change order setting forth the additional work that must 23 be undertaken, which shall not invalidate the contract. The cost 24 of a change order to the government agency shall be determined 25 in accordance with the provisions of the contract for change 26 orders or force accounts, or, if there is not a provision set 27 forth in the contract, then the cost to the government agency 28 shall be the costs to the contractor for wages, labor costs 29 other than wages, wage taxes, materials, equipment rentals, 30 insurance and subcontracts attributable to the additional 19970S0005B0228 - 79 -
1 activity plus a reasonable sum for overhead and profit. 2 Additional costs to undertake work not specified in the 3 invitation for bids or requests for proposals shall not be 4 approved unless written authorization is given the successful 5 bidder or offeror prior to its undertaking the additional 6 activity. 7 CHAPTER 35 8 (RESERVED) 9 CHAPTER 37 10 CONTRACT CLAUSES AND PREFERENCE PROVISIONS 11 Subchapter 12 A. Labor 13 B. Steel Products 14 C. Trade Practices 15 D. Motor Vehicles 16 E. Used Oil Products 17 F. Guaranteed Energy Savings Contract 18 SUBCHAPTER A 19 LABOR 20 Sec. 21 3701. Contract provisions prohibiting discrimination. 22 3702. Contract provision requiring residents to be employed. 23 § 3701. Contract provisions prohibiting discrimination. 24 Each contract entered into by a government agency for the 25 construction, alteration or repair of any public building or 26 public work shall contain the following provisions by which the 27 contractor agrees that: 28 (1) In the hiring of employees for the performance of 29 work under the contract or any subcontract, no contractor, 30 subcontractor or any person acting on behalf of the 19970S0005B0228 - 80 -
1 contractor or subcontractor shall by reason of race, creed or 2 color discriminate against any citizen of this Commonwealth 3 who is qualified and available to perform the work to which 4 the employment relates. 5 (2) No contractor or subcontractor or any person on 6 their behalf shall in any manner discriminate against or 7 intimidate any employee hired for the performance of work 8 under the contract on account of race, creed or color. 9 (3) The contract may be canceled or terminated by the 10 government agency, and all money due or to become due under 11 the contract may be forfeited for a violation of the terms or 12 conditions of that portion of the contract. 13 § 3702. Contract provision requiring residents to be employed. 14 Each contract entered into by a government agency for the 15 construction, alteration or repair of any public works shall 16 contain a provision that laborers and mechanics employed on the 17 public works shall have been residents of this Commonwealth for 18 at least 90 days prior to their employment. Failure to comply 19 with this section shall be sufficient legal reason to refuse 20 payment of the contract price to the contractor. 21 SUBCHAPTER B 22 STEEL PRODUCTS 23 Sec. 24 3711. Short title of subchapter and general provisions. 25 3712. Definitions. 26 3713. Requirement of contract provision. 27 3714. Payments under contracts. 28 § 3711. Short title of subchapter and general provisions. 29 (a) Short title.--This subchapter shall be known and may be 30 cited as the Steel Products Procurement Act. 19970S0005B0228 - 81 -
1 (b) Legislative findings.--It is hereby determined by the 2 General Assembly to reaffirm the legislative findings contained 3 in the act of March 3, 1978 (P.L.6, No.3), known as the Steel 4 Products Procurement Act, and codified in this chapter: 5 (1) This Commonwealth is one of the leading states in 6 the United States in the production of steel. 7 (2) The production of steel products constitutes a major 8 industry of this Commonwealth and, as such, provides the jobs 9 and family incomes of hundreds of thousands of the people of 10 this Commonwealth and, in turn, millions of persons in the 11 United States. 12 (3) The taxes paid to the Commonwealth and its political 13 subdivisions by employers and employees engaged in the 14 production and sale of steel products are one of the largest 15 single sources of public revenues in this Commonwealth. 16 (4) It has, for many years, been the policy of this 17 Commonwealth to aid and support the development and expansion 18 of industry in this Commonwealth in order to foster the 19 economic well-being of this Commonwealth and its people. 20 (5) The economy and general welfare of this Commonwealth 21 and its people, as well as the economy, general welfare and 22 national security of the United States, are inseparably 23 related to the preservation and development of the steel 24 industry in this Commonwealth and in the other states of the 25 United States. The General Assembly therefore declares it to 26 be the policy of this Commonwealth that all public officers 27 and agencies should, at all times, aid and promote the 28 development of the steel industry of the United States in 29 order to stimulate and improve the economic well-being of 30 this Commonwealth and its people. 19970S0005B0228 - 82 -
1 (c) Police power.--This chapter shall be deemed to be an 2 exercise of the police powers of this Commonwealth for the 3 protection of the health, safety and general welfare of the 4 people of this Commonwealth. 5 (d) Purpose of chapter.--This chapter is intended as 6 remedial legislation designed to promote the general welfare and 7 stimulate the economy of this Commonwealth and its people; each 8 and every provision of this chapter is intended to receive a 9 liberal construction as will best effectuate that purpose, and 10 no provision is intended to receive a strict or limited 11 construction. 12 § 3712. Definitions. 13 The following words and phrases when used in this subchapter 14 shall have the meanings given to them in this section unless the 15 context clearly indicates otherwise: 16 "Public works." Any structure, building, highway, waterway, 17 street, bridge, transit system, airport or other betterment, 18 work or improvement, whether of a permanent or temporary nature 19 and whether for governmental or proprietary use. The term 20 includes, but is not limited to, any railway, street railway, 21 subway, elevated and monorail passenger or passenger and rail 22 rolling stock, self-propelled cars, gallery cars, locomotives, 23 passenger buses, wires, poles and equipment for electrification 24 of a transit system, rails, tracks, roadbeds, guideways, 25 elevated structures, buildings, stations, terminals, docks, 26 shelters and repairs to any of the foregoing. 27 "Steel products." Products rolled, formed, shaped, drawn, 28 extruded, forged, cast, fabricated or otherwise similarly 29 processed, or processed by a combination of two or more of these 30 operations, from steel made in the United States by the open 19970S0005B0228 - 83 -
1 hearth, basic oxygen, electric furnace, Bessemer or other steel- 2 making process. The term includes cast iron products. The term 3 also includes machinery and equipment listed in United States 4 Department of Commerce Standard Industrial Classification 25 5 (furniture and fixture), 35 (machinery, except electrical) and 6 37 (transportation equipment) and made of, fabricated from or 7 containing steel components. If a product contains both foreign 8 and United States steel, the product shall be determined to be a 9 United States steel product only if at least 75% of the cost of 10 the articles, materials and supplies have been mined, produced 11 or manufactured, as the case may be, in the United States. 12 Transportation equipment shall be determined to be a United 13 States steel product if it complies with section 165 of the 14 Surface Transportation Assistance Act of 1982 (Public Law 97- 15 424, 96 Stat. 2097). 16 "United States." The United States of America, including all 17 territory, continental or insular, subject to the jurisdiction 18 of the United States. 19 § 3713. Requirement of contract provision. 20 (a) General rule.--Each contract in excess of $250,000 which 21 is entered into by a government agency for the construction, 22 reconstruction, alteration, repair, improvement or maintenance 23 of public works shall contain a provision that if any steel 24 products are to be used or supplied in the performance of the 25 contract, only steel products as defined in this subchapter 26 shall be used or supplied in the performance of the contract or 27 any subcontracts. The amount of $250,000 shall be adjusted 28 annually by the department to reflect the annual percentage 29 change in the Composite Construction Cost Index of the United 30 States Department of Commerce occurring in the one-year period 19970S0005B0228 - 84 -
1 ending on December 31 of each year. 2 (b) Exception.--This section does not apply in any case 3 where the head of the government agency in writing determines 4 that steel products as defined in this subchapter are not 5 produced in the United States in sufficient quantities to meet 6 the requirements of the contract. 7 § 3714. Payments under contracts. 8 (a) Compliance with required contract provisions.--No 9 government agency shall authorize, provide for or make any 10 payments to any person under any contract containing the 11 provision required by section 3713 (relating to requirement of 12 contract provision) unless, when unidentified steel products are 13 supplied under a contract, the person has provided 14 documentation, including, but not limited to, invoices, bills of 15 lading and mill certification that the steel was melted and 16 manufactured in the United States, which establishes that the 17 person has fully complied with section 3713. If a steel product 18 is identifiable from its face, the person must submit 19 certification which satisfies the government agency that the 20 person has fully complied with section 3713. Any payments made 21 to any person by any government agency which should not have 22 been made as a result of this section shall be recoverable by 23 either the government agency or the Attorney General directly 24 from the contractor, subcontractor, manufacturer or supplier who 25 did not comply with section 3713. 26 (b) Penalties.--In addition to the withholding of payments, 27 any person who willfully violates any of the provisions of this 28 subchapter shall be prohibited from submitting any bids to any 29 government agency for any contract for a period of five years 30 from the date of the determination that a violation has 19970S0005B0228 - 85 -
1 occurred. In the event the person who violates the provisions of 2 section 3713 is a subcontractor, manufacturer or supplier, that 3 person shall be prohibited from performing any work or supplying 4 any materials to a government agency for a period of five years 5 from the date of the determination that a violation has 6 occurred. 7 (c) Application of Title 2.--Title 2 (relating to 8 administrative law and procedure) applies to decisions by 9 government agencies that a person has violated section 3713. 10 SUBCHAPTER C 11 TRADE PRACTICES 12 Sec. 13 3721. Short title of subchapter and general provisions. 14 3722. Definitions. 15 3723. Unlawful acts. 16 3724. Preference for aluminum and steel products made in 17 United States. 18 3725. Requirement to list discriminating countries. 19 3726. Procedure to determine discrimination. 20 3727. Foreign registry docket. 21 3728. Aluminum or steel products from a country listed on 22 foreign registry docket. 23 § 3721. Short title of subchapter and general provisions. 24 (a) Short title.--This subchapter shall be known and may be 25 cited as the Trade Practices Act. 26 (b) Legislative findings.--It is hereby determined by the 27 General Assembly to reaffirm the legislative findings contained 28 in the act of July 23, 1968 (P.L.686, No.226), entitled "An act 29 equalizing trade practices in public works procurement; 30 authorizing the purchase by the Commonwealth, its political 19970S0005B0228 - 86 -
1 subdivisions, and all public agencies, of aluminum and steel 2 products produced in a foreign country, provided the foreign 3 country does not prohibit or discriminate against the 4 importation to, sale or use in the foreign country of supplies, 5 material or equipment manufactured in this Commonwealth; 6 establishing procedures for determining whether foreign 7 countries discriminate against supplies, materials or equipment 8 manufactured in this Commonwealth; and imposing penalties and 9 providing for relief for violation of this act," and codified in 10 this chapter: 11 (1) It has long been the policy of this Commonwealth not 12 to purchase any supplies, equipment or materials manufactured 13 in any foreign country which prohibits the specification for 14 or use of supplies, equipment or materials manufactured in 15 this Commonwealth. 16 (2) Many world trading countries, directly or indirectly 17 by statute, regulation, policy, procedure or practice, grant 18 or bestow a preference for supplies, equipment or materials 19 manufactured in their country, thereby discriminating against 20 the use of supplies, equipment or materials manufactured in 21 this Commonwealth. The General Assembly therefore declares it 22 to be the policy of this Commonwealth that aluminum and steel 23 products made in the United States should be purchased by all 24 public agencies in preference to aluminum and steel products 25 made in foreign countries which discriminate against 26 supplies, equipment or materials manufactured in this 27 Commonwealth. 28 (c) Purpose of subchapter.--This subchapter is intended as 29 remedial legislation designed to promote the general welfare and 30 stimulate the economy of this Commonwealth and its people; each 19970S0005B0228 - 87 -
1 and every provision of this chapter is intended to receive a 2 liberal construction as will best effectuate the purpose, no 3 provision is intended to receive a strict or limited 4 construction. 5 § 3722. Definitions. 6 The following words and phrases when used in this subchapter 7 shall have the meanings given to them in this section unless the 8 context clearly indicates otherwise: 9 "Aluminum or steel products made in a foreign country." 10 Aluminum or steel products rolled, formed, shaped, drawn, 11 extruded, forged, cast, fabricated or otherwise similarly 12 processed, or processed by a combination of two or more of these 13 operations, from aluminum or steel not made in the United 14 States. 15 "Court." The Commonwealth Court. 16 "Discriminates." Any statute, regulation or policy of a 17 foreign country which directly or indirectly: 18 (1) Prevents the importation, sale or use of any 19 supplies, materials or equipment manufactured in this 20 Commonwealth. 21 (2) Grants or bestows a preference, discount or other 22 competitive advantage to supplies, materials or equipment 23 manufactured in the foreign country, the effect of which is 24 to place similar supplies, materials or equipment 25 manufactured in this Commonwealth at a competitive 26 disadvantage. 27 (3) Restricts the opportunities for persons having a 28 business situs in this Commonwealth to bid on or compete for 29 government contracts, including, but not limited to, a 30 preference for residents of the foreign country. 19970S0005B0228 - 88 -
1 (4) Solicits for awards or negotiates public works 2 contracts on a selective tender basis. 3 (5) Imposes discriminatory duties, tariffs or border 4 taxes on the importation of supplies, materials or equipment 5 not produced in the foreign country, the effect of which is 6 to place supplies, materials or equipment manufactured in 7 this Commonwealth at a competitive disadvantage with like 8 goods manufactured in any foreign country. 9 (6) Adopts or condones any other unfair method of 10 competition in international trade, including, but not 11 limited to, the exportation of aluminum or steel products 12 made in the foreign country through cartels or the 13 subsidization of aluminum or steel products. 14 "Importer." Any person registered and doing business in this 15 Commonwealth who engages in the receiving, storing, distributing 16 or other processing of aluminum or steel products made in a 17 foreign country or who engages in the solicitation or acceptance 18 of orders or contracts for the furnishing of or supplying of 19 aluminum or steel products made in a foreign country. 20 "Public works." Any structure, building, highway, waterway, 21 street, bridge, pier, transit car or system, airport or other 22 betterment, work or improvement, whether of a permanent or 23 temporary nature and whether for governmental or proprietary use 24 contracted for by any government agency or financed in whole or 25 in part by any government agency. 26 § 3723. Unlawful acts. 27 It is unlawful for: 28 (1) Any government agency to specify, purchase or permit 29 to be furnished or used in any public works aluminum or steel 30 products made in a foreign country which has been determined 19970S0005B0228 - 89 -
1 as discriminating by the court unless the amount of the 2 purchase or contract is equal to or less than $250,000. This 3 amount shall be adjusted annually by the department to 4 reflect the annual percentage charge in accordance with the 5 change in the Composite Construction Cost Index of the United 6 States Department of Commerce, occurring in the one-year 7 period ending on December 31 of each year. 8 (2) Any person to sell or offer for sale to any person 9 for use in any public works aluminum or steel products made 10 in a foreign country which has been determined as 11 discriminating by the court. 12 § 3724. Preference for aluminum and steel products made in 13 United States. 14 If all considerations in or affecting a bid or proposal or a 15 bidder or offeror are equal, each government agency shall give 16 preference to aluminum and steel products made in the United 17 States. 18 § 3725. Requirement to list discriminating countries. 19 In all its invitations for bids or requests for proposals, 20 schedules or purchase orders issued for public works exceeding 21 the amount established in section 3723 (relating to unlawful 22 acts), every government agency shall include a listing of the 23 foreign countries which have been found by the court to 24 discriminate. 25 § 3726. Procedure to determine discrimination. 26 (a) Petition.--Any government agency, importer or taxpayer 27 of this Commonwealth may file with the court a petition 28 specifically setting forth alleged discrimination by a foreign 29 country and praying for a determination. A copy of the petition 30 to the court and notice of the time of hearing set by the court 19970S0005B0228 - 90 -
1 shall be served by registered mail on the consular officer, if 2 any, of the country having an office in this Commonwealth and 3 upon a person in charge of the embassy of the foreign country in 4 Washington, D.C. 5 (b) Hearing.--Upon presentation of a petition filed pursuant 6 to subsection (a), the court shall make an order fixing a time 7 for a hearing. The hearing shall be fixed on a day not later 8 than 45 days after the filing of the petition. The 9 representative of the foreign country and any other interested 10 person may appear and present testimony at the hearing. At the 11 hearing, the court shall consider the statutes, regulations, 12 policies, procedures and practices of the foreign country 13 specified in the petition. 14 § 3727. Foreign registry docket. 15 (a) Entering name in docket.--If, after a hearing, the court 16 determines that the foreign country discriminates, it shall 17 direct the prothonotary of the court to enter the name of the 18 foreign country in a foreign registry docket maintained in the 19 office of the prothonotary. 20 (b) Striking name from docket.--Any foreign country 21 determined to be practicing discrimination may petition the 22 court to have its name stricken from the foreign registry 23 docket. The court shall grant the prayer of the petition if, 24 after hearing, it determines that the foreign country has 25 discontinued and not engaged in discrimination for a period of 26 at least one year prior to the filing of the petition. Notice of 27 the filing of the petition shall be served upon the original 28 petitioner and all other parties to the original petition. 29 § 3728. Aluminum or steel products from a country listed on 30 foreign registry docket. 19970S0005B0228 - 91 -
1 (a) General rule.--It is unlawful for any person in the 2 performance of a public works contract, subcontract or purchase 3 order to furnish aluminum or steel products made in a foreign 4 country that is listed on a foreign registry docket if the 5 amount exceeds the amount established in section 3723 (relating 6 to unlawful acts). The person or any organization, corporation, 7 partnership, business unit, association or joint venture in 8 which the person has a substantial interest shall not be 9 eligible to bid or submit an offer on or be awarded any contract 10 or subcontract or be issued a purchase order for public works 11 for a period of three years. 12 (b) Persons deemed not in violation.--Notwithstanding 13 subsection (a), a person shall not be held to have violated this 14 subchapter if he has not received notification of the listing as 15 provided in section 3725 (relating to requirement to list 16 discriminating countries) or solely because his subcontractor or 17 supplier of materials violates this subchapter if the person had 18 no knowledge of the violation. 19 SUBCHAPTER D 20 MOTOR VEHICLES 21 Sec. 22 3731. Short title of subchapter and general provisions. 23 3732. Definitions. 24 3733. Police power. 25 3734. Contract provisions. 26 3735. Payment under contract and action to recover 27 unauthorized payments. 28 3736. Penalty. 29 § 3731. Short title of subchapter and general provisions. 30 (a) Short title.--This subchapter shall be known and may be 19970S0005B0228 - 92 -
1 cited as the Motor Vehicle Procurement Act. 2 (b) Legislative findings.--It is hereby determined by the 3 General Assembly to reaffirm the legislative findings contained 4 in the act of April 4, 1984 (P.L.193, No.40), known as the Motor 5 Vehicle Procurement Act, and codified in this chapter: 6 (1) The production of motor vehicles and component parts 7 constitutes a major industry of this Commonwealth. It 8 provides employment for and incomes of hundreds of thousands 9 of the people of this Commonwealth and, in turn, millions of 10 persons in the United States. 11 (2) The taxes paid to the Commonwealth and its political 12 subdivisions by employers and employees engaged in the 13 production and sale of motor vehicles is one of the largest 14 single sources of public revenues in this Commonwealth. 15 (3) It has for many years been the policy of this 16 Commonwealth to aid and support the development and expansion 17 of industry here to foster the economic well-being of this 18 Commonwealth and its people. 19 (4) The economy and general welfare of this Commonwealth 20 and its citizens, as well as the economy, general welfare and 21 national security of the United States, are inseparably 22 related in the preservation and development of the motor 23 vehicle industry in this Commonwealth and in other states of 24 the United States. 25 (5) The production of motor vehicles and motor vehicle 26 components in Canada involves the use of a substantial amount 27 of resources from the United States, including labor and 28 materials. The General Assembly declares it to be the policy 29 of the Commonwealth of Pennsylvania that public officers and 30 agencies should aid and promote the development of the motor 19970S0005B0228 - 93 -
1 vehicle industry of North America to stimulate and improve 2 the economic well-being of this Commonwealth and its 3 citizens. 4 (c) Purpose of subchapter.--This subchapter is intended as 5 remedial legislation designed to promote the general welfare and 6 stimulate the economy of this Commonwealth and its people. Each 7 provision shall receive a liberal construction to effectuate 8 that intention. None of the provisions of this subchapter shall 9 receive a strict or limited construction. 10 § 3732. Definitions. 11 The following words and phrases when used in this subchapter 12 shall have the meanings given to them in this section unless the 13 context clearly indicates otherwise: 14 "Motor vehicle." A vehicle which is self-propelled except 15 one which is propelled solely by human or animal power. The term 16 includes those vehicles designed primarily for use in 17 construction or agriculture or road maintenance such as tractors 18 and earth-moving equipment. 19 "North America." The United States and Canada. The United 20 States includes all territory, continental or insular, subject 21 to the jurisdiction of the United States. 22 "Procure." To acquire by purchase, lease or rent. The term 23 does not include any rentals or leases where the term thereof is 24 less than one month. 25 § 3733. Police power. 26 This subchapter shall be deemed to be an exercise of the 27 police power of this Commonwealth for the protection of the 28 health, safety and general welfare of its citizens. 29 § 3734. Contract provisions. 30 (a) Motor vehicles to be manufactured in North America.--All 19970S0005B0228 - 94 -
1 government agencies shall procure only motor vehicles which are 2 manufactured in North America. A motor vehicle is manufactured 3 in North America if a substantial majority of the principal 4 components are assembled into the final product in an assembly 5 plant in North America. Contract documents for the procurement 6 of motor vehicles shall contain a provision that the vehicles 7 procured by the government agency shall be manufactured in North 8 America. 9 (b) Exception.--This section shall not apply where the head 10 of the government agency states in writing that it is 11 inconsistent with the public interest or that the cost is 12 unreasonable. 13 § 3735. Payment under contract and action to recover 14 unauthorized payments. 15 A government agency shall not authorize, provide for or make 16 a payment to a person under a contract containing the provision 17 required by section 3734 (relating to contract provisions) 18 unless the government agency is satisfied that the person has 19 complied with the provision. The payment made to a person by a 20 government agency which should not have been made shall be 21 recoverable directly from the supplier of the motor vehicle who 22 did not comply with section 3734 by the government agency or the 23 Attorney General by appropriate legal action. Nothing in this 24 section shall authorize any government agency to initiate a 25 legal action independently of the Attorney General unless 26 otherwise authorized under the act of October 15, 1980 (P.L.950, 27 No.164), known as the Commonwealth Attorneys Act. 28 § 3736. Penalty. 29 In addition to the withholding of payments, any person who 30 willfully violates any of the provisions of this subchapter may 19970S0005B0228 - 95 -
1 be prohibited by any government agency from participation in 2 contracts awarded by the government agency for a period of five 3 years from the date of the determination that a violation has 4 occurred. 5 SUBCHAPTER E 6 USED OIL PRODUCTS 7 Sec. 8 3741. Preference. 9 § 3741. Preference. 10 As provided for in the act of April 9, 1982 (P.L.314, No.89), 11 known as the Pennsylvania Used Oil Recycling Act, government 12 agencies and persons holding contracts with government agencies 13 shall encourage and, to the extent possible, require the 14 procurement and purchase of recycled oil products as 15 substantially equivalent to products made from new oil. 16 SUBCHAPTER F 17 GUARANTEED ENERGY SAVINGS CONTRACTS 18 Sec. 19 3751. Definitions. 20 3752. Selection process. 21 3753. Award of single contract. 22 § 3751. Definitions. 23 The following words and phrases when used in this subchapter 24 shall have the meanings given to them in this section unless the 25 context clearly indicates otherwise: 26 "Energy conservation measure." A training program or 27 facility alteration designed to reduce energy consumption or 28 operating costs. The term shall include, without limitation: 29 (1) Insulation of the building structure or systems 30 within the building. 19970S0005B0228 - 96 -
1 (2) Storm windows or doors, caulking or weather 2 stripping, multiglazed windows or doors, heat-absorbing or 3 heat-reflective glazed and coated window or door systems, 4 additional glazing, reductions in glass area or other window 5 and door system modifications that reduce energy consumption. 6 (3) Automated or computerized energy control systems. 7 (4) Heating, ventilating or air-conditioning system 8 modifications or replacements. 9 (5) Replacement or modification of lighting fixtures to 10 increase the energy efficiency of the lighting system without 11 increasing the overall illumination of a facility unless an 12 increase in illumination is necessary to conform to 13 applicable State or local building codes for the lighting 14 system after the proposed modifications are made. 15 (6) Energy recovery systems. 16 (7) Systems that produce steam or forms of energy such 17 as heat, as well as electricity, for use within a building or 18 complex of buildings. 19 (8) Energy conservation measures that provide operating 20 cost reductions based on life-cycle cost analysis. 21 "Guaranteed energy savings contract." A contract for the 22 evaluation and recommendation of energy conservation measures 23 and for implementation of one or more such measures. 24 § 3752. Selection process. 25 In connection with the letting of any guaranteed energy 26 savings contract, Commonwealth agencies shall have the power to 27 waive the process for the selection of design professionals 28 prescribed under section 905 (relating to procurement of design 29 professionals). 30 § 3753. Award of single contract. 19970S0005B0228 - 97 -
1 Notwithstanding section 905 (relating to procurement of 2 design professionals), the Commonwealth agencies may enter into 3 a single guaranteed energy savings contract for the design and 4 complete implementation of the energy conservation measures 5 involved in a project. 6 CHAPTER 39 7 CONSTRUCTION CONTRACTS OVER $50,000 8 Subchapter 9 A. Preliminary Provisions 10 B. General Provisions 11 C. Retainage 12 D. Prompt Payment Schedules 13 E. Final Payment 14 SUBCHAPTER A 15 PRELIMINARY PROVISIONS 16 Sec. 17 3901. Application and purpose of chapter. 18 3902. Definitions. 19 § 3901. Application and purpose of chapter. 20 (a) Application.--Except as otherwise specifically provided 21 in this chapter, this chapter applies to contracts entered into 22 by a government agency through competitive sealed bidding or 23 competitive sealed proposals. 24 (b) Purpose of chapter.--The purpose of this chapter is to 25 establish a uniform and mandatory system governing public 26 contracts to the extent of the requirements set forth in this 27 chapter and shall be construed to effectuate such purpose. The 28 provisions of this chapter shall in no way affect the provisions 29 of the act of August 15, 1961 (P.L.987, No.442), known as the 30 Pennsylvania Prevailing Wage Act, nor the regulations 19970S0005B0228 - 98 -
1 promulgated under that act, nor shall any requirements of this 2 chapter affect any provisions of a contract to be awarded 3 pursuant to any Federal law or regulations containing specific 4 provisions which are different from the public contract 5 requirements of this chapter. 6 § 3902. Definitions. 7 The following words and phrases when used in this chapter 8 shall have the meanings given to them in this section unless the 9 context clearly indicates otherwise: 10 "Contract." A contract exceeding $50,000 for construction as 11 defined in section 103 (relating to definitions), including 12 heating or plumbing contracts but excepting work performed for 13 the Department of Transportation. 14 "Contractor." A person who enters into a contract with a 15 government agency. 16 "Deficiency item." Work performed but which the design 17 professional, the contractor or the inspector will not certify 18 as being completed according to the contract. 19 "Design professional." A professional engineer or 20 professional land surveyor licensed under the act of May 23, 21 1945 (P.L.913, No.367), known as the Engineer, Land Surveyor and 22 Geologist Registration Law, a landscape architect licensed under 23 the act of January 24, 1966 (1965 P.L.1527, No.535), known as 24 the Landscape Architects' Registration Law, or an architect 25 licensed under the act of December 14, 1982 (P.L.1227, No.281), 26 known as the Architects Licensure Law. 27 "Government agency." Includes any State-aided institutions. 28 "Inspector." The person authorized or engaged by the 29 government agency to inspect the work performed and materials 30 furnished pursuant to a contract to determine whether the work 19970S0005B0228 - 99 -
1 completed is in compliance with the contract. 2 "Local government unit." Any county, city, borough, 3 incorporated town, township, school district, vocational school 4 district, county institution, local authority or any joint or 5 cooperative body of local government units or any 6 instrumentality, authority or corporation thereof which has 7 authority to enter into a contract. 8 "State-aided institution." Any institution which receives 9 State funds directly or indirectly for construction. 10 "Subcontractor." A person who has contracted to furnish 11 labor or materials to or has performed labor for a contractor or 12 another subcontractor in connection with a contract. 13 "Substantial completion." Construction that is sufficiently 14 completed in accordance with the contract and certified by the 15 architect or engineer of the government agency, as modified by 16 change orders agreed to by the parties, so that the project can 17 be used, occupied or operated for its intended use. In no event 18 shall a project be certified as substantially complete until at 19 least 90% of the work on the project is completed. 20 SUBCHAPTER B 21 GENERAL PROVISIONS 22 Sec. 23 3911. Time for awarding contract. 24 3912. Time for executing contract. 25 3913. Release of successful bidder. 26 § 3911. Time for awarding contract. 27 (a) General rule.--In the case of a contract to be entered 28 into by a government agency through competitive sealed bidding, 29 the contract shall be awarded to the lowest responsible and 30 responsive bidder within 60 days of the bid opening, or all bids 19970S0005B0228 - 100 -
1 shall be rejected except as otherwise provided in this section. 2 (b) Delay.--If the award is delayed by the required approval 3 of another government agency, the sale of bonds or the award of 4 a grant, the contract shall be awarded to the lowest responsible 5 and responsive bidder within 120 days of the bid opening, or all 6 bids shall be rejected. 7 (c) Extensions.--Thirty-day extensions of the date for the 8 award may be made by the mutual written consent of the 9 government agency and the lowest responsible and responsive 10 bidder. 11 (d) List of bidders.--All government agencies shall be 12 required to provide a list of the bidders and their bid amount 13 on each contract within ten working days of the bid opening to 14 interested parties for a fee to be determined by the government 15 agency to cover the cost of developing such list. This 16 requirement shall not apply to the contracting bodies of any 17 political subdivision or local authority which has the authority 18 to enter into a contract. 19 § 3912. Time for executing contract. 20 In the case of a contract entered into by a government agency 21 through competitive sealed bidding, the contract shall be 22 executed by the government agency within 45 days of the date 23 that the contract is awarded. 24 § 3913. Release of successful bidder. 25 Failure of the government agency to comply with the 26 requirements of sections 3911 (relating to time for awarding 27 contract) and 3912 (relating to time for executing contract) 28 shall, unless the successful bidder waives the noncompliance by 29 written notice to the government agency, release the successful 30 bidder from any liability in respect to its bid or contract and 19970S0005B0228 - 101 -
1 entitle all bidders to the immediate return of any bonds or 2 security deposits posted in connection with the bid or contract. 3 SUBCHAPTER C 4 RETAINAGE 5 Sec. 6 3921. Retainage. 7 3922. Payment of retainage to subcontractors. 8 § 3921. Retainage. 9 (a) Contract provision.--A contract may include a provision 10 for the retainage of a portion of the amount due the contractor 11 to insure the proper performance of the contract except that the 12 sum withheld by the government agency from the contractor shall 13 not exceed 10% of the amount due the contractor until 50% of the 14 contract is completed. When the contract is 50% completed, one- 15 half of the amount retained by the government agency shall be 16 returned to the contractor. However, the architect or engineer 17 must approve the application for payment. The contractor must be 18 making satisfactory progress, and there must be no specific 19 cause for greater withholding. The sum withheld by the 20 government agency from the contractor after the contract is 50% 21 completed shall not exceed 5% of the value of completed work 22 based on monthly progress payment requests. In the event a 23 dispute arises between the government agency and any prime 24 contractor, which dispute is based upon increased costs claimed 25 by one prime contractor occasioned by delays or other actions of 26 another prime contractor, additional retainage in the sum of one 27 and one-half times the amount of any possible liability may be 28 withheld until a time as a final resolution is agreed to by all 29 parties directly or indirectly involved unless the contractor 30 causing the additional claim furnishes a bond satisfactory to 19970S0005B0228 - 102 -
1 the government agency to indemnify the agency against the claim. 2 All money retained by the government agency may be withheld from 3 the contractor until substantial completion of the contract. 4 (b) Department of General Services.--Notwithstanding 5 subsection (a), when the Department of General Services is the 6 government agency, the contract may include a provision for the 7 retainage of a portion of the amount due the contractor to 8 insure the proper performance of the contract except that the 9 sum withheld by the department for the contractor shall not 10 exceed 6% of the then total estimates until 50% of the contract 11 is satisfactorily completed. The sum withheld by the department 12 from the contractor after the contract is 50% satisfactorily 13 completed shall not exceed 3% of the original contract amount. 14 § 3922. Payment of retainage to subcontractors. 15 In the absence of sufficient reason, within 20 days of the 16 receipt of payment by the contractor, the contractor shall pay 17 all subcontractors with which it has contracted their earned 18 share of the payment the contractor received. 19 SUBCHAPTER D 20 PROMPT PAYMENT SCHEDULES 21 Sec. 22 3931. Performance by contractor or subcontractor. 23 3932. Government agency's progress payment obligations. 24 3933. Contractors' and subcontractors' payment obligations. 25 3934. Withholding of payment for good faith claims. 26 3935. Penalty and attorney fees. 27 3936. Contracts involving Federal aid. 28 3937. Certain provisions unenforceable. 29 3938. Applicability. 30 3939. Claims by innocent parties. 19970S0005B0228 - 103 -
1 § 3931. Performance by contractor or subcontractor. 2 (a) Entitlement of contractor to payment.--Performance by a 3 contractor in accordance with the provisions of a contract shall 4 entitle the contractor to payment by the government agency. 5 (b) Entitlement of subcontractor to payment.--Performance by 6 a subcontractor in accordance with the provisions of a contract 7 shall entitle the subcontractor to payment from the contractor 8 with whom the subcontractor has contracted. 9 § 3932. Government agency's progress payment obligations. 10 (a) Payments in accordance with contract.--The government 11 agency shall pay the contractor or design professional strictly 12 in accordance with the contract. 13 (b) Application for progress payments.--If the contract does 14 not contain a term governing the time for payment, the 15 contractor or design professional shall be entitled to make 16 application for payment from the government agency for progress 17 payments, and the government agency shall make payment less the 18 applicable retainage amount as authorized in section 3921 19 (relating to retainage) to the contractor or design professional 20 within 45 calendar days of the date the application for payment 21 is received. 22 (c) Interest on progress payments not timely made.--Except 23 as otherwise agreed by the parties, if any progress payment less 24 the applicable retainage amount as authorized in section 3921 is 25 not made to a contractor or design professional by the due date 26 established in the contract or in subsection (b), the government 27 agency shall pay to the contractor or design professional, in 28 addition to the amount due, interest on the amount due, and the 29 interest shall be computed at the rate determined by the 30 Secretary of Revenue for interest payments on overdue taxes or 19970S0005B0228 - 104 -
1 the refund of taxes as provided in sections 806 and 806.1 of the 2 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 3 Code. 4 (d) When interest payment not required.--In the event that 5 the contract does not contain a grace period and if a contractor 6 or design professional is not paid by the payment date required 7 by subsection (b), no interest penalty payment required under 8 this section shall be paid if payment is made on or before the 9 15th calendar day after the payment date required under this 10 subchapter. 11 § 3933. Contractors' and subcontractors' payment obligations. 12 (a) Performance by subcontractor entitles subcontractor to 13 payment.--Performance by a subcontractor in accordance with the 14 provisions of the contract shall entitle the subcontractor to 15 payment from the party with whom the subcontractor has 16 contracted. For purposes of this section, the contract between 17 the contractor and subcontractor is presumed to incorporate the 18 terms of the contract between the contractor and the government 19 agency. 20 (b) Disclosure of progress payment due dates.--A contractor 21 or subcontractor shall disclose to a subcontractor, before a 22 subcontract is executed, the due date for receipt of progress 23 payments from the government agency. Notwithstanding any other 24 provisions of this subchapter, if a contractor or a 25 subcontractor fails to accurately disclose the due date to a 26 subcontractor, the contractor or subcontractor shall be 27 obligated to pay the subcontractor as though the due dates 28 established in subsection (c) were met by the government agency. 29 This subsection shall not apply to a change in due dates because 30 of conditions outside of the contractor's control, including, 19970S0005B0228 - 105 -
1 but not limited to, design changes, change orders or delays in 2 construction due to weather conditions. 3 (c) Payment.--When a subcontractor has performed in 4 accordance with the provisions of the contract, a contractor 5 shall pay to the subcontractor, and each subcontractor shall in 6 turn pay to its subcontractors, the full or proportional amount 7 received for each such subcontractor's work and material, based 8 on work completed or services provided under the subcontract, 14 9 days after receipt of a progress payment. Payment shall be made 10 under this section unless it is being withheld under section 11 3934 (relating to withholding of payment for good faith claims). 12 (d) Interest due when progress payment not timely.--If any 13 progress payment is not made to a subcontractor by the due date 14 established in the contract or in subsection (c), the contractor 15 shall pay to the subcontractor, in addition to the amount due, 16 interest as computed in section 3932(c) (relating to government 17 agency's progress payment obligations). 18 (e) When interest payment not required.--In the event that 19 the contract does not contain a grace period and if a 20 subcontractor is not paid by the payment date required by 21 subsection (c), no interest penalty payment required under this 22 section shall be paid if payment is made on or before the 15th 23 calendar day after the payment date required under this 24 subchapter. 25 § 3934. Withholding of payment for good faith claims. 26 (a) When government agency may withhold payment.--The 27 government agency may withhold payment for deficiency items 28 according to terms of the contract. The government agency shall 29 pay the contractor according to the provisions of this 30 subchapter for all other items which appear on the application 19970S0005B0228 - 106 -
1 for payment and have been satisfactorily completed. The 2 contractor may withhold payment from any subcontractor 3 responsible for a deficiency item. The contractor shall pay any 4 subcontractor according to the provisions of this subchapter for 5 any item which appears on the application for payment and has 6 been satisfactorily completed. 7 (b) Notification when payment withheld for deficiency 8 item.--If a government agency withholds payment from a 9 contractor for a deficiency item, it shall notify the contractor 10 of the deficiency item within the time period specified in the 11 contract or 15 calendar days of the date that the application 12 for payment is received. If a contractor withholds payment from 13 a subcontractor for a deficiency item, it must notify the 14 subcontractor or supplier and the government agency of the 15 reason within 15 calendar days of the date after receipt of the 16 notice of the deficiency item from the owner. 17 § 3935. Penalty and attorney fees. 18 (a) Penalty.--If arbitration or a claim with the Board of 19 Claims or a court of competent jurisdiction is commenced to 20 recover payment due under this subchapter and it is determined 21 that the government agency, contractor or subcontractor has 22 failed to comply with the payment terms of this subchapter, the 23 arbitrator, the Board of Claims or the court may award, in 24 addition to all other damages due, a penalty equal to 1% per 25 month of the amount that was withheld in bad faith. An amount 26 shall be deemed to have been withheld in bad faith to the extent 27 that the withholding was arbitrary or vexatious. An amount shall 28 not be deemed to have been withheld in bad faith to the extent 29 it was withheld pursuant to section 3934 (relating to 30 withholding of payment for good faith claims). 19970S0005B0228 - 107 -
1 (b) Attorney fees.--Notwithstanding any agreement to the 2 contrary, the prevailing party in any proceeding to recover any 3 payment under this subchapter may be awarded a reasonable 4 attorney fee in an amount to be determined by the Board of 5 Claims, court or arbitrator, together with expenses, if it is 6 determined that the government agency, contractor or 7 subcontractor acted in bad faith. An amount shall be deemed to 8 have been withheld in bad faith to the extent that the 9 withholding was arbitrary or vexatious. 10 § 3936. Contracts involving Federal aid. 11 If any provision of this subchapter conflicts with a Federal 12 statute or regulation or with conditions attached to the receipt 13 of Federal aid, this subchapter shall not operate to prevent 14 receipt of the Federal aid in accordance with any Federal 15 statute or regulation. 16 § 3937. Certain provisions unenforceable. 17 A provision in the contract making it subject to the laws of 18 another state or requiring that any litigation, arbitration or 19 other dispute resolution process on the contract occurs in 20 another state shall be unenforceable. 21 § 3938. Applicability. 22 (a) Not applicable in certain situations.--This subchapter 23 shall not apply in the following situations: 24 (1) Section 3932 (relating to government agency's 25 progress payment obligations) shall not apply when the State 26 government unit's nonpayment on a particular project is 27 caused by the failure of the General Assembly to enact a 28 budget for the fiscal year of payment. 29 (2) Section 3932 shall not apply when a local government 30 unit's nonpayment on a particular project is caused by 19970S0005B0228 - 108 -
1 failure of the Federal or State Government to pay funds due 2 and payable to the local government unit. 3 (3) Section 3932 shall not apply when government 4 agency's nonpayment on a particular project is caused by the 5 failure of the General Assembly to enact an operating budget 6 for the fiscal year of payment or a capital budget for the 7 capital project or by failure of the Federal, State or local 8 government to pay funds designated or to be designated for 9 the specific project. 10 (4) Nothing in this subchapter shall be construed to 11 require payment of interest penalties by the Federal or State 12 Government if the municipality is liable for such interest. 13 (b) Not applicable to following entities.--This act shall 14 not apply to any of the following: 15 (1) A municipality determined to be distressed under the 16 act of July 10, 1987 (P.L.246, No.47), known as the 17 Municipalities Financial Recovery Act. 18 (2) A school district which has been determined to be a 19 distressed school district under section 691 of the act of 20 March 10, 1949 (P.L.30, No.14), known as the Public School 21 Code of 1949. 22 (3) A city of the first class that has entered into an 23 intergovernmental cooperation agreement under the act of June 24 5, 1991 (P.L.9, No.6), known as the Pennsylvania 25 Intergovernmental Cooperation Authority Act for Cities of the 26 First Class, for so long as any deficit-reducing bonds issued 27 by the authority pursuant to section 301(b)(1) of the act are 28 outstanding and payable. 29 (4) Any corporate entity or school district as defined 30 in the Pennsylvania Intergovernmental Cooperation Authority 19970S0005B0228 - 109 -
1 Act for Cities of the First Class. 2 § 3939. Claims by innocent parties. 3 (a) No obligation to third parties.--The government agency 4 shall have no obligation to any third parties for any claim. 5 (b) Barred claims.--Once a contractor has made payment to 6 the subcontractor according to the provisions of this 7 subchapter, future claims for payment against the contractor or 8 the contractor's surety by parties owed payment from the 9 subcontractor which has been paid shall be barred. 10 SUBCHAPTER E 11 FINAL PAYMENT 12 Sec. 13 3941. Final payment under contract. 14 3942. Arbitration. 15 § 3941. Final payment under contract. 16 (a) Contract containing provision for retainage.--A contract 17 containing a provision for retainage as provided in section 3921 18 (relating to retainage) shall contain a provision requiring the 19 architect or engineer to make final inspection within 30 days of 20 receipt of the request of the contractor for final inspection 21 and application for final payment. If the work is substantially 22 completed, the architect or engineer shall issue a certificate 23 of completion and a final certificate for payment, and the 24 government agency shall make payment in full within 45 days 25 except as provided in section 3921, less only one and one-half 26 times the amount as is required to complete any then-remaining 27 uncompleted minor items, which amount shall be certified by the 28 architect or engineer and, upon receipt by the government agency 29 of any guarantee bonds which may be required, in accordance with 30 the contract, to insure proper workmanship for a designated 19970S0005B0228 - 110 -
1 period of time. The certificate given by the architect or 2 engineer shall list in detail each uncompleted item and a 3 reasonable cost of completion. Final payment of any amount 4 withheld for the completion of the minor items shall be paid 5 upon completion of the items in the certificate of the engineer 6 or architect. 7 (b) Interest.--The final payment due the contractor from the 8 government agency after substantial completion of the contract 9 shall bear interest at a rate of 6% for all contracts without 10 provisions for retainage and at a rate of 10% for all contracts 11 with provisions for retainage, the interest to begin after the 12 date that such payment becomes due and payable to the 13 contractor. However, where the government agency has issued 14 bonds to finance the project, interest shall be payable to the 15 contractor at the rate of interest of the bond issue or at the 16 rate of 10%, whichever is less, but in no event shall the 17 interest payable to the contractor be at a rate of interest less 18 than the legal rate of interest. 19 § 3942. Arbitration. 20 If a dispute should arise between the contractor and the 21 government agency over the payment of retainages and final 22 payment, then the dispute shall be arbitrated under the 23 applicable terms of the contract. If the contract contains no 24 provision for arbitration, then both parties may mutually agree 25 to arbitrate the dispute under the rules of the American 26 Arbitration Association or in accordance with 42 Pa.C.S. Ch. 73 27 (relating to arbitration). In any event, either party shall have 28 the right of appeal from any decision and award as provided by 29 law. 30 CHAPTER 41 19970S0005B0228 - 111 -
1 PURCHASE OF SURPLUS FEDERAL PROPERTY 2 Sec. 3 4101. Contracts with United States. 4 4102. Bids and down payments. 5 § 4101. Contracts with United States. 6 Any government agency may enter into a contract with the 7 Federal Government for the purchase, lease or other acquisition, 8 including the warehousing and distribution, of any surplus real 9 or personal Federal property without complying with any 10 requirement of law as to specifications, advertising, award of 11 contract or approval by another government agency. However, any 12 Commonwealth agency may only enter into a contract authorized by 13 this section through the Department of General Services. 14 § 4102. Bids and down payments. 15 Any government agency authorized to enter into a contract 16 under section 4101 (relating to contracts with United States) 17 may designate by appropriate order an officeholder or employee 18 of its own to enter a bid in its behalf at any sale of any 19 surplus real or personal Federal property and may authorize the 20 designee to make any down payment or payment in full required in 21 connection with the bidding. 22 CHAPTER 43 23 PUBLIC FACILITIES CONCESSIONS 24 Sec. 25 4301. Short title of chapter and general provisions. 26 4302. Definitions. 27 4303. Terms of contracts. 28 § 4301. Short title of chapter and general provisions. 29 (a) Short title.--This chapter shall be known and may be 30 cited as the Public Facilities Concession Regulation Act. 19970S0005B0228 - 112 -
1 (b) Legislative findings.--It is hereby determined by the 2 General Assembly to reaffirm the legislative findings contained 3 in the act of November 26, 1978 (P.L.1303, No.315), known as the 4 Public Facilities Concession Regulation Act, and codified in 5 this chapter: 6 (1) It is and has been the policy of this Commonwealth 7 to require and encourage public agencies to own and operate a 8 variety of public facilities for the conduct of public 9 business and for the health, education, protection, 10 transportation, recreation, entertainment and cultural 11 advancement of the people of this Commonwealth. 12 (2) It is and has been the policy of this Commonwealth 13 to promote the public welfare by permitting the operation, 14 within these public facilities, of various concessions to 15 provide goods and services to the public. 16 (3) Due to the nature, configuration and location of 17 many public facilities, members of the public utilizing the 18 facilities must either patronize the concessionaires 19 operating therein or undergo great expense, inconvenience and 20 hardship. 21 (4) The general welfare of the people of this 22 Commonwealth requires that concessionaires operating in 23 public facilities offer to the public goods and services of 24 good quality at reasonable prices. The General Assembly 25 therefore declares it to be the policy of this Commonwealth 26 that all public officers and agencies should, at all times, 27 make efforts to see that concessionaires in public facilities 28 provide goods and services of high quality, at reasonable 29 prices, in order to protect the public and encourage use of 30 public facilities. 19970S0005B0228 - 113 -
1 (c) Police power.--This chapter shall be deemed to be an 2 exercise of the police powers of this Commonwealth for the 3 protection of the health, safety and general welfare of the 4 people of this Commonwealth. 5 (d) Purpose of chapter.--This chapter is intended as 6 remedial legislation designed to promote the general welfare, 7 protect the public and encourage full and proper use of public 8 facilities. Each provision of this chapter is intended to 9 receive a liberal construction as will best effectuate those 10 purposes, and no provision is intended to receive a strict or 11 limited construction. 12 (e) Certain rights preserved.--This chapter is not intended 13 to limit or deny any other rights previously enjoyed by any 14 government agency. 15 § 4302. Definitions. 16 The following words and phrases when used in this chapter 17 shall have the meanings given to them in this section unless the 18 context clearly indicates otherwise: 19 "Public facility." Any building, airport, school, park, 20 hospital or other structure, grounds or place owned or operated 21 by a government agency, whether for governmental or proprietary 22 use. 23 § 4303. Terms of contracts. 24 (a) General rule.--Each government agency shall require that 25 every contract granting any concession, license, permit or right 26 to sell, lease, contract for or otherwise make available for 27 consideration goods or services to the public in any public 28 facility contains provisions giving the government agency the 29 right to regulate the kinds, quality and prices of the goods and 30 services, upon terms and conditions as may be appropriate. 19970S0005B0228 - 114 -
1 (b) Exceptions.--This section is not intended to apply in 2 any of the following cases: 3 (1) Where the right to regulate price or quality is 4 vested exclusively in or has been preempted by the United 5 States or any of its agencies or another government agency. 6 (2) Where the head of the government agency determines 7 in writing that the retention of the right to regulate is not 8 necessary to protect the general welfare. 9 CHAPTER 45 10 ANTIBID-RIGGING 11 Sec. 12 4501. Short title of chapter. 13 4502. Definitions. 14 4503. Prohibited activities. 15 4504. Civil action and damages. 16 4505. Suspension or debarment. 17 4506. Liability for increased costs. 18 4507. Noncollusion affidavits. 19 4508. Responsibility for enforcement. 20 4509. Investigation. 21 § 4501. Short title of chapter. 22 This chapter shall be known and may be cited as the Antibid- 23 Rigging Act. 24 § 4502. Definitions. 25 The following words and phrases when used in this chapter 26 shall have the meanings given to them in this section unless the 27 context clearly indicates otherwise: 28 "Bid-rigging." The concerted activity of two or more persons 29 to determine in advance the winning bidder of a contract let or 30 to be let for competitive bidding by a government agency. The 19970S0005B0228 - 115 -
1 term includes, but is not limited to, any one or more of the 2 following: 3 (1) Agreeing to sell items or services at the same 4 price. 5 (2) Agreeing to submit identical bids. 6 (3) Agreeing to rotate bids. 7 (4) Agreeing to share profits with a contractor who does 8 not submit the low bid. 9 (5) Submitting prearranged bids, agreed-upon higher or 10 lower bids or other complementary bids. 11 (6) Agreeing to set up territories to restrict 12 competition. 13 (7) Agreeing not to submit bids. 14 "Government agency." The Commonwealth and any of its 15 departments, boards, agencies, authorities and commissions, any 16 political subdivision, municipal or other local authority or any 17 officer or agency of any political subdivision or local 18 authority. 19 "Person." An individual, corporation or partnership or any 20 other entity capable of submitting a bid to the Commonwealth. 21 § 4503. Prohibited activities. 22 (a) Bid-rigging unlawful.--It is unlawful for any person to 23 conspire, collude or combine with another in order to commit or 24 attempt to commit bid-rigging involving: 25 (1) A contract for the purchase of equipment, goods, 26 services or materials or for construction or repair let or to 27 be let by a government agency. 28 (2) A subcontract for the purchase of equipment, goods, 29 services or materials or for construction or repair with a 30 prime contractor or proposed prime contractor for a 19970S0005B0228 - 116 -
1 government agency. 2 (b) Simultaneous bids.--Notwithstanding other provisions of 3 this chapter, it is not unlawful for the same person to 4 simultaneously submit bids for the same work, or a portion 5 thereof, as a proposed prime contractor and subcontractor. 6 (c) Fines and imprisonment.--Any person who violates this 7 section commits a felony of the third degree and shall, upon 8 conviction, be sentenced to pay a fine of not more than 9 $1,000,000, if an entity other than an individual, or a fine of 10 not more than $50,000, if an individual, or to serve a term of 11 imprisonment for not more than three years, or both. 12 (d) Alternative civil penalty.--In lieu of criminal 13 prosecution for violation of this section, the Attorney General 14 may bring an action for a civil penalty. In this action, a 15 person found by a court to have violated this section shall be 16 liable for a civil penalty of not more than $100,000. 17 (e) Disposition of fines and penalties.--Criminal fines and 18 civil penalties collected under subsections (c) and (d) shall be 19 paid into the State Treasury and deposited in the appropriate 20 fund. 21 (f) Factors to be considered in determining fines, 22 imprisonment or civil penalties.--In determining the appropriate 23 sanctions to be imposed for a violation of this section, the 24 court shall consider at least the following three factors: 25 (1) The prior record and the number of previous 26 violations. 27 (2) The net worth of the person. 28 (3) The size and amount of the contract involved. 29 (g) Civil action not barred.--A conviction or civil penalty 30 imposed under this section shall not bar a government agency 19970S0005B0228 - 117 -
1 from pursuing additional civil action and administrative 2 sanctions. 3 (h) Limitation on prosecution.--No criminal prosecution 4 under this section shall be brought against a person who has 5 been previously charged by information or indictment with a 6 criminal violation of the Federal antitrust laws, based upon the 7 same allegedly unlawful conduct upon which a criminal 8 prosecution under this chapter could be based, where jeopardy 9 has attached under the Federal prosecution. 10 § 4504. Civil action and damages. 11 (a) Government agency to have right of action.--Any 12 government agency entering into a contract which is or has been 13 the subject of activities prohibited by section 4503 (relating 14 to prohibited activities) shall have a right of action against 15 the participants in the prohibited activities to recover 16 damages. 17 (b) Options.--The government agency shall have the option to 18 proceed jointly and severally in a civil action against any one 19 or more of the participants for recovery of the full amount of 20 the damages. There shall be no right to contribution among 21 participants not named defendants by the government agency. 22 (c) Measure of damages.--The measure of damages recoverable 23 under this section shall be the actual damages, which damages 24 shall be trebled plus the cost of suit, including reasonable 25 attorney fees. 26 (d) When cause of action arises.--The cause of action shall 27 arise at the time the government agency which entered into the 28 contract discovered, or should have discovered, the conduct 29 amounting to the unlawful offense. The action shall be brought 30 within four years of the date that the cause of action arose. No 19970S0005B0228 - 118 -
1 civil action shall be maintained after the expiration of ten 2 years from the date the contract was signed by the parties. 3 (e) Conviction to be dispositive of liability.--Any 4 conviction under section 4503 shall be dispositive of the 5 liability of the participants with the only issues for trial 6 being the fact and amount of damages. 7 § 4505. Suspension or debarment. 8 (a) Maximum suspension or debarment.--A government agency 9 proceeding under its rules and regulations to exclude or render 10 ineligible a person from participation in contracts or 11 subcontracts based upon conduct prohibited by section 4503 12 (relating to prohibited activities) shall limit the exclusion or 13 ineligibility to a period not to exceed the following: 14 (1) Three years in the case of a person found for the 15 first time to have engaged in this conduct. 16 (2) Five years in the case of a person found to have 17 engaged in this conduct for a second or subsequent time. 18 (b) Lists of persons excluded.--A government agency that 19 lets a contract by competitive bidding shall maintain a current 20 list of persons excluded or ineligible by reason of suspension 21 or debarment for participation in contracts or subcontracts with 22 that agency and shall furnish a copy of the list upon request to 23 a person considering the submission of a bid as a prime 24 contractor or as a subcontractor. 25 § 4506. Liability for increased costs. 26 A person who enters into a contract with a government agency, 27 either directly as a contractor or indirectly as a 28 subcontractor, during a period of suspension or debarment 29 imposed upon that person by that agency under its rules and 30 regulations shall be liable to the government agency and to an 19970S0005B0228 - 119 -
1 eligible contractor for increased costs incurred as a result of 2 replacing the excluded or ineligible person. 3 § 4507. Noncollusion affidavits. 4 Noncollusion affidavits may be required by rule or regulation 5 of any government agency for all persons. Any requirement for 6 noncollusion affidavits shall be set forth in the invitation to 7 bid. Failure of any person to provide a required affidavit to 8 the government agency may be grounds for disqualification of his 9 bid. Any required noncollusion affidavit shall state whether or 10 not the person has been convicted or found liable for any act 11 prohibited by Federal or State law in any jurisdiction involving 12 conspiracy or collusion with respect to bidding on any public 13 contract within the last three years. The form for any required 14 noncollusion affidavit shall provide that the person's statement 15 on the affidavit that he has been convicted or found liable for 16 any act prohibited by Federal or State law in any jurisdiction 17 involving conspiracy or collusion with respect to bidding on any 18 public contract within the last three years does not prohibit a 19 government agency from accepting a bid from or awarding a 20 contract to that person, but it may be grounds for 21 administrative suspension or debarment in the discretion of the 22 government agency under the rules and regulations of that agency 23 or, in the case of a government agency with no administrative 24 suspension or debarment regulations or procedures, may be 25 grounds for consideration on the question of whether the agency 26 should decline to award a contract to that person on the basis 27 of lack of responsibility. The provisions of this section are in 28 addition to and not in derogation of any other powers and 29 authority of any government agency. 30 § 4508. Responsibility for enforcement. 19970S0005B0228 - 120 -
1 (a) Criminal prosecution.--The Office of Attorney General 2 and the district attorneys of the several counties shall have 3 concurrent jurisdiction for the investigation and prosecution of 4 violations of section 4503 (relating to prohibited activities). 5 (b) Civil action.--The Office of Attorney General shall have 6 the authority to bring civil action under section 4504 (relating 7 to civil action and damages) on behalf of the Commonwealth and 8 any of its departments, boards, agencies, authorities and 9 commissions. Political subdivisions or municipal or other local 10 authorities or any officer or agency of any such political 11 subdivision or local authority shall have the right to bring a 12 civil action under section 4504. Upon the filing of a complaint, 13 a copy shall be served on the Attorney General. The plaintiff, 14 at any time, may request the Attorney General to act on its 15 behalf. The Attorney General, upon determining that it is in the 16 best interest of the Commonwealth, shall have the authority to 17 intervene on behalf of the Commonwealth in these actions. 18 § 4509. Investigation. 19 (a) Required attendance.--Whenever the Office of Attorney 20 General believes that a person may be in possession, custody or 21 control of documentary material or may have information relevant 22 to the subject matter of a civil investigation for the purpose 23 of ascertaining whether a person is or has been engaged in a 24 violation of this chapter, the Attorney General may require the 25 attendance and testimony of witnesses and the production of 26 books, accounts, papers, records, documents and files relating 27 to the civil investigation. For this purpose, the Attorney 28 General or his representatives may sign subpoenas, administer 29 oaths or affirmations, examine witnesses and receive evidence 30 during the investigation. A request for information shall state 19970S0005B0228 - 121 -
1 the subject matter of the investigation, the conduct 2 constituting the alleged violation which is under investigation 3 and the provisions of this chapter applicable to the alleged 4 violation. A request for documentary material shall describe the 5 material to be produced with reasonable particularity so as to 6 fairly identify the documents demanded, provide a return date 7 within which the material is to be produced and identify the 8 member of the Attorney General's staff to whom the material 9 shall be given. In case of disobedience of a subpoena or the 10 contumacy of a witness appearing before the Attorney General or 11 his representative, the Attorney General or his representative 12 may invoke the aid of a court of record of this Commonwealth, 13 and the court may issue an order requiring the person subpoenaed 14 to obey the subpoena or to give evidence or to produce books, 15 accounts, papers, records, documents and files relative to the 16 matter in question. Failure to obey an order of the court may be 17 punished by the court as a contempt. 18 (b) Confidentiality.--No information or documentary material 19 produced under a demand under this section shall, unless 20 otherwise ordered by a court for good cause shown, be produced 21 for inspection or copying by, nor shall the contents be 22 disclosed to, a person other than the Attorney General or his 23 representative without the consent of the person who produced 24 the information or material. However, the Attorney General or 25 his representative shall disclose information or documentary 26 material produced under this section or information derived 27 therefrom to officials of a government agency affected by the 28 alleged violation, for use by that agency in connection with an 29 investigation or proceeding within its jurisdiction and 30 authority, upon the prior certification of an appropriate 19970S0005B0228 - 122 -
1 official of the agency that the information shall be maintained 2 in confidence other than use for official purposes. Under 3 reasonable terms and conditions as the Attorney General or his 4 representative shall prescribe, the documentary material shall 5 be available for inspection and copying by the person who 6 produced the material or a duly authorized representative of 7 that person. The Attorney General or his representative may use 8 the documentary material or information or copies as he 9 determines necessary in the civil enforcement of this chapter, 10 including presentation before any court. Material which contains 11 trade secrets or other highly confidential matter shall not be 12 presented except with the approval of the court in which a 13 proceeding is pending after adequate notice to the person 14 furnishing the material. 15 (c) Limitation on use.--No criminal prosecution under 16 section 4503 (relating to prohibited activities) may be brought 17 by either the Attorney General or a district attorney based 18 solely upon information or documents obtained in a civil 19 investigation under this section. 20 Section 2. Section 2310 of Title 1 is amended to read: 21 § 2310. Sovereign immunity reaffirmed; specific waiver. 22 Pursuant to section 11 of Article 1 of the Constitution of 23 Pennsylvania, it is hereby declared to be the intent of the 24 General Assembly that the Commonwealth, and its officials and 25 employees acting within the scope of their duties, shall 26 continue to enjoy sovereign immunity and official immunity and 27 remain immune from suit except as the General Assembly shall 28 specifically waive the immunity. When the General Assembly 29 specifically waives sovereign immunity, a claim against the 30 Commonwealth and its officials and employees shall be brought 19970S0005B0228 - 123 -
1 only in such manner and in such courts and in such cases as 2 directed by the provisions of Title 42 (relating to judiciary 3 and judicial procedure) or 62 (relating to procurement), unless 4 otherwise specifically authorized by statute. 5 Section 3. Section 763(a) of Title 42 is amended to read: 6 § 763. Direct appeals from government agencies. 7 (a) General rule.--Except as provided in subsection (c), the 8 Commonwealth Court shall have exclusive jurisdiction of appeals 9 from final orders of government agencies in the following cases: 10 (1) All appeals from Commonwealth agencies under 11 Subchapter A of Chapter 7 of Title 2 (relating to judicial 12 review of Commonwealth agency action) or otherwise and 13 including appeals from the Board of Claims, the Environmental 14 Hearing Board, the Pennsylvania Public Utility Commission, 15 the Unemployment Compensation Board of Review and from any 16 other Commonwealth agency having Statewide jurisdiction. 17 (2) All appeals jurisdiction of which is vested in the 18 Commonwealth Court by any statute hereafter enacted. 19 * * * 20 Section 4. This act is intended to provide a complete and 21 exclusive procedure to govern the procurement by Commonwealth 22 agencies of supplies, services and construction, including the 23 disposal of surplus supplies. 24 Section 5. The terms of office of the present members of the 25 selection committee appointed pursuant to section 2401.1(19) of 26 the act of April 9, 1929 (P.L.177, No.175), known as The 27 Administrative Code of 1929, repealed by this act, shall not be 28 affected by 62 Pa.C.S. § 905(d). 29 Section 6. (a) The following acts and parts of acts are 30 repealed: 19970S0005B0228 - 124 -
1 Act of June 25, 1895 (P.L.269, No.182), entitled "An act 2 providing that none but citizens of the United States shall be 3 employed in any capacity in the erection, enlargement or 4 improvement of any public building or public work within this 5 Commonwealth." 6 Sections 478, 2401.1(19), 2403(b)(c) and (g), 2405, 2408(11), 7 2409, 2409.1, 2410, 2412 and 2413 of the act of April 9, 1929 8 (P.L.177, No.175), known as The Administrative Code of 1929. 9 Section 1809 of the act of June 24, 1931 (P.L.1206, No.331), 10 known as The First Class Township Code. 11 Section 808 of the act of May 1, 1933 (P.L.103, No.69), known 12 as The Second Class Township Code. 13 Act of July 18, 1935 (P.L.1173, No.382), entitled "An act to 14 prohibit discrimination on account of race, creed or color in 15 employment under contracts for public buildings or public 16 works." 17 Act of July 19, 1935 (P.L.1321, No.414), entitled "An act 18 requiring specifications for the construction, alteration, or 19 repair of public works of the Commonwealth, county, 20 municipality, or other subdivisions of the Commonwealth, to 21 contain a provision that the laborers or mechanics employed 22 thereon shall have been residents of this Commonwealth for at 23 least ninety days prior to their employment; and prescribing 24 penalties." 25 Act of April 12, 1945 (P.L.220, No.99), entitled "An act 26 authorizing the Commonwealth and any administrative department, 27 boards, and commissions thereof acting through the Department of 28 Property and Supplies, and political subdivisions of the 29 Commonwealth, including municipal authorities, to enter into 30 contracts with the United States of America, or any agency 19970S0005B0228 - 125 -
1 thereof, for the purchase, lease, or other acquisition of 2 property, real or personal, offered for sale pursuant to the 3 Surplus Property Act of one thousand nine hundred forty-four, 4 without complying with any requirement of existing law as to 5 specifications, advertising, award of contract, and approval of 6 purchases by a State agency receiving competitive bids, or the 7 delivery of property purchased before payment therefor." 8 Sections 404 and 405.1 of the act of June 1, 1945 (P.L.1242, 9 No.428), known as the State Highway Law. 10 Act of June 10, 1947 (P.L.493, No.223), entitled "An act 11 further prescribing the bonds required of foreign corporations 12 contracting for public buildings, public works or projects." 13 Sections 754 and 755 of the act of March 10, 1949 (P.L.30, 14 No.14), known as the Public School Code of 1949. 15 Section 11 of the act of March 31, 1949 (P.L.372, No.34), 16 known as The General State Authority Act of one thousand nine 17 hundred forty-nine. 18 Act of May 5, 1965 (P.L.40, No.34), entitled "An act 19 authorizing the Commonwealth through the Department of Property 20 and Supplies and its duly authorized bureau or agents, to enter 21 into contracts with the United States of America or any agency 22 thereof, for the acquisition, acceptance, receipt, warehousing 23 and distribution of surplus property of the United States of 24 America pursuant to the 'Federal Property and Administrative 25 Services Act of 1949,' particularly section 203(j) and (k), as 26 amended, and Federal regulations appertaining thereto." 27 Section 1408 of the act of February 1, 1966 (1965 P.L.1656, 28 No.581), known as The Borough Code. 29 Act of July 23, 1968 (P.L.686, No.226), entitled "An act 30 equalizing trade practices in public works procurement; 19970S0005B0228 - 126 -
1 authorizing the purchase by the Commonwealth, its political 2 subdivisions, and all public agencies, of aluminum and steel 3 products produced in a foreign country, provided the foreign 4 country does not prohibit or discriminate against the 5 importation to, sale or use in the foreign country of supplies, 6 material or equipment manufactured in this Commonwealth; 7 establishing procedures for determining whether foreign 8 countries discriminate against supplies, materials or equipment 9 manufactured in this Commonwealth; and imposing penalties and 10 providing for relief for violation of this act." 11 Act of October 26, 1972 (P.L.1017, No.247), entitled "An act 12 relating to the prevention of environment pollution and the 13 preservation of public natural resources in construction 14 projects." 15 Act of March 3, 1978 (P.L.6, No.3), known as the Steel 16 Products Procurement Act. 17 Act of November 26, 1978 (P.L.1303, No.315), known as the 18 Public Facilities Concession Regulation Act. 19 Act of November 26, 1978 (P.L.1309, No.317), entitled "An act 20 regulating the awarding and execution of certain public 21 contracts; providing for contract provisions relating to the 22 retention, interest, and payment of funds payable under the 23 contracts; and repealing inconsistent acts." 24 Act of October 28, 1983 (P.L.176, No.45), known as the 25 Antibid-Rigging Act. 26 Act of April 4, 1984 (P.L.193, No.40), known as the Motor 27 Vehicle Procurement Act. 28 Act of November 28, 1986 (P.L.1465, No.146), known as the 29 Reciprocal Limitations Act. 30 (b) The following acts and parts of acts are repealed 19970S0005B0228 - 127 -
1 insofar as they relate to Commonwealth agencies as defined in 62 2 Pa.C.S. § 103: 3 Act of December 20, 1967 (P.L.869, No.385), known as the 4 Public Works Contractors' Bond Law of 1967. 5 Act of January 23, 1974 (P.L.9, No.4), entitled "An act 6 prescribing the procedure, after the opening of bids, for the 7 withdrawal of bids on certain public contracts, setting forth 8 the rights of the parties involved and providing penalties," 9 except insofar as the act applies to the leases of real 10 property. 11 Act of May 10, 1996 (P.L.153 No.29), known as the Guaranteed 12 Energy Savings Act. 13 (c) The following acts and parts of acts are repealed 14 insofar as they are inconsistent with this act: 15 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to 16 carry out the provisions of section twelve, article three, of 17 the constitution, relative to contracts for supplies for the 18 legislature and the various departments of the state 19 government." 20 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 21 regulating the time for advertising for and receiving proposals 22 for furnishing paper, cardboard, cuts, plates, and other 23 supplies for the use of the Commonwealth for executing the 24 public printing, and the time contracts for furnishing such 25 supplies shall run." 26 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 27 providing for and regulating the public printing and binding, 28 the editing for publication and the distribution of all 29 documents, reports, bulletins, and other publications for the 30 use of the Commonwealth, the several departments, boards, 19970S0005B0228 - 128 -
1 commissions, and other agencies engaged in the legislative, 2 judicial, and administrative work of the State Government; the 3 sale of waste paper; the appointment of a director and other 4 employes; and repealing inconsistent and conflicting 5 legislation." 6 Sections 507, 508, 510 and 511 of the act of April 9, 1929 7 (P.L.177, No.175), known as The Administrative Code of 1929. 8 Act of June 23, 1931 (P.L.1181, No.321), entitled "An act 9 authorizing persons, co-partnerships, associations, and 10 corporations, who, whether as sub-contractor or otherwise, have 11 furnished material or supplied or performed labor in connection 12 with any public work or improvement, to intervene in or 13 institute actions on certain bonds given to the Commonwealth or 14 to municipal corporations in connection with the performance of 15 public contracts; fixing the time within which such actions must 16 be brought, and the amounts recoverable therein; and providing 17 for distribution of amounts recovered; and prescribing 18 procedure." 19 Section 6 of the act of May 20, 1937 (P.L.728, No.193), 20 referred to as the Board of Claims Act only insofar as it is 21 inconsistent with the procedure provided for in 62 Pa.C.S. § 22 1712 regarding the resolution of a contract controversy by the 23 head of a purchasing agency. 24 Section 10 of the act of July 5, 1947 (P.L.1217, No.498), 25 known as the State Public School Building Authority Act. 26 Section 12 of the act of December 6, 1967 (P.L.678, No.318), 27 known as The Pennsylvania Higher Educational Facilities 28 Authority Act of 1967. 29 Section 4 of the act of November 20, 1968 (P.L.1075, No.329), 30 entitled "An act providing for the growth and development of 19970S0005B0228 - 129 -
1 noncommercial educational television; creating the Pennsylvania 2 Public Television Network Commission as an independent 3 commission and defining its powers and duties." 4 (d) Nothing in this act shall repeal, modify or supplant the 5 following acts and parts of acts: 6 Section 516 of the act of April 9, 1929 (P.L.177, No.175), 7 known as The Administrative Code of 1929. 8 Act of July 19, 1957 (P.L.1017, No.451), known as the State 9 Adverse Interest Act. 10 Act of February 11, 1976 (P.L.14, No.10), known as the 11 Pennsylvania Rural and Intercity Common Carrier Surface 12 Transportation Assistance Act. 13 (e) All other acts and parts of acts are repealed insofar as 14 they are inconsistent with this act. 15 Section 7. This act shall apply to contracts solicited or 16 entered into on or after the effective date of this act unless 17 the parties agree to its application to a contract solicited or 18 entered into prior to the effective date of this act. 19 Section 8. This act shall take effect in 180 days. L11L62JLW/19970S0005B0228 - 130 -