PRIOR PRINTER'S NOS. 228, 1100 PRINTER'S NO. 1478
No. 5 Session of 1997
INTRODUCED BY THOMPSON, LOEPER, GERLACH, TOMLINSON, SALVATORE, MUSTO, O'PAKE, ARMSTRONG, ROBBINS, WENGER, HART, RHOADES, MOWERY, WOZNIAK, HECKLER, MURPHY, MADIGAN, DELP, EARLL, CORMAN, LEMMOND AND SLOCUM, JANUARY 29, 1997
SENATOR LEMMOND, STATE GOVERNMENT, RE-REPORTED AS AMENDED, NOVEMBER 18, 1997
AN ACT 1 Amending Titles 62 (Procurement), 1 (General Provisions) and 42 2 (Judiciary and Judicial Procedure) of the Pennsylvania 3 Consolidated Statutes, adding provisions relating to 4 procurement; and making repeals. 5 TABLE OF CONTENTS 6 TITLE 62 7 PROCUREMENT 8 PART I. COMMONWEALTH PROCUREMENT CODE 9 Chapter 1. General Provisions 10 § 101. Short title of part. 11 § 102. Application of part. 12 § 103. Definitions. 13 § 104. General principles of law otherwise applicable. 14 § 105. Determinations. 15 § 106. Public access to procurement information. 16 § 107. Reciprocal limitations. 17 § 108. Recycled materials.
1 Chapter 3. Procurement Organization 2 Subchapter A. Organization of Public Procurement 3 § 301. Procurement responsibility. 4 Subchapter B. Procurement Policy 5 § 311. Powers and duties. 6 § 312. Procurement regulations. 7 Subchapter C. Powers and Duties of Department 8 § 321. Powers and duties. 9 § 322. Specific construction powers, duties and procedures. 10 Subchapter D. Powers and Duties of the Board 11 of Commissioners of Public Grounds and 12 Buildings and the Office of the Budget 13 § 326. Board of Commissioners of Public Grounds and Buildings. 14 § 327. Office of the Budget. 15 Subchapter E. Coordination, Training and Education 16 § 331. Collection of data concerning public procurement. 17 § 332. Advisory groups. 18 Chapter 5. Source Selection and Contract Formation 19 Subchapter A. Definitions 20 § 501. Definitions. 21 Subchapter B. Methods of Source Selection 22 § 511. Methods of source selection. 23 § 512. Competitive sealed bidding. 24 § 513. Competitive sealed proposals. 25 § 514. Small procurements. 26 § 515. Sole source procurement. 27 § 516. Emergency procurement. 28 § 517. Multiple awards. 29 § 518. Competitive selection procedures for certain services. 30 § 519. Selection procedure for insurance and notary bonds. 19970S0005B1478 - 2 -
1 § 520. Supplies manufactured by, and services performed by, 2 persons with disabilities. 3 Subchapter C. Cancellation of Invitations for Bids or 4 Requests for Proposals 5 § 521. Cancellation of invitations for bids or requests for 6 proposals. 7 Subchapter D. Qualifications and Duties 8 § 531. Debarment or suspension. 9 § 532. Prequalification of bidders and offerors. 10 § 533. Security and performance bonds. 11 § 534. Cost or pricing data. 12 § 535. PRINTING. <-- 13 Subchapter E. Types of Contracts 14 § 541. Approval of accounting system. 15 § 542. Multiterm contracts. 16 § 543. Effective contracts. 17 Subchapter F. Inspection of Plant and Audit of Records 18 § 551. Right to inspect plant. 19 § 552. Right to audit records. 20 Subchapter G. Determinations and Reports 21 § 561. Finality of determinations. 22 § 562. Anticompetitive practices. 23 § 563. Retention of procurement records. 24 § 564. Record of certain actions. 25 Chapter 7. (Reserved) 26 Chapter 9. Procurement of Construction and Design 27 Professional Services 28 § 901. Definitions. 29 § 902. Bid or proposal security. 30 § 903. Contract performance and payment bonds. 19970S0005B1478 - 3 -
1 § 904. Copies of bonds. 2 § 905. Procurement of design professional services. 3 Chapter 11. (Reserved) 4 Chapter 13. (Reserved) 5 Chapter 15. Supply Management 6 § 1501. Definitions. 7 § 1502. Supply management regulations. 8 § 1503. Proceeds from sale or disposal of surplus supplies. 9 § 1504. EXCEPTION. <-- 10 Chapter 17. Legal and Contractual Remedies 11 Subchapter A. General Provisions 12 § 1701. Definitions. 13 § 1702. Sovereign immunity. 14 Subchapter B. Prelitigation Resolution of Controversies 15 § 1711. Authority to resolve protests of solicitations or 16 awards. 17 § 1712. Authority to resolve contract and breach of contract 18 controversies. 19 Subchapter C. Board of Claims 20 § 1721. Function of Board of Claims. 21 § 1722. (Reserved). 22 § 1723. (Reserved). 23 § 1724. (Reserved). 24 § 1725. Hearings, decisions and awards. 25 § 1726. Appeals. 26 Subchapter D. Solicitations or Awards in Violation of Law 27 § 1741. Applicability. 28 § 1742. Remedies prior to execution of contract. 29 § 1743. Remedies after execution of contract. 30 Subchapter E. Interest 19970S0005B1478 - 4 -
1 § 1751. Interest. 2 Chapter 19. Intergovernmental Relations 3 § 1901. Definitions. 4 § 1902. Cooperative purchasing authorized. 5 § 1903. Sale, acquisition or use of supplies by a public 6 procurement unit. 7 § 1904. Cooperative use of supplies or services. 8 § 1905. Joint use of facilities. 9 § 1906. Supply of personnel, information and technical 10 services. 11 § 1907. Use of payments received by a supplying public 12 procurement unit. 13 § 1908. Compliance of public procurement units. 14 § 1909. Review of procurement requirements. 15 § 1910. Contract controversies. 16 § 1911. IMMUNITY. <-- 17 § 1912. INVESTMENT MANAGEMENT AGREEMENTS. 18 Chapter 21. Small and Disadvantaged Businesses 19 § 2101. Policy. 20 § 2102. Definitions. 21 § 2103. Regulations. 22 § 2104. Duties of department. 23 § 2105. Bonding and progress payments. 24 § 2106. Business assistance offices. 25 § 2107. Report to General Assembly. 26 § 2108. Compliance with Federal requirements. 27 Chapter 23. Ethics in Public Contracting 28 Subchapter A. General Policy and Standards 29 § 2301. Policy. 30 § 2302. General standards of ethical conduct. 19970S0005B1478 - 5 -
1 § 2303. Reporting of breaches of ethical standards.
2 Subchapter B. Specific Standards
3 § 2311. Bonds.
4 PART II. GENERAL PROCUREMENT PROVISIONS
5 Chapter 31. General Provisions
6 § 3101. Application of part.
7 § 3102. Definitions.
8 Chapter 33. Prevention of Environmental Pollution
9 § 3301. Invitations for bids and requests for proposals.
10 § 3302. Additional work.
11 Chapter 35. (Reserved)
12 Chapter 37. Contract Clauses and Preference Provisions
13 Subchapter A. Labor
14 § 3701. Contract provisions prohibiting discrimination.
15 § 3702. Contract provision requiring residents to be employed. <--
16 Subchapter B. Steel Products
17 § 3711. Short title of subchapter and general provisions.
18 § 3712. Definitions.
19 § 3713. Requirement of contract provision.
20 § 3714. Payments under contracts.
21 Subchapter C. Trade Practices
22 § 3721. Short title of subchapter and general provisions.
23 § 3722. Definitions.
24 § 3723. Unlawful acts.
25 § 3724. Preference for aluminum and steel products made in
26 United States.
27 § 3725. Requirement to list discriminating countries.
28 § 3726. Procedure to determine discrimination.
29 § 3727. Foreign registry docket.
30 § 3728. Aluminum or steel products from a country listed on
19970S0005B1478 - 6 -
1 foreign registry docket. 2 Subchapter D. Motor Vehicles 3 § 3731. Short title of subchapter and general provisions. 4 § 3732. Definitions. 5 § 3733. Police power. 6 § 3734. Contract provisions. 7 § 3735. Payment under contract and action to recover 8 unauthorized payments. 9 § 3736. Penalty. 10 Subchapter E. Used Oil Products 11 § 3741. Preference. 12 Subchapter F. Guaranteed Energy Savings Contracts 13 § 3751. Definitions. 14 § 3752. Selection process. 15 § 3753. Award of single contract. 16 Chapter 39. Construction Contracts Over $50,000 17 Subchapter A. Preliminary Provisions 18 § 3901. Application and purpose of chapter. 19 § 3902. Definitions. 20 Subchapter B. General Provisions 21 § 3911. Time for awarding contract. 22 § 3912. Time for executing contract. 23 § 3913. Release of successful bidder. 24 Subchapter C. Retainage. 25 § 3921. Retainage. 26 § 3922. Payment of retainage to subcontractors. 27 Subchapter D. Prompt Payment Schedules 28 § 3931. Performance by contractor or subcontractor. 29 § 3932. Government agency's progress payment obligations. 30 § 3933. Contractors' and subcontractors' payment obligations. 19970S0005B1478 - 7 -
1 § 3934. Withholding of payment for good faith claims. 2 § 3935. Penalty and attorney fees. 3 § 3936. Contracts involving Federal aid. 4 § 3937. Certain provisions unenforceable. 5 § 3938. Applicability. 6 § 3939. Claims by innocent parties. 7 Subchapter E. Substantial/final Payment 8 § 3941. Substantial/final payment under contract. 9 § 3942. Arbitration. 10 Chapter 41. Purchase of Surplus Federal Property 11 § 4101. Contracts with United States. 12 § 4102. Bids and down payments. 13 Chapter 43. Public Facilities Concessions 14 § 4301. Short title of chapter and general provisions. 15 § 4302. Definitions. 16 § 4303. Terms of contracts. 17 Chapter 45. Antibid-Rigging 18 § 4501. Short title of chapter. 19 § 4502. Definitions. 20 § 4503. Prohibited activities. 21 § 4504. Civil action and damages. 22 § 4505. Suspension or debarment. 23 § 4506. Liability for increased costs. 24 § 4507. Noncollusion affidavits. 25 § 4508. Responsibility for enforcement. 26 § 4509. Investigation. 27 TITLE 62 28 PROCUREMENT 29 Part 30 I. Commonwealth Procurement Code 19970S0005B1478 - 8 -
1 II. General Procurement Provisions 2 PART I 3 COMMONWEALTH PROCUREMENT CODE 4 Chapter 5 1. General Provisions 6 3. Procurement Organization 7 5. Source Selection and Contract Formation 8 7. (Reserved) 9 9. Procurement of Construction and Design Professional 10 Services 11 11. (Reserved) 12 13. (Reserved) 13 15. Supply Management 14 17. Legal and Contractual Remedies 15 19. Intergovernmental Relations 16 21. Small and Disadvantaged Businesses 17 23. Ethics in Public Contracting 18 The General Assembly of the Commonwealth of Pennsylvania 19 hereby enacts as follows: 20 Section 1. Title 62 of the Pennsylvania Consolidated 21 Statutes is amended by adding parts to read: 22 CHAPTER 1 23 GENERAL PROVISIONS 24 Sec. 25 101. Short title of part. 26 102. Application of part. 27 103. Definitions. 28 104. General principles of law otherwise applicable. 29 105. Determinations. 30 106. Public access to procurement information. 19970S0005B1478 - 9 -
1 107. Reciprocal limitations.
2 108. Recycled materials.
3 § 101. Short title of part.
4 This part shall be known and may be cited as the Commonwealth
5 Procurement Code.
6 § 102. Application of part.
7 (a) Application to Commonwealth procurement.--This part
8 applies to every expenditure of funds, other than the investment
9 of funds, by Commonwealth agencies under any contract,
10 irrespective of their source, including Federal assistance
11 moneys except as specified in section 2108 (relating to
12 compliance with Federal requirements). This part does not apply
13 to grants or NOR DOES IT APPLY TO contracts between Commonwealth <--
14 agencies or between the Commonwealth and its political
15 subdivisions or other governments except as provided in Chapter
16 19 (relating to intergovernmental relations). Nothing in this
17 part or in accompanying regulations shall prevent any
18 Commonwealth agency or political subdivision from complying with
19 the terms and conditions of any grant, gift, bequest or
20 cooperative agreement.
21 (b) Application to disposal of Commonwealth supplies.--This
22 part applies to the disposal of supplies of Commonwealth
23 agencies.
24 (c) Application to local agencies.--Any political
25 subdivision or other local public agency may specifically or by
26 reference adopt all or any part of this part and its
27 accompanying regulations.
28 (d) Application to General Assembly and unified judicial
29 system.--The General Assembly and its agencies and the unified
30 judicial system and its agencies may use the department as its
19970S0005B1478 - 10 -
1 purchasing agency for the purchase of supplies under this part
2 and may use the department to dispose of surplus supplies under
3 Chapter 15 (relating to supply management).
4 (E) APPLICATION TO CERTAIN ENTITIES.--NOTHING IN THIS PART <--
5 SHALL APPLY TO THE ENTITY CREATED BY THE ACT OF AUGUST 7, 1963
6 (P.L.549, NO.290), REFERRED TO AS THE PENNSYLVANIA HIGHER
7 EDUCATION ASSISTANCE AGENCY ACT.
8 § 103. Definitions.
9 Subject to additional definitions contained in subsequent
10 provisions of this part which are applicable to specific
11 provisions of this part, the following words and phrases when
12 used in this part shall have the meanings given to them in this
13 section unless the context clearly indicates otherwise:
14 "Change order." A written order signed by the contracting
15 officer directing the contractor to make changes which the
16 changes clause of the contract authorizes the contracting
17 officer to order. The change order may be either with the
18 consent of the contractor or a unilateral order by the
19 contracting officer.
20 "Commonwealth agency." An executive agency, an independent
21 agency or an instrumentality A STATE-AFFILIATED ENTITY. <--
22 "Construction." The process of building, altering,
23 repairing, improving or demolishing any public structure or
24 building or other public improvements of any kind to any public
25 real property. The term does not include the routine operation
26 or maintenance of existing structures, buildings or real
27 property.
28 "Contract." A type of written agreement, regardless of what
29 it may be called, for the procurement or disposal of supplies,
30 services or construction.
19970S0005B1478 - 11 -
1 "Contract modification." A written alteration in
2 specifications, delivery point, rate of delivery, period of
3 performance, price, quantity or other provisions of any contract
4 accomplished by mutual action of the parties to the contract.
5 "Contracting officer." A person authorized to enter into and
6 administer contracts and make written determinations with
7 respect to contracts.
8 "Department." The Department of General Services of the
9 Commonwealth.
10 "Employee." An individual drawing a salary or wages from a
11 Commonwealth agency, whether elected or not, and any
12 noncompensated individual performing personal services for any
13 Commonwealth agency.
14 "Executive agency." The Governor and the departments,
15 boards, commissions, authorities and other officers and agencies
16 of the Commonwealth. The term does not include any court or
17 other officer or agency of the unified judicial system, the
18 General Assembly and its officers and agencies or any
19 independent agency or instrumentality STATE-AFFILIATED ENTITY. <--
20 "FIRM, FIXED-PRICE CONTRACT." A CONTRACT WHERE THE TOTAL <--
21 AMOUNT TO BE PAID TO THE CONTRACTOR IS FIXED AND IS NOT SUBJECT
22 TO ADJUSTMENT BY REASON OF THE COST EXPERIENCE OF THE
23 CONTRACTOR. THE TERM INCLUDES CONTRACTS WHERE THE UNIT PRICE IS
24 SET BUT THE TOTAL PRICE VARIES BECAUSE ACTUAL QUANTITIES
25 PURCHASED DEVIATE FROM THE QUANTITIES ESTIMATED TO BE PURCHASED.
26 THE TERM ALSO INCLUDES CONTRACTS WHERE THE PRICE MAY BE ADJUSTED
27 IN ACCORDANCE WITH A CONTRACTUALLY ESTABLISHED PRICE ADJUSTMENT
28 PROVISION WHICH IS NOT BASED UPON THE CONTRACTOR'S COSTS.
29 "Grant." The furnishing of assistance by the Federal
30 Government, Commonwealth or any person, whether financial or
19970S0005B1478 - 12 -
1 otherwise, to any person to support a program authorized by law. 2 The term does not include an award whose primary purpose is to 3 procure FOR THE GRANTOR an end product, whether in the form of <-- 4 supplies, services or construction. A contract resulting from 5 such an award is not a grant but a procurement contract. 6 "Independent agency." Boards, commissions and other agencies 7 and officers of the Commonwealth which are not subject to the 8 policy supervision and control of the Governor. The term does 9 not include any instrumentality STATE-AFFILIATED ENTITY, any <-- 10 court or other officer or agency of the unified judicial system 11 or, the General Assembly and its officers and agencies, ANY <-- 12 STATE-RELATED INSTITUTION, POLITICAL SUBDIVISION OR ANY LOCAL, 13 REGIONAL OR METROPOLITAN TRANSPORTATION AUTHORITY. 14 "Instrumentality." Commonwealth authorities and Commonwealth <-- 15 instrumentalities, including, but not limited to, the 16 Pennsylvania Turnpike Commission, the Pennsylvania Higher 17 Education Assistance Agency, the Pennsylvania Housing Finance 18 Agency, the Pennsylvania Municipal Retirement System, the 19 Pennsylvania Infrastructure Investment Authority, the State 20 Public School Building Authority, the Pennsylvania Higher 21 Educational Facilities Authority and the State System of Higher 22 Education. The term does not include any court or other officer 23 or agency of the unified judicial system, the General Assembly 24 and its officers and agencies, or any State-related institution 25 or political subdivisions. 26 "Policy statement." Any document, except an adjudication, 27 regulation or privileged communication prepared by a 28 Commonwealth agency which sets forth substantive or procedural 29 personal or property rights, privileges, immunities, duties, 30 liabilities or obligations of the public or any person, 19970S0005B1478 - 13 -
1 including any document interpreting or implementing any statute 2 enforced or administered by the agency. 3 "Procurement." Buying, purchasing, renting, leasing, 4 licensing or otherwise acquiring any supplies, services or 5 construction. The term also includes all functions that pertain 6 to the obtaining of any supply, service or construction, 7 including description of requirements, selection and 8 solicitation of sources, preparation and award of contract and 9 all phases of contract administration. 10 "Purchasing agency." A Commonwealth agency authorized by 11 this part or by other law to enter into contracts FOR ITSELF OR <-- 12 AS THE AGENT OF ANOTHER COMMONWEALTH AGENCY. WHEN PURCHASING FOR 13 ANOTHER COMMONWEALTH AGENCY, THE PURCHASING AGENCY ACTS ON 14 BEHALF OF THE PRINCIPAL WHICH NEEDS THE SUPPLIES, SERVICES AND 15 CONSTRUCTION AND SHALL COORDINATE AND COOPERATE WITH THAT 16 AGENCY. 17 "Regulation." A regulation as defined in 45 Pa.C.S. § 501 18 (relating to definitions). 19 "Services." The furnishing of labor, time or effort by a 20 contractor not involving the delivery of a specific end product 21 other than drawings, specifications or reports which are merely 22 incidental to the required performance. The term does not 23 include employment agreements, collective bargaining agreements 24 or agreements with litigation consultants. THE TERM INCLUDES <-- 25 UTILITY SERVICES AND THOSE SERVICES FORMERLY PROVIDED BY PUBLIC 26 UTILITIES SUCH AS ELECTRICAL, TELEPHONE, WATER AND SEWAGE 27 SERVICE. 28 "Specification." A description of the physical or functional 29 characteristics or the nature of a supply, service or 30 construction item, including a description of any requirement 19970S0005B1478 - 14 -
1 for inspecting, testing or preparing a supply, service or 2 construction item for delivery. 3 "STATE-AFFILIATED ENTITY." A COMMONWEALTH AUTHORITY OR A <-- 4 COMMONWEALTH ENTITY. THE TERM INCLUDES THE PENNSYLVANIA TURNPIKE 5 COMMISSION, THE PENNSYLVANIA HOUSING FINANCE AGENCY, THE 6 PENNSYLVANIA MUNICIPAL RETIREMENT SYSTEM, THE PENNSYLVANIA 7 INFRASTRUCTURE INVESTMENT AUTHORITY, THE STATE PUBLIC SCHOOL 8 BUILDING AUTHORITY, THE PENNSYLVANIA HIGHER EDUCATIONAL 9 FACILITIES AUTHORITY AND THE STATE SYSTEM OF HIGHER EDUCATION. 10 THE TERM DOES NOT INCLUDE ANY COURT OR OTHER OFFICER OR AGENCY 11 OF THE UNIFIED JUDICIAL SYSTEM, THE GENERAL ASSEMBLY AND ITS 12 OFFICERS AND AGENCIES, ANY STATE-RELATED INSTITUTION, POLITICAL 13 SUBDIVISION OR ANY LOCAL, REGIONAL OR METROPOLITAN 14 TRANSPORTATION AUTHORITY. 15 "State-related institution." The Pennsylvania State 16 University, the University of Pittsburgh, Lincoln University or 17 Temple University. 18 "STATEWIDE REQUIREMENTS CONTRACT." A CONTRACT ENTERED INTO <-- 19 BY THE DEPARTMENT OF GENERAL SERVICES AS PURCHASING AGENCY WHICH 20 COVERS THE ANNUAL, SEMIANNUAL OR QUARTERLY CONTRACT REQUIREMENTS 21 OF ALL COMMONWEALTH AGENCIES AND ALLOWS THE AGENCIES TO ORDER 22 NEEDED SUPPLIES DIRECTLY FROM THE CONTRACTOR. 23 "Supplies." Any property, including, but not limited to, 24 equipment, materials, printing, insurance and leases of and 25 installment purchases of tangible or intangible personal 26 property. The term does not include real property or leases of 27 real property. 28 "Using agency." A Commonwealth agency which utilizes any 29 supplies, services or construction procured under this part. 30 § 104. General principles of law otherwise applicable. 19970S0005B1478 - 15 -
1 Unless displaced by the particular provisions of this part, 2 existing Pennsylvania law, including Title 13 (relating to 3 commercial code), shall supplement the provisions of this part. 4 § 105. Determinations. 5 Written determinations required by this part shall be 6 retained in the appropriate official contract file. 7 § 106. Public access to procurement information. 8 Procurement information shall be a public record to the <-- 9 extent provided in the act of June 21, 1957 (P.L.390, No.212), 10 referred to as the Right-to-Know Law, and shall be available to 11 the public as provided in that act. 12 EXCEPT AS PROVIDED IN SECTION 512(D) (RELATING TO COMPETITIVE <-- 13 SEALED BIDDING), ANY DOCUMENTS CREATED BY OR PROVIDED TO ANY 14 COMMONWEALTH AGENCY FOR ANY PROCUREMENT SHALL BE SUBJECT TO 15 INSPECTION AND COPYING ONLY TO THE EXTENT ALREADY REQUIRED UNDER 16 THE ACT OF JUNE 21, 1957 (P.L.390, NO.212), REFERRED TO AS THE 17 RIGHT-TO-KNOW LAW. 18 § 107. Reciprocal limitations. 19 (a) Short title of section.--This section shall be known and 20 may be cited as the Reciprocal Limitations Act. 21 (b) Legislative findings.--It is hereby determined by the 22 General Assembly to reaffirm the legislative findings contained 23 in the act of November 28, 1986 (P.L.1465, No.146), known as the 24 Reciprocal Limitations Act, and codified in this section: 25 (1) The award of contracts to the lowest responsible 26 bidder generally provides for the most economical procurement 27 of supplies and construction. 28 (2) In some cases, award to the lowest responsible 29 bidder may not be the most economical and practicable when 30 the best interests of the Commonwealth are concerned. 19970S0005B1478 - 16 -
1 (3) Some states apply a preference favoring in-state 2 supplies or bidders or they apply a prohibition against the 3 use of out-of-State supplies or bidders. 4 (4) The application of this preference or prohibition by 5 other states diminishes or eliminates opportunities for 6 bidders and manufacturers who reside in this Commonwealth to 7 obtain construction contracts from or to sell supplies to 8 states that have this preference, thereby resulting in the 9 loss of business for resident bidders and manufacturers. 10 Therefore, in order to offset or counteract the 11 discriminatory practices of other states, discourage other 12 states from applying a preference and ultimately to aid 13 employment, help business and industry located in this 14 Commonwealth, attract new business and industry to this 15 Commonwealth and provide additional tax revenue both from 16 those receiving contracts and those employed by contractors, 17 the General Assembly hereby declares that it is the policy of 18 this Commonwealth to respond in like manner against those 19 states that apply preferences or prohibitions by giving a 20 similar offsetting preference to residents in this 21 Commonwealth and bidders offering supplies manufactured in 22 this Commonwealth and by prohibiting the purchase or use of 23 certain supplies, in accordance with the provisions of this 24 section. 25 (c) Preference for supplies.--In all procurements of 26 supplies exceeding the amount established by the department for 27 small procurements under section 514 (relating to small 28 procurements), all Commonwealth agencies shall give preference 29 to those bidders or offerors offering supplies produced, 30 manufactured, mined, grown or performed in this Commonwealth as 19970S0005B1478 - 17 -
1 against those bidders or offerors offering supplies produced, 2 manufactured, mined, grown or performed in any state that gives 3 or requires a preference to supplies produced, manufactured, 4 mined, grown or performed in that state. The amount of the 5 preference shall be equal to the amount of the preference 6 applied by the other state for that particular supply. 7 (d) Preference for resident bidders or offerors.--When a 8 contract for construction or supplies exceeding the amount 9 established by the department for small procurements under 10 section 514 is to be awarded, a resident bidder or offeror shall 11 be granted a preference as against a nonresident bidder or 12 offeror from any state that gives or requires a preference to 13 bidders or offerors from that state. The amount of the 14 preference shall be equal to the amount of the preference 15 applied by the state of the nonresident bidder or offeror. 16 (e) Prohibition.--For public contracts exceeding the amount 17 established by the department for small procurements under 18 section 514, no Commonwealth agency shall specify for, use or 19 procure any supplies which are produced, manufactured, mined, 20 grown or performed in any state that prohibits the specification 21 for, use or procurement of these supplies in or on its public 22 buildings or other works when these supplies are not produced, 23 manufactured, mined, grown or performed in that state. 24 (f) Listing discriminating states.--The department shall 25 prepare a list of the states which apply a preference favoring 26 in-State supplies or bidders or offerors or a prohibition 27 against the use of out-of-State supplies or bidders or offerors 28 and shall publish the list in the Pennsylvania Bulletin. When a 29 state applies a new preference or prohibition, the department 30 shall publish that information in the Pennsylvania Bulletin as 19970S0005B1478 - 18 -
1 an addition to the original list. 2 (g) Inclusion in invitation for bids or request for 3 proposals.--In all invitations for bids and requests for 4 proposals for the procurement of supplies exceeding the amount 5 established by the department for small procurements under 6 section 514 all Commonwealth agencies shall include a list of 7 all the states that have been found by the department to have 8 applied a preference favoring in-State supplies, bidders or 9 offerors and the amount of the preference. All invitations for 10 bids, requests for proposals and notices issued for the purpose 11 of securing bids or proposals for public contracts as issued by 12 any Commonwealth agency exceeding the amount established by the 13 department for small procurements under section 514 shall 14 include a list of all states that have been found by the 15 department to have applied a preference for in-State bidders or 16 offerors and the amount of the preference. All invitations for 17 bids, requests for proposals and notices issued for the purpose 18 of securing bids or proposals for contracts for construction or 19 supplies as issued by any Commonwealth agency exceeding the 20 amount established by the purchasing agency for small 21 procurements under section 514 shall also include a list of all 22 states that apply a prohibition against certain supplies and 23 shall inform potential bidders or offerors that they are 24 prohibited from using supplies from those states. If a bid or 25 proposal discloses that the bidder or offeror is offering 26 supplies from a state which prohibits the use of out-of-State 27 supplies, the bid or proposal shall be rejected. 28 (h) Federal funds.--The provisions of this section shall not 29 be applicable when the application of this section may 30 jeopardize the receipt of Federal funds. 19970S0005B1478 - 19 -
1 (i) Waiver.--The provisions of this section may be waived 2 when the head of the purchasing agency determines in writing 3 that it is in the best interests of the Commonwealth. 4 (j) Definitions.--As used in this section, the following 5 words and phrases shall have the meanings given to them in this 6 subsection: 7 "Resident bidder or offeror." A person, partnership, 8 corporation or other business entity authorized to transact 9 business in this Commonwealth and having a bona fide 10 establishment for transacting business in this Commonwealth at 11 which it was transacting business on the date when bids or 12 proposals for the public contract were first solicited. 13 § 108. Recycled materials. 14 (a) Commonwealth agency review.--All Commonwealth agencies 15 shall review their procurement procedures and specifications in 16 accordance with section 1504 of the act of July 28, 1988 17 (P.L.556, No.101), known as the Municipal Waste Planning, 18 Recycling and Waste Reduction Act. 19 (b) Preference for recycled content.--For contracts 20 exceeding the amount established by the department for small 21 procurements under section 514 (relating to small procurements), 22 the contracting officer shall comply with section 1505 of the 23 Municipal Waste Planning, Recycling and Waste Reduction Act 24 regarding a preference for bids containing a minimum percentage 25 of recycled content for the supply subject to the bid. 26 CHAPTER 3 27 PROCUREMENT ORGANIZATION 28 Subchapter 29 A. Organization of Public Procurement 30 B. Procurement Policy 19970S0005B1478 - 20 -
1 C. Powers and Duties of Department 2 D. Powers and Duties of the Board of Commissioners of 3 Public Grounds and Buildings and the Office of the Budget 4 E. Coordination, Training and Education 5 SUBCHAPTER A 6 ORGANIZATION OF PUBLIC PROCUREMENT 7 Sec. 8 301. Procurement responsibility. 9 § 301. Procurement responsibility. 10 (a) General organization.--Formulation of procurement policy 11 governing the procurement, management, control and disposal of 12 supplies, services and construction for executive and 13 independent agencies shall be the responsibility of the 14 department as provided for in Subchapter B (relating to 15 procurement policy). The procurement and supervision of the 16 procurement of supplies, services and construction for executive 17 agencies and those independent agencies for which the department 18 acts as purchasing agency shall be the responsibility of the 19 department as provided for in Subchapter C (relating to powers 20 and duties of department). 21 (b) Application to independent agencies.--Except as 22 otherwise specifically provided by law and this section, 23 independent agencies shall use the department as their 24 purchasing agency for the procurement of supplies or 25 construction. INDEPENDENT AGENCIES SHALL HAVE THE AUTHORITY TO <-- 26 PROCURE THEIR OWN SERVICES. However, when any independent agency 27 acts as its own purchasing agency it shall use the procedures 28 provided in this part for any procurement of supplies, services 29 or construction. 30 (c) Exceptions for executive and independent agencies.--The 19970S0005B1478 - 21 -
1 following supplies, services and construction need not be
2 procured through the department, nor shall the procurement
3 policy be established by the department, but shall nevertheless
4 be procured by the appropriate purchasing agency, subject to the
5 requirements of this part:
6 (1) Bridge, highway, dam, airport (except vertical <--
7 construction), railroad or other heavy or specialized <--
8 construction including:
9 (i) The construction of facilities and improvements
10 by the Department of Conservation and Natural Resources
11 in State parks and State forests.
12 (ii) Construction activities, excluding buildings,
13 solely within the expertise of the Department of
14 Environmental Protection, including, but not limited to,
15 mine reclamation, oil and gas well plugging, waste site
16 remediation, flood control and stream rehabilitation.
17 (2) Works of art, historic objects and documents for
18 acquisition and public exhibition.
19 (3) Published books, maps, periodicals and technical
20 pamphlets.
21 (4) Perishable food stuffs.
22 (5) THE PROCUREMENT OF SERVICES, THE RENTING OF <--
23 MACHINERY AND EQUIPMENT AND THE LICENSING OF SPECIALIZED
24 COMPUTER SOFTWARE BY THE OFFICE OF ATTORNEY GENERAL, THE
25 DEPARTMENT OF THE AUDITOR GENERAL AND THE TREASURY
26 DEPARTMENT.
27 (d) Application to instrumentalities.--Instrumentalities <--
28 STATE-AFFILIATED ENTITIES.--STATE-AFFILIATED ENTITIES may <--
29 formulate their own procurement policy governing the
30 procurement, management, control and disposal of supplies,
19970S0005B1478 - 22 -
1 services and construction and may act as their own purchasing 2 agency for the procurement of supplies, services and 3 construction, but they are required to use the procedures 4 provided in this part for such procurement. 5 SUBCHAPTER B 6 PROCUREMENT POLICY 7 Sec. 8 311. Powers and duties. 9 312. Procurement regulations. 10 § 311. Powers and duties. 11 Except as otherwise provided in this part, the department may 12 promulgate regulations governing the procurement, management, 13 control and disposal of any and all supplies, services and 14 construction to be procured by Commonwealth agencies. The 15 department shall consider and decide matters of policy within 16 the provisions of this part. The department may audit and 17 monitor the implementation of its regulations and the 18 requirements of this part. 19 § 312. Procurement regulations. 20 Regulations shall be promulgated by the department as 21 provided in 45 Pa.C.S. Part II (relating to publication and 22 effectiveness of Commonwealth documents) and by the appropriate 23 purchasing agencies for those matters contained in section 24 301(c) (relating to procurement responsibility). The department 25 may not delegate its power to promulgate regulations. No 26 regulation may change any commitment, right or obligation of any 27 Commonwealth agency or of a contractor under a contract in 28 existence on the effective date of the regulation. 29 SUBCHAPTER C 30 POWERS AND DUTIES OF DEPARTMENT 19970S0005B1478 - 23 -
1 Sec.
2 321. Powers and duties.
3 322. Specific construction powers, duties and procedures.
4 § 321. Powers and duties.
5 Except as otherwise specifically provided in this part, the
6 department shall have the following powers and duties:
7 (1) Procure or supervise the procurement of all
8 supplies, services and construction needed by executive
9 agencies and those independent agencies for which the
10 department acts as purchasing agency. Procurement authority
11 may be delegated in writing by the Secretary of General
12 Services.
13 (2) Exercise general supervision and control over all
14 inventories of supplies belonging to executive agencies.
15 (3) Sell, trade or otherwise dispose of surplus supplies
16 belonging to executive or independent agencies.
17 (4) Oversee COORDINATE programs of executive and <--
18 independent agencies for the inspection, testing and
19 acceptance of supplies and construction TO ENSURE <--
20 AVAILABILITY OF FACILITIES AND TO AVOID A DUPLICATION OF
21 FUNCTIONS.
22 (5) Establish and maintain a central office where
23 businesses operating in this Commonwealth may obtain
24 information pertaining to the procurement needs of
25 Commonwealth agencies.
26 (6) Participate in the management and maintenance of a
27 contractor responsibility program in coordination with the
28 Office of the Budget and other agencies as may be directed by
29 the Governor.
30 § 322. Specific construction powers, duties and procedures.
19970S0005B1478 - 24 -
1 The following procedure shall apply to construction to be 2 completed by the department which costs more than the amount 3 established by the department under section 514 (relating to 4 small procurements) for construction procurement, unless the 5 work is to be done by Commonwealth agency employees or by 6 inmates or patients of a Commonwealth agency institution: 7 (1) The Commonwealth agency or State-related institution 8 shall notify the department to have plans and specifications 9 for the project. 10 (2) Promptly after the notice, in such cases, or 11 promptly after any appropriation made to it becomes 12 available, the department shall, if necessary, select an 13 architect and/or an engineer, in accordance with the 14 selection procedures of section 905 (relating to procurement 15 of design professional services) to design the work and 16 prepare the specifications therefor. The department may, as 17 an alternative, enter into a design/build contract. 18 (3) The department shall enter into a contract with the 19 architect or engineer, which shall provide all of the 20 following: 21 (i) A date for the completion of the plans and 22 specifications. 23 (ii) That the plans and specifications must meet 24 with the approval of the Commonwealth agency or State- 25 related institution for which the building is being 26 erected, altered or enlarged and, in the case of an 27 administrative board or commission of the Commonwealth 28 agency with which the board or commission is respectively 29 connected, to the extent of the type and general 30 character of the building, design of the floor layouts, 19970S0005B1478 - 25 -
1 medical equipment or other equipment of a nature peculiar 2 to the building for which the plans and specifications 3 are being prepared. 4 (iii) That the plans, drawings and specifications 5 must be approved by the department. 6 (iv) That the plans and specifications must be 7 approved by the Department of Labor and Industry, the 8 Department of Health and the Department of Environmental 9 Protection, to the extent to which those Commonwealth 10 agencies, respectively, have jurisdiction to require the 11 submission to them for approval of certain features of 12 the building. 13 The architect or engineer in preparing plans and 14 specifications shall consult with the department and the 15 department shall insist upon the prompt completion of the 16 plans and specifications, within the time prescribed in the 17 architect's or engineer's contracts unless it shall 18 specifically agree in writing to an extension thereof. 19 (4) The enforcement of all contracts provided for by 20 this section shall be under the control and supervision of 21 the department. The department shall have the authority to 22 engage the services of a construction management firm to 23 coordinate the work of the total project. All questions or 24 disputes arising between the department and any contractor 25 with respect to any matter pertaining to a contract entered 26 into with the department or any part thereto or any breach of 27 contract arising thereunder shall be submitted to final and 28 binding arbitration as provided by the terms of the contract 29 which finding shall be final and not subject to further 30 appeal or, if not so provided, shall be referred to the Board 19970S0005B1478 - 26 -
1 of Claims as set forth in the act of May 20, 1937 (P.L.728, 2 No.193), referred to as the Board of Claims Act, whose 3 decision and award shall be final and binding and conclusive 4 upon all parties thereto, except that either party shall have 5 the right to appeal from the decision and award as provided 6 by law. 7 (5) The department shall examine all bills on account of 8 the contracts entered into under the provisions of this 9 section, and, if they are correct, the department shall 10 certify that the materials have been furnished, or that the 11 work or labor has been performed in a workmanlike manner, and 12 in accordance with the contract, approve the bills and issue 13 its requisition therefor, or forward its certificate to the 14 proper Commonwealth agency or State-related institution, as 15 the case may be. Progress payments and final payments shall 16 not estop the department from pursuing its lawful remedies 17 for defects in workmanship or materials or both and other 18 damages. 19 (6) The department may award construction contracts for 20 all the work or separately for parts of the work or both on 21 all projects under $25,000 base construction cost. All 22 projects equal to or exceeding $25,000 shall be subject to 23 the act of May 1, 1913 (P.L.155, No.104), entitled "An act 24 regulating the letting of certain contracts for the erection, 25 construction, and alteration of public buildings." Whenever 26 the department enters into a single contract for a project, 27 in the absence of good and sufficient reasons, the contractor 28 shall pay each subcontractor within 15 days of receipt of 29 payment from the department, an amount equal to the 30 percentage of completion allowed to the contractor on the 19970S0005B1478 - 27 -
1 account of the subcontractor's work. The contractor shall 2 also require the subcontractor to make similar payments to 3 his subcontractors. 4 (7) The department shall have the right to engage the 5 services of any architect or consulting or supervising 6 engineer or engineers, whom it may deem necessary for the 7 proper designing of or inspection or supervision of projects 8 constructed, altered or enlarged by the department under this 9 section in accordance with the selection procedures of 10 section 905. 11 (8) Changes in scope in the plans or specifications, or 12 both, may be made after their approval only with the consent 13 of the Governor and all of the Commonwealth agencies and 14 State-related institutions whose approval of the original 15 plans or specifications, or both, was necessary under this 16 section. 17 (9) If the appropriation is to a Commonwealth agency, 18 other than the department or State-related institution, the 19 department shall award and enter into the contract as agent 20 for the Commonwealth agency or State-related institution to 21 which the appropriation was made. 22 SUBCHAPTER D 23 POWERS AND DUTIES OF THE BOARD OF COMMISSIONERS OF 24 PUBLIC GROUNDS AND BUILDINGS AND THE OFFICE OF THE BUDGET 25 Sec. 26 326. Board of Commissioners of Public Grounds and Buildings. 27 327. Office of the Budget. 28 § 326. Board of Commissioners of Public Grounds and Buildings. 29 No sole source procurement for supplies or leases of real <-- 30 estate for an executive or independent agency for which the 19970S0005B1478 - 28 -
1 department acts as the purchasing agency shall be valid or 2 effective unless, upon review, it is approved by the Board of 3 Commissioners of Public Grounds and Buildings as provided in 4 section 515 (relating to sole source procurement). 5 NO LEASE OF REAL ESTATE FOR USE BY AN EXECUTIVE OR <-- 6 INDEPENDENT AGENCY AND NO SOLE SOURCE PROCUREMENT OF SUPPLIES 7 FOR AN EXECUTIVE OR INDEPENDENT AGENCY FOR WHICH THE DEPARTMENT 8 ACTS AS THE PURCHASING AGENCY SHALL BE VALID OR EFFECTIVE 9 UNLESS, UPON REVIEW, IT IS APPROVED BY THE BOARD OF 10 COMMISSIONERS OF PUBLIC GROUNDS AND BUILDINGS. WHERE THE BOARD 11 IS REVIEWING A PROPOSED SOLE SOURCE LEASE OR PROCUREMENT BEING 12 SUBMITTED PURSUANT TO SECTION 515 (RELATING TO SOLE SOURCE 13 PROCUREMENT), APPROVAL OF THE LEASE OR PROCUREMENT SHALL REQUIRE 14 THE UNANIMOUS VOTE OF THE BOARD. WHERE THE BOARD IS REVIEWING A 15 PROPOSED NON-SOLE SOURCE LEASE, THE LEASE SHALL BE APPROVED WHEN 16 ONE MEMBER OF THE BOARD VOTES TO APPROVE THE LEASE. ALL VOTES 17 SHALL TAKE PLACE AT A PUBLIC MEETING. 18 § 327. Office of the Budget. 19 (a) Encumbrance of funds.--For executive agencies and 20 independent agencies and instrumentalities STATE-AFFILIATED <-- 21 ENTITIES where the department is used as the purchasing agency, 22 Office of the Budget shall encumber sufficient funds for the 23 payment of all invoices for the procurement of supplies, 24 services and construction. 25 (b) Contractor responsibility program.--The Office of the 26 Budget shall participate in the management and maintenance of a 27 contractor responsibility program in coordination with the 28 department and other agencies as may be directed by the 29 Governor. 30 (c) Contracts for services.--Except for contracts awarded 19970S0005B1478 - 29 -
1 pursuant to section 514 (relating to small procurements), the
2 Office of the Budget shall review and approve all contracts for
3 services for executive agencies and independent agencies and
4 instrumentalities STATE-AFFILIATED ENTITIES where the department <--
5 acts as purchasing agency for:
6 (1) Fiscal responsibility and budgetary appropriateness.
7 (2) Availability of funds.
8 (d) Agency comptrollers.--A Commonwealth agency comptroller
9 may, at his option, serve as a nonvoting member of an evaluation
10 committee for requests for proposals or a similar contract
11 bidding or selection committee for the acquisition of services.
12 (E) EXCEPTIONS.--NOTWITHSTANDING THE FOREGOING, SUBSECTIONS <--
13 (A) AND (C) SHALL NOT APPLY TO PROCUREMENTS MADE BY THE OFFICE
14 OF ATTORNEY GENERAL, THE DEPARTMENT OF THE AUDITOR GENERAL OR
15 THE TREASURY DEPARTMENT. HOWEVER, WHERE THE DEPARTMENT IS USED
16 AS THE PURCHASING AGENCY, THE OFFICE OF ATTORNEY GENERAL, THE
17 DEPARTMENT OF THE AUDITOR GENERAL AND THE TREASURY DEPARTMENT
18 SHALL CERTIFY TO THE DEPARTMENT THAT THEY HAVE ENCUMBERED
19 SUFFICIENT FUNDS FOR THE PROCUREMENT.
20 SUBCHAPTER E
21 COORDINATION, TRAINING AND EDUCATION
22 Sec.
23 331. Collection of data concerning public procurement.
24 332. Advisory groups.
25 § 331. Collection of data concerning public procurement.
26 All executive and independent agencies shall furnish such
27 reports as the department may require concerning usage, needs
28 and stock on hand, and the department may prescribe the format
29 and forms to be used by the agencies in requisitioning, ordering
30 and reporting supplies, services and construction.
19970S0005B1478 - 30 -
1 § 332. Advisory groups. 2 (a) Procurement Advisory Council.--The department may 3 establish a Procurement Advisory Council and allocate funds for 4 it that may be available. If created, the council, upon adequate 5 public notice, shall meet at least once a year for the 6 discussion of problems and recommendations for improvement of 7 the procurement process. When requested by the department, the 8 council may conduct studies, research and analyses and make 9 reports and recommendations with respect to subjects or matters 10 within the jurisdiction of the department. The council may 11 consist of any qualified persons the department deems 12 appropriate. 13 (b) Other advisory groups.--The department may appoint 14 advisory groups to assist with respect to specifications or 15 procurement in specific areas and with respect to any other 16 matters within the authority of the department. 17 (c) Reimbursement of expenses.--Members of the council and 18 other advisory groups may be reimbursed for expenses incurred in 19 the performance of their duties, subject to expenditure 20 limitations prescribed by the department. 21 (D) CONFLICT OF INTEREST.--MEMBERS OF THE COUNCIL AND OTHER <-- 22 ADVISORY GROUPS SHALL BE CONSIDERED STATE ADVISORS UNDER THE ACT 23 OF JULY 19, 1957 (P.L.1017, NO.451), KNOWN AS THE STATE ADVERSE 24 INTEREST ACT, AND, AS SUCH, SHALL BE SUBJECT TO THE PROHIBITIONS 25 FOR STATE ADVISORS SET FORTH IN THAT ACT, PROVIDED THAT A MEMBER 26 SHALL NOT BE DEEMED TO HAVE AN ADVERSE INTEREST BY VIRTUE OF ANY 27 ACTION TAKEN BY THE COUNCIL OR OTHER ADVISORY GROUPS IF THE 28 MEMBER DISCLOSES THE CONFLICT OF INTEREST AND PROPERLY RECUSES 29 HIMSELF FROM PARTICIPATING IN ANY RECOMMENDATION OF THE COUNCIL 30 OR AN ADVISORY GROUP. 19970S0005B1478 - 31 -
1 CHAPTER 5 2 SOURCE SELECTION AND CONTRACT FORMATION 3 Subchapter 4 A. Definitions 5 B. Methods of Source Selection 6 C. Cancellation of Invitations for Bids or Requests for 7 Proposals 8 D. Qualifications and Duties 9 E. Types of Contracts 10 F. Inspection of Plant and Audit of Records 11 G. Determinations and Reports 12 SUBCHAPTER A 13 DEFINITIONS 14 Sec. 15 501. Definitions. 16 § 501. Definitions. 17 The following words and phrases when used in this chapter 18 shall have the meanings given to them in this section unless the 19 context clearly indicates otherwise: 20 "Established catalog price." The price included in a 21 catalog, price list, schedule or other form that: 22 (1) is regularly maintained by a manufacturer or 23 contractor; 24 (2) is either published or otherwise available for 25 inspection by customers; and 26 (3) states prices at which sales are currently or were 27 last made to a significant number of any category of buyers 28 or buyers constituting the general buying public for the 29 supplies or services involved. 30 "Invitation for bids." All documents, including those either 19970S0005B1478 - 32 -
1 attached or incorporated by reference, used for soliciting bids. 2 "Life cycle cost." The total cost of the supply in terms of 3 purchase cost, installation cost, maintenance cost, energy cost, 4 supply cost and other costs. 5 "Procurement description." The words used in a solicitation 6 to describe the supplies, services or construction to be 7 procured. The term includes specifications attached to or made a 8 part of the solicitation. 9 "Request for proposals." All documents, including those 10 either attached or incorporated by reference, used for 11 soliciting proposals. 12 "Responsible bidder or offeror." A person who has the 13 capability in all respects to fully perform the contract 14 requirements and the integrity and reliability which will assure 15 good faith performance. 16 "Responsive bidder or offeror." A person who has submitted a 17 bid which conforms in all material respects to the invitation 18 for bids. 19 "Sealed bid or proposal." A bid or proposal whose contents 20 is not disclosed until the bid opening time or the proposal 21 receipt date. Bids and proposals are typically submitted in 22 sealed envelopes to meet this requirement, but electronic 23 submission is not prohibited so long as the purchasing agency 24 has the electronic capability to maintain the confidentiality of 25 the bid or proposal until the bid opening time or proposal 26 receipt date. 27 SUBCHAPTER B 28 METHODS OF SOURCE SELECTION 29 Sec. 30 511. Methods of source selection. 19970S0005B1478 - 33 -
1 512. Competitive sealed bidding. 2 513. Competitive sealed proposals. 3 514. Small procurements. 4 515. Sole source procurement. 5 516. Emergency procurement. 6 517. Multiple awards. 7 518. Competitive selection procedures for certain services. 8 519. Selection procedure for insurance and notary bonds. 9 520. Supplies manufactured by, and services performed by, 10 persons with disabilities. 11 § 511. Methods of source selection. 12 Unless otherwise authorized by law, all Commonwealth agency 13 contracts shall be awarded by competitive sealed bidding under 14 section 512 (relating to competitive sealed bidding) except as 15 provided in: 16 Section 513 (relating to competitive sealed proposals). 17 Section 514 (relating to small procurements). 18 Section 515 (relating to sole source procurement). 19 Section 516 (relating to emergency procurement). 20 Section 517 (relating to multiple awards). 21 Section 518 (relating to competitive selection procedures 22 for certain services). 23 Section 519 (relating to selection procedure for 24 insurance and notary bonds). 25 Section 520 (relating to supplies manufactured by, and 26 services performed by, persons with disabilities). 27 Section 905 (relating to procurement of design 28 professional services). 29 § 512. Competitive sealed bidding. 30 (a) Conditions for use.--Contracts shall be awarded by 19970S0005B1478 - 34 -
1 competitive sealed bidding except as otherwise provided in 2 section 511 (relating to methods of source selection). 3 (b) Invitation for bids.--An invitation for bids shall be 4 issued and shall include a procurement description and all 5 contractual terms, whenever practical, and conditions applicable 6 to the procurement. 7 (c) Public notice.--Adequate public notice of the invitation 8 for bids shall be given a reasonable time prior to the date set 9 for the opening of bids. The notice may include electronic <-- 10 publication which is accessible to the public and publication in 11 a newspaper of general circulation a reasonable time before bid 12 opening. The notice may also include advertisement as provided 13 for in 45 Pa.C.S. § 306 (relating to use of trade publications). 14 THE PURCHASING AGENCY SHALL ESTABLISH WRITTEN POLICIES AND MAY <-- 15 PROMULGATE REGULATIONS REGARDING METHODS OF PUBLIC NOTICE. THE 16 METHOD OF PUBLIC NOTICE MAY INCLUDE ANY OF THE FOLLOWING: 17 (1) ELECTRONIC PUBLICATION WHICH IS ACCESSIBLE TO THE 18 GENERAL PUBLIC. 19 (2) ADVERTISEMENT AS PROVIDED FOR IN 45 PA.C.S. § 306 20 (RELATING TO USE OF TRADE PUBLICATIONS). 21 (3) ISSUANCE OF INVITATIONS FOR BIDS TO BIDDERS ON THE 22 SOLICITATION MAILING LIST OF THE PURCHASING AGENCY. 23 (4) PUBLICATION IN A NEWSPAPER OF GENERAL CIRCULATION. 24 (5) WHERE PREQUALIFICATION IS A REQUIREMENT OF 25 SUBMITTING A BID, NOTIFICATION TO ALL CONTRACTORS WHO HAVE 26 BEEN PREQUALIFIED BY THE PURCHASING AGENCY. 27 COPIES OF INVITATIONS TO BID SHALL BE MADE AVAILABLE TO ANY 28 INTERESTED PERSON UPON REQUEST TO THE PURCHASING AGENCY. 29 PURCHASING AGENCIES MAY ESTABLISH PROCEDURES FOR THE 30 DISTRIBUTION OF INVITATIONS TO BID INCLUDING THE IMPOSITION OF A 19970S0005B1478 - 35 -
1 FEE TO REIMBURSE THE AGENCY FOR THE COSTS OF PHOTOCOPYING AND 2 MAILING. 3 (d) Bid opening.--Bids shall be opened publicly in the 4 presence of one or more witnesses at the time and place 5 designated in the invitation for bids. The amount of each bid 6 and any other relevant information as may be specified by 7 regulation, together with the name of each bidder, shall be 8 recorded. The record shall be open to public inspection. 9 (e) Bid acceptance and evaluation.--Bids shall be 10 unconditionally accepted without alteration or modification 11 except as authorized in this part or in the invitation for bids. 12 Bids shall be evaluated based on the requirements set forth in 13 the invitation for bids, which may include criteria to determine 14 acceptability such as inspection, testing, quality, workmanship, 15 delivery and suitability for a particular purpose. Those 16 criteria that will affect the bid price and be considered in 17 evaluation for award shall be objectively measurable, such as 18 discounts, transportation costs and total or life cycle costs. 19 The invitation for bids shall set forth the evaluation criteria 20 to be used. No criteria may be used in bid evaluation that are 21 not set forth in the invitation for bids. 22 (f) Modification or withdrawal of bids.-- 23 (1) Bids may be modified or withdrawn by written notice 24 or in person by a bidder or its authorized representative if 25 its identity is made known and a receipt for the bid is 26 signed prior to the exact hour and date set for the opening 27 of bids. Except as otherwise provided in this part, 28 withdrawals and modifications of bids received after the 29 exact hour and date specified for the opening of bids shall 30 not be considered. 19970S0005B1478 - 36 -
1 (2) Withdrawal of erroneous bids after bid opening but 2 before award based on bid mistakes shall be permitted by the 3 written determination of the contracting officer when the 4 bidder requests relief and presents credible evidence that 5 the reason for the lower bid price was a clerical mistake as 6 opposed to a judgment mistake and was actually due to an 7 unintentional arithmetical error or an unintentional omission 8 of a substantial quantity of work, labor, material or 9 services made directly in the compilation of the bid. The 10 request for relief and the supporting evidence must be 11 received by the contracting officer within a reasonable time 12 period after the bid opening. The time period shall be 13 specified by the department. 14 (3) The contracting officer shall not permit a 15 withdrawal of a bid if the withdrawal of the bid would result 16 in the awarding of the contract on another bid of the same 17 bidder, its partner or a corporation or business venture 18 owned by or in which the bidder has a substantial interest. 19 No bidder who is permitted to withdraw a bid shall supply any 20 material or labor to or perform any subcontract or other work 21 agreement for any person to whom a contract or subcontract is 22 awarded in the performance of the contract for which the 23 withdrawn bid was submitted, without the written approval of 24 the contracting officer. 25 (g) Award.--The contract shall be awarded within 60 days of 26 the bid opening by written notice to the lowest responsible and 27 responsive bidder whose bid meets the requirements and criteria 28 set forth in the invitation for bids or all bids shall be 29 rejected except as otherwise provided in this section. 30 Extensions of the date for the award may be made by mutual 19970S0005B1478 - 37 -
1 written consent of the contracting officer and the lowest 2 responsible and responsive bidder. Within 30 days of the bid 3 opening the contracting officer shall, if bid security was 4 required by the invitation for bids, return the bid security to 5 all but the lowest and next-to-lowest bidders then under 6 consideration for contract award. 7 (h) Multistep sealed bidding.--When it is considered 8 impractical to prepare initially a procurement description to 9 support an award based on price, an invitation for bids may be 10 issued requesting the submission of unpriced offers, to be 11 followed by an invitation for bids limited to those bidders 12 whose offers have been qualified under the criteria set forth in 13 the first solicitation. 14 § 513. Competitive sealed proposals. 15 (a) Conditions for use.--When the contracting officer 16 determines in writing that the use of competitive sealed bidding 17 is either not practicable or advantageous to the Commonwealth, a 18 contract may be entered into by competitive sealed proposals. 19 (b) Request for proposals.--Proposals shall be solicited 20 through a request for proposals. 21 (c) Public notice.--Public notice of the request for 22 proposals shall be given in the same manner as provided in 23 section 512(c) (relating to competitive sealed bidding). 24 (d) Receipt of proposals.--Offerors shall submit their 25 proposal to ensure that their proposals are received prior to 26 the time and date established for receipt of the proposals. 27 Proposals shall be submitted in the format required by the 28 request for proposals. Proposals shall be opened so as to avoid 29 disclosure of their contents to competing offerors. 30 (e) Evaluation.--The relative importance of the evaluation 19970S0005B1478 - 38 -
1 factors shall be fixed prior to opening the proposals. A
2 Commonwealth agency is required to invite its comptroller to
3 participate in the evaluation as a nonvoting member of any
4 evaluation committee.
5 (f) Discussion with responsible offerors and revision of
6 proposals.--As provided in the request for proposals,
7 discussions may be conducted with responsible offerors who
8 submit proposals determined to be reasonably susceptible of
9 being selected for award for the purpose of clarification to
10 assure full understanding of and responsiveness to the
11 solicitation requirements and for the purpose of obtaining best
12 and final offers. Offerors shall be accorded fair and equal
13 treatment with respect to any opportunity for discussion and
14 revision of proposals. In conducting discussions, there shall be
15 no disclosure of any information derived from proposals
16 submitted by competing offerors.
17 (g) Award of contract.--The responsible offeror whose
18 proposal is determined in writing to be the most advantageous to
19 the purchasing agency, taking into consideration price and all
20 evaluation factors, shall be selected for contract negotiation.
21 (h) Contract negotiation.--After selection, the purchasing
22 agency shall proceed to negotiate a contract with the selected
23 offeror.
24 § 514. Small procurements.
25 If the procurement is not the subject of a STATEWIDE <--
26 requirements contract between the purchasing agency and a
27 contractor, the head of the purchasing agency may authorize in
28 writing procurements without formal bid procedures in the field, <--
29 not exceeding the amount established by the purchasing agency.
30 The department may authorize procurement on a no-bid basis for
19970S0005B1478 - 39 -
1 procurements which do not exceed the amount established by the 2 department for small, no-bid procurements. Procurement 3 requirements shall not be artificially divided so as to 4 constitute a small procurement under this section. Small 5 procurements shall be made in accordance with the requirements 6 of the written authorization and this section. Records of all 7 small procurements shall be transmitted to the purchasing 8 agency. 9 § 515. Sole source procurement. 10 A contract may be awarded for a supply, service or 11 construction item without competition when the contracting 12 officer FIRST determines in writing that one of the following <-- 13 conditions exists: 14 (1) Only a single contractor is capable of providing the 15 supply, service or construction. 16 (2) A Federal or State statute or regulation exempts the 17 supply, service or construction from the competitive 18 procedure. 19 (3) The total cost of the supply, service or 20 construction is less than the amount established by the 21 department for small, no-bid procurements under section 514 22 (relating to small procurements). 23 (4) It is clearly not feasible to award the contract on 24 a competitive basis. 25 (5) The services are to be provided by attorneys or 26 litigation consultants selected by the Office of General 27 Counsel, THE OFFICE OF ATTORNEY GENERAL, THE DEPARTMENT OF <-- 28 THE AUDITOR GENERAL OR THE TREASURY DEPARTMENT. 29 (6) The services are to be provided by expert witnesses. 30 (7) The services involve the repair, MODIFICATION OR <-- 19970S0005B1478 - 40 -
1 CALIBRATION of equipment and they are to be performed by the 2 manufacturer of the equipment or by the manufacturer's 3 authorized dealer, provided the contracting officer 4 determines that bidding is not appropriate under the <-- 5 circumstances. The contract is for APPROPRIATE UNDER THE <-- 6 CIRCUMSTANCES. 7 (8) THE CONTRACT IS FOR investment advisors or managers 8 selected by the Public School Employees' Retirement System, 9 the State Employees' Retirement System or an instrumentality <-- 10 A STATE-AFFILIATED ENTITY. <-- 11 (8) (9) The contract is for financial or investment <-- 12 experts TO BE USED AND SELECTED BY THE TREASURY DEPARTMENT OR <-- 13 FINANCIAL OR INVESTMENT EXPERTS selected by the Secretary of 14 the Budget. 15 (9) (10) It is in the best interest of the Commonwealth. <-- 16 The written determination authorizing sole source procurement 17 shall be included in the contract file. With the exception of 18 small procurements under section 514 and emergency procurements 19 under section 516 (relating to emergency procurement), if the 20 sole source procurement is for a supply for which the department 21 acts as purchasing agency, it must be approved by the Board of 22 Commissioners of Public Grounds and Buildings prior to the award 23 of a contract. 24 § 516. Emergency procurement. 25 The head of a purchasing agency may make or authorize others 26 to make an emergency procurement when there exists a threat to 27 public health, welfare or safety or circumstances outside the 28 control of the agency creates an urgency of need which does not 29 permit the delay involved in using more formal competitive 30 methods. Whenever practical, in the case of a procurement of a 19970S0005B1478 - 41 -
1 supply, at least two bids shall be solicited. A written 2 determination of the basis for the emergency and for the 3 selection of the particular contractor shall be included in the 4 contract file. 5 § 517. Multiple awards. 6 (a) Conditions for use.--Contracts may be entered into on a 7 multiple award basis when the head of the purchasing agency 8 determines that one or more of the following criteria is 9 applicable: 10 (1) It is administratively or economically impractical 11 to develop or modify specifications for a myriad of related 12 supplies because of rapid technological changes. 13 (2) The subjective nature in the use of certain supplies 14 and the fact that recognizing this need creates a more 15 efficient use of the item. 16 (3) It is administratively or economically impractical 17 to develop or modify specifications because of the 18 heterogeneous nature of the product lines. 19 (4) There is a need for compatibility with existing 20 systems. 21 (5) The agency should select the contractor to furnish 22 the supply, service or construction based upon best value or 23 return on investment. 24 (b) Solicitation process.--Invitations to bid or requests 25 for proposals shall be issued for the supplies, services or 26 construction to be purchased. 27 (c) Public notice.--Public notice of the invitation for bids 28 shall be given in the same manner as provided in section 512(c) 29 (relating to competitive sealed bidding). 30 (d) Receipt of bids or proposals.--Bids shall be opened in 19970S0005B1478 - 42 -
1 the same manner as provided in section 512(d). Proposals shall 2 be received in the same manner as provided in section 513(d) 3 (relating to competitive sealed proposals). 4 (e) Award.--The invitation for bids or request for proposals 5 shall describe the method for selection of the successful 6 bidders or offerors. There are three options: 7 (1) Awards shall be made to the lowest responsible and 8 responsive bidder or offeror for each designated 9 manufacturer. 10 (2) Awards shall be made to the two or three lowest 11 responsible and responsive bidders or offerors for each 12 designated manufacturer. 13 (3) Awards shall be made to all responsible and 14 responsive bidders or offers. The Commonwealth agency shall 15 have the discretion to select the contractor to furnish the 16 supply, service or construction based upon best value or 17 return on investment. 18 § 518. Competitive selection procedures for certain services. 19 (a) Conditions for use.--The services of accountants, 20 clergy, physicians, lawyers, dentists and other personal 21 services which are not performed by other Commonwealth employees 22 shall be procured in accordance with this section except as 23 authorized under section 514 (relating to small procurements), 24 515 (relating to sole source procurement) or 516 (relating to 25 emergency procurement). 26 (b) Statement of qualifications.--Persons engaged in 27 providing the types of services specified in subsection (a) may 28 submit statements of qualifications and expressions of interest 29 in providing these services. The contracting officer may specify 30 a uniform format for statements of qualifications. Persons may 19970S0005B1478 - 43 -
1 amend these statements at any time by filing a new statement. 2 (c) Request for proposals.--Adequate notice of the need for 3 the services specified in subsection (a) shall be given by the 4 purchasing agency through a request for proposals. The request 5 for proposals shall describe the services required, list the 6 type of information and data required of each offeror and state <-- 7 the relative importance of particular qualifications THE <-- 8 PARTICULAR INFORMATION. 9 (d) Discussions.--The contracting officer may conduct 10 discussions with any offeror who has submitted a proposal to 11 determine the offeror's qualifications for further 12 consideration. Discussions shall not disclose any information 13 derived from proposals submitted by other offerors. 14 (e) Award.--Award shall be made to the offeror determined in 15 writing by the contracting officer to be best qualified based on 16 the evaluation factors set forth in the request for proposals. 17 Fair and reasonable compensation shall be determined through 18 negotiation. If compensation cannot be agreed upon with the best 19 qualified offeror, then negotiations will be formally terminated 20 with the selected offeror. If proposals were submitted by one or 21 more other offerors determined to be qualified, negotiations may 22 be conducted with the other offeror or offerors in the order of 23 their respective qualification ranking. The contract may be 24 awarded to the offeror then ranked as best qualified if the 25 amount of compensation is determined to be fair and reasonable. 26 § 519. Selection procedure for insurance and notary bonds. 27 (a) Conditions for use.--Insurance and notary bonds shall be 28 procured by the department in accordance with this section 29 except as authorized under section 515 (relating to sole source 30 procurement) or 516 (relating to emergency procurement). 19970S0005B1478 - 44 -
1 (b) Statement of qualifications.--Insurance and bond 2 carriers may submit statements of qualifications and expressions 3 of interest in providing insurance or notary bonds. The 4 department may specify a uniform format for statements of 5 qualifications. 6 (c) Request for proposals.--Adequate notice of the need for 7 insurance or notary bond coverage shall be given by the 8 purchasing agency through a request for proposals. The request 9 for proposals shall describe the type of insurance or bond 10 coverage required and list the type of information and data 11 required of each offeror. 12 (d) Receipt of proposals.--Offerors shall submit their 13 proposals prior to the time and date specified. 14 (e) Discussions with responsible offerors and revision to 15 proposals.--Discussions and negotiations may be conducted with 16 responsible offerors who submit proposals determined to be 17 reasonably susceptible of being selected for award. Offerors 18 shall be accorded fair and equal treatment with respect to any 19 opportunity for discussion, negotiation and revision of 20 proposals. Revisions may be permitted after submissions and 21 prior to award for the purpose of obtaining best and final 22 offers. 23 (f) Award.--Award shall be made to the offeror whose 24 proposal is determined in writing by the department to be the 25 most advantageous to the Commonwealth based on criteria 26 determined by the department, including the coverage offered and 27 the cost of the premium. 28 § 520. Supplies manufactured by, and services performed by, 29 persons with disabilities. 30 (a) General rule.--Contracts may be entered into for 19970S0005B1478 - 45 -
1 supplies manufactured by, and services performed by, persons 2 with disabilities without competition in accordance with this 3 section. 4 (b) Fair market price.--Upon request from an agency for 5 persons with disabilities and notice to the purchasing agency, 6 the department shall determine the fair market price of any 7 supply manufactured by, or service performed by, persons with 8 disabilities and offered for sale to any Commonwealth agency by 9 an agency for persons with disabilities. The department shall 10 revise the prices in accordance with changing market conditions. 11 (c) Distribution.--At the request of the department, the 12 Department of Public Welfare, or a nonprofit agency with the 13 approval of the Department of Public Welfare, shall facilitate 14 the distribution of orders for supplies manufactured by or 15 services performed by persons with disabilities among agencies 16 for persons with disabilities. 17 (d) Procurement of supplies manufactured by, and services 18 performed by, persons with disabilities.--Except as provided in 19 subsection (e), all supplies manufactured by, and services 20 furnished by, persons with disabilities shall be procured in 21 accordance with applicable specifications of the department or 22 other Commonwealth agencies from any agency for persons with 23 disabilities whenever the supplies and services are available at 24 a price determined by the department to be the fair market 25 price. The head of a purchasing agency shall annually discuss 26 its needs for supplies or services with the agency for persons 27 with disabilities. 28 (e) Procurement from Commonwealth agency.--If any supply 29 manufactured by, or any service performed by, persons with 30 disabilities and offered for sale is available for procurement 19970S0005B1478 - 46 -
1 from any Commonwealth agency and this part or any other statute 2 requires the procurement of the supply or service from the 3 Commonwealth agency, then the procurement of the supply or 4 service shall be made in accordance with the other provisions. 5 (f) Definitions.--As used in this section, the following 6 words and phrases shall have the meanings given to them in this 7 subsection: 8 "Agency for persons with disabilities." Any charitable, 9 nonprofit agency incorporated under the laws of this 10 Commonwealth and approved by the department through which 11 persons with disabilities manufacture supplies or perform 12 services in this Commonwealth. 13 "Mentally retarded." Subaverage general intellectual 14 functioning which originates during the developmental period and 15 is associated with the impairment of maturation, learning or 16 social adjustment. 17 "Persons with a disability." A person who is visually 18 impaired, mentally retarded or physically disabled. 19 "Physically disabled." A limitation of most activities and 20 functioning by virtue of a severe impairment of the various 21 bodily systems which cannot be eliminated, modified or 22 substantially reduced by the usual rehabilitation services and 23 which precludes competitive employment. 24 "Supply manufactured by, or service performed by, person with 25 disabilities." At least 75% of the personnel either engaged in 26 the direct labor of manufacturing of a product or engaged in the 27 direct labor in performing a service in this Commonwealth must 28 be visually impaired, mentally retarded or physically disabled. 29 In addition, at least 75% of the amount paid by the Commonwealth 30 agency for the product or the service shall be remitted to the 19970S0005B1478 - 47 -
1 agency for persons with disabilities to cover payment of wages 2 and salaries to persons with disabilities and to cover other 3 actual manufacturing costs incurred by the agency for persons 4 with disabilities in manufacturing of a product. 5 "Visually impaired." A condition in which central visual 6 acuity does not exceed 20/200 in the better eye with correcting 7 lenses or in which the widest diameter of the visual field 8 subtends an angle no greater than 20 degrees. 9 SUBCHAPTER C 10 CANCELLATION OF INVITATIONS FOR BIDS OR 11 REQUESTS FOR PROPOSALS 12 Sec. 13 521. Cancellation of invitations for bids or requests for 14 proposals. 15 § 521. Cancellation of invitations for bids or requests for 16 proposals. 17 An invitation for bids, a request for proposals or other 18 solicitation may be canceled or any or all bids or proposals may 19 be rejected when it is in the best interests of the 20 Commonwealth. Bids may be rejected in part when specified in the 21 solicitation. The reasons for the cancellation or rejection 22 shall be made part of the contract file. 23 SUBCHAPTER D 24 QUALIFICATIONS AND DUTIES 25 Sec. 26 531. Debarment or suspension. 27 532. Prequalification of bidders and offerors. 28 533. Security and performance bonds. 29 534. Cost or pricing data. 30 535. PRINTING. <-- 19970S0005B1478 - 48 -
1 § 531. Debarment or suspension. 2 (a) Authority.--After reasonable notice to the person 3 involved and reasonable opportunity for that person to be heard, 4 the head of a purchasing agency, after consultation with the 5 head of the using agency, shall have authority to debar a person 6 for cause from consideration for award of contracts for a period 7 of not more than three years or to suspend a person from 8 consideration for award of contracts if there is probable cause 9 for debarment for a period of not more than three months. 10 (b) Causes for debarment or suspension.--The causes for 11 debarment or suspension include: 12 (1) Commission of embezzlement, theft, forgery, bribery, 13 falsification or destruction of records, making false 14 statements or receiving stolen property. 15 (2) Commission of fraud or a criminal offense or other 16 improper conduct or knowledge of, approval of, or 17 acquiescence in such activities by a contractor or any 18 affiliate, officer, employee or other individual or entity 19 associated with: 20 (i) obtaining; 21 (ii) attempting to obtain; or 22 (iii) performing a public contract or subcontract. 23 The contractor's acceptance of the benefits derived from the 24 conduct shall be deemed evidence of such knowledge, approval 25 or acquiescence. 26 (3) Violation of Federal or State antitrust statutes. 27 (4) Violation of any Federal or State law regulating 28 campaign contributions. 29 (5) Violations of any Federal or State environmental 30 law. 19970S0005B1478 - 49 -
1 (6) Violation of any Federal or State law regulating 2 hours of labor, minimum wage standards or prevailing wage 3 standards; discrimination in wages; or child labor 4 violations. 5 (7) Violation of the act of June 2, 1915 (P.L.736, 6 No.338), known as the Workers' Compensation Act. 7 (8) Violation of any Federal or State law prohibiting 8 discrimination in employment. 9 (9) Debarment by any agency or department of the Federal 10 Government or by any other state. 11 (10) Three or more occurrences where a contractor has 12 been declared ineligible for a contract. 13 (11) Unsatisfactory performance, including, but not 14 limited to, any of the following: 15 (i) Failure to comply with terms of a Commonwealth 16 agency contract or subcontract, including, but not 17 limited to: willful failure to perform in accordance with 18 the terms of one or more contracts, a history of failure 19 to perform, or unsatisfactory performance of one or more 20 contracts. 21 (ii) Offering unbalanced bids. 22 (iii) Failure to complete the work in the time frame 23 specified in the contract. 24 (iv) Being declared in default on prior work or 25 project. 26 (v) Failure to submit documents, information or 27 forms as required by contract. 28 (vi) Making false statements or failing to provide 29 information or otherwise to cooperate with the 30 contracting agency, the Office of State Inspector General 19970S0005B1478 - 50 -
1 or other Commonwealth authorities. 2 (vii) Discrimination in violation of laws or 3 regulations in the conduct of business as a contractor. 4 (12) Any other act or omission indicating a lack of 5 skill, ability, capacity, quality control, business integrity 6 or business honesty that seriously and directly affect the 7 present responsibility of a contractor as determined by the 8 purchasing agency. 9 (c) Decision.--After the contractor has been given notice of 10 the potential debarment and the opportunity to be heard, the 11 head of a purchasing agency shall issue a written decision to <-- 12 debar or suspend. The decision shall: 13 (1) State the reasons for the action taken. 14 (2) Inform the debarred or suspended person CONTRACTOR <-- 15 involved of the right to judicial review as provided in 16 subsection (e). 17 (d) Notice of decision.--A copy of the decision under 18 subsection (c) shall be delivered by registered mail to the 19 debarred or suspended person CONTRACTOR and any other party <-- 20 intervening. 21 (e) Finality of decision and appeal.--A decision under 22 subsection (c) shall be final and conclusive unless the debarred <-- 23 or suspended person CONTRACTOR appeals to the Commonwealth Court <-- 24 under 42 Pa.C.S. § 763(a)(1) (relating to direct appeals from 25 government agencies) within 30 days after receipt of the 26 decision. 27 (f) Effect of suspension/debarment.--Suspension or debarment 28 of a contractor, vendor or other person shall automatically 29 prohibit all Commonwealth agencies from awarding any contract to 30 such contractor, vendor or other person or renewing or extending 19970S0005B1478 - 51 -
1 any contract with such contractor, vendor or other person, 2 unless the contracting officer determines that there are 3 compelling reasons for such award, renewal or extension and the 4 head of the purchasing agency approves the determination. 5 § 532. Prequalification of bidders and offerors. 6 Prospective bidders and offerors may be prequalified for 7 particular types of supplies, services and construction. 8 § 533. Security and performance bonds. 9 (a) Contract for supplies or services.-- 10 (1) In the case of competitive sealed bidding or 11 competitive sealed proposals for a contract for supplies or 12 services, bidders or offerors may be required by the 13 contracting officer to provide bid or proposal security. Bid 14 or proposal security shall be in the form of a certified or 15 bank check or a bond provided by a surety company authorized 16 to do business in this Commonwealth or another form of 17 security as specified in the invitation for bids or request 18 for proposals. Bid or proposal security shall be at least in 19 the minimum amount or percentage of the amount of the bid as 20 shall be specified in the advertisement, invitation for bids 21 or request for proposals. 22 (2) When the invitation for bids or the request for 23 proposals requires security, noncompliance by the bidder or 24 offeror with the instructions in the invitation for bids or 25 request for proposals requires that the bid or proposal be 26 rejected unless it is determined that the bid or proposal 27 fails to comply with the security requirements in a 28 nonsubstantial manner. 29 (3) After the bids are opened, they shall be irrevocable 30 for the period specified in the invitation for bids or the 19970S0005B1478 - 52 -
1 request for proposals except as provided in section 512(f) 2 (relating to competitive sealed bidding). If a bidder or 3 offeror is permitted to withdraw its bid before award, no 4 action shall be had against the bidder or offeror or against 5 the bid or proposal security. 6 (4) A contractor may be required by the contracting 7 officer to provide a performance bond executed by a surety 8 company authorized to do business in this Commonwealth. In 9 lieu of a bond, a contractor may provide other security as 10 permitted by the head of the purchasing agency. The 11 performance bond or other required security shall be in an 12 amount determined by the head of the purchasing agency, and 13 it shall be conditioned upon the faithful performance of the 14 contract. 15 (b) Contract for construction.--Bid security and performance 16 bonds as required for contracts for construction are provided 17 for in sections 902 (relating to bid or proposal security) and 18 903 (relating to contract performance and payment bonds). 19 § 534. Cost or pricing data. 20 (a) Submission by contractor.--A contractor shall, except as 21 provided in subsection (c), submit cost or pricing data and 22 shall certify that, to the best of its knowledge and belief, the 23 cost or pricing data submitted was accurate, complete and 24 current as of a mutually determined specified date prior to the 25 date of: 26 (1) the award of any contract under section 513 27 (relating to competitive sealed proposals) or 515 (relating 28 to sole source procurement) where, under either section, the 29 total contract price is expected to exceed an amount 30 established by the head of the purchasing agency; or 19970S0005B1478 - 53 -
1 (2) the pricing of any change order or contract
2 modification which is expected to exceed an amount
3 established by the head of the purchasing agency.
4 (b) Price adjustment.--Any contract, change order or
5 contract modification under which a certificate is required
6 shall contain a provision that the price to the purchasing
7 agency, including profit or fee, shall be adjusted to exclude
8 any significant sums by which the purchasing agency finds that
9 the price was increased because the cost or pricing data
10 furnished by the contractor was inaccurate, incomplete or not
11 current as of the date agreed upon between the parties.
12 (c) Cost or pricing data not required.--The requirements of
13 this section need not be applied to contracts under any of the
14 following circumstances:
15 (1) When responsive proposals are received from three <--
16 TWO or more offerors. <--
17 (2) When the contract price is based on established
18 catalog prices or market prices.
19 (3) When contract prices are set by statute or
20 regulation.
21 (4) When it is determined in writing by the contracting
22 officer that the requirements of this section may be waived
23 and the reasons for the waivers are stated in writing.
24 § 535. PRINTING. <--
25 NO CONTRACT FOR PRINTING SHALL BE ENTERED INTO WITH ANY
26 CONTRACTOR UNTIL THE PURCHASING AGENCY IS SATISFIED THAT THE
27 CONTRACTOR IS THE OWNER OR LESSEE OF MACHINERY AND EQUIPMENT
28 NECESSARY TO PROPERLY AND PROMPTLY PERFORM ANY ORDERS ISSUED TO
29 THE CONTRACTOR UNDER THE PROPOSED PRINTING CONTRACT.
30 SUBCHAPTER E
19970S0005B1478 - 54 -
1 TYPES OF CONTRACTS 2 Sec. 3 541. Approval of accounting system. 4 542. Multiterm contracts. 5 543. Effective contracts. 6 § 541. Approval of accounting system. 7 Except with respect to firm fixed-price contracts, no <-- 8 contract type shall be used unless it has been determined in 9 writing by the head of a purchasing agency that: 10 (1) The proposed contractor's accounting system will 11 permit timely development of all necessary cost data in the 12 form required by the specific contract type contemplated. 13 (2) The proposed contractor's accounting system is 14 adequate to allocate costs in accordance with generally 15 accepted accounting principles. 16 NO CONTRACT TYPE SHALL BE USED UNLESS IT HAS BEEN DETERMINED <-- 17 IN WRITING BY THE HEAD OF THE PURCHASING AGENCY THAT: 18 (1) THE PROPOSED CONTRACTOR'S ACCOUNTING SYSTEM WILL 19 PERMIT TIMELY DEVELOPMENT OF ALL NECESSARY COST DATA IN THE 20 FORM REQUIRED BY THE SPECIFIC CONTRACT TYPE CONTEMPLATED. 21 (2) THE PROPOSED CONTRACTOR'S ACCOUNTING SYSTEM IS 22 ADEQUATE TO ALLOCATE COSTS IN ACCORDANCE WITH GENERALLY 23 ACCEPTED ACCOUNTING PRINCIPLES. 24 NOTWITHSTANDING THE PRECEDING, A CONTRACT MAY BE USED WITHOUT A 25 PRIOR WRITTEN DETERMINATION WHERE THE CONTRACT IS A FIRM FIXED 26 PRICE CONTRACT, OR A CONTRACT AWARDED UNDER SECTION 516 27 (RELATING TO EMERGENCY PROCUREMENT). 28 § 542. Multiterm contracts. 29 (a) Specified period.--A contract for supplies, construction 30 or services may be entered into for a period of time deemed to 19970S0005B1478 - 55 -
1 be in the best interests of the Commonwealth. The term of the 2 contract and conditions of renewal or extension, if any, shall 3 be included in the solicitation, and funds shall be available 4 for the first fiscal period at the time of contracting. Payment 5 and performance obligations for succeeding fiscal periods shall 6 be subject to the availability and appropriation of funds. 7 (b) Cancellation for unavailability of funds in succeeding 8 fiscal periods.--When funds are not appropriated or otherwise 9 made available to support continuation of performance in a 10 subsequent fiscal period, the contract shall be canceled, and 11 the contractor shall be reimbursed for the reasonable value of 12 any nonrecurring costs incurred but not amortized in the price 13 of the supplies, services or construction delivered under the 14 contract. Such reimbursement shall not include loss of 15 anticipated profit, loss of use of money or administrative or 16 overhead costs. The cost of cancellation may be paid from any 17 appropriations available for that purpose. The contractor shall 18 not be entitled to any reimbursement where the Commonwealth 19 elects not to exercise a renewal or extension option provided 20 for in the contract. 21 § 543. Effective contracts. 22 (A) GENERAL RULE.--Irrespective of the type of contract, no <-- 23 contract shall be effective until executed by all necessary 24 Commonwealth officials as provided by law. 25 (B) CERTAIN CONTRACTS.--THOSE STATEWIDE REQUIREMENTS <-- 26 CONTRACTS WHERE THE TOTAL DOLLAR PURCHASING AMOUNT, BASED UPON 27 ESTIMATED QUANTITIES, IS IN EXCESS OF $1,000,000 SHALL NOT BE 28 EFFECTIVE UNLESS FIRST APPROVED BY THE STATE TREASURER. THE 29 $1,000,000 AMOUNT SHALL BE ADJUSTED EACH YEAR BY THE DEPARTMENT 30 TO REFLECT THE ANNUAL PERCENTAGE CHANGE IN THE COMPOSITE 19970S0005B1478 - 56 -
1 CONSTRUCTION COST INDEX OF THE UNITED STATES DEPARTMENT OF 2 COMMERCE OCCURRING IN THE ONE-YEAR PERIOD ENDING DECEMBER 31 3 EACH YEAR. 4 SUBCHAPTER F 5 INSPECTION OF PLANT AND AUDIT OF RECORDS 6 Sec. 7 551. Right to inspect plant. 8 552. Right to audit records. 9 § 551. Right to inspect plant. 10 The purchasing agency may, at reasonable times, inspect the 11 part of the plant or place of business of a contractor or any 12 subcontractor which is related to the performance of any 13 contract awarded or to be awarded by the purchasing agency. 14 § 552. Right to audit records. 15 (a) Audit of cost or pricing data.--The purchasing agency or 16 its designee may, at reasonable times and places, audit the 17 books and records of any person who has submitted cost or 18 pricing data under section 534 (relating to cost or pricing 19 data) to the extent that the books and records relate to the 20 cost or pricing data. A person who receives a contract, change 21 order or contract modification for which cost or pricing data is 22 required shall maintain the books and records that relate to the 23 cost or pricing data for three years from the date of final 24 payment under the contract unless a shorter period is otherwise 25 authorized by the purchasing agency in writing. 26 (b) Contract audit.--The purchasing agency may audit the 27 books and records of a contractor or any subcontractor under any 28 negotiated contract or subcontract other than a firm fixed-price 29 contract to the extent that the books and records relate to the 30 performance of the contract or subcontract. The books and 19970S0005B1478 - 57 -
1 records shall be maintained by the contractor for a period of 2 three years from the date of final payment under the prime 3 contract and by the subcontractor for a period of three years 4 from the date of final payment under the prime contract unless a 5 shorter period is otherwise authorized by the purchasing agency 6 in writing. 7 SUBCHAPTER G 8 DETERMINATIONS AND REPORTS 9 Sec. 10 561. Finality of determinations. 11 562. Anticompetitive practices. 12 563. Retention of procurement records. 13 564. Record of certain actions. 14 § 561. Finality of determinations. 15 The determinations required by the following sections are 16 final and conclusive unless they are clearly erroneous, 17 arbitrary, capricious or contrary to law: 18 Section 512(f) (relating to competitive sealed bidding). 19 Section 513(a) and (g) (relating to competitive sealed 20 proposals). 21 Section 515 (relating to sole source procurement). 22 Section 516 (relating to emergency procurement). 23 Section 518(e) (relating to competitive selection 24 procedures for certain services). 25 Section 519(f) (relating to selection procedure for 26 insurance and notary bonds). 27 Section 534(c) (relating to cost or pricing data). 28 Section 541 (relating to approval of accounting system). 29 § 562. Anticompetitive practices. 30 Collusion among bidders is unlawful. Every contract, 19970S0005B1478 - 58 -
1 combination or conspiracy which unreasonably restrains trade 2 among bidders or offerors is unlawful. Contracts so arrived at 3 may be declared void at the option of the Commonwealth. In 4 addition to remedies available to the Commonwealth in the 5 Federal courts, there shall be the same remedies in the courts 6 of this Commonwealth. When any person has reason to believe 7 collusion or other anticompetitive practices have occurred among 8 any bidders or offerors, a notice of the relevant facts shall be 9 transmitted to the Attorney General who shall investigate the 10 reports. 11 § 563. Retention of procurement records. 12 All procurement records, including any written determinations 13 issued in accordance with section 561 (relating to finality of 14 determinations), shall be retained for a minimum of three years 15 from the date of final payment under the contract and disposed 16 of in accordance with records retention guidelines and schedules 17 as provided by law. In accordance with applicable law, all 18 retained documents shall be made available to the State 19 Treasurer, Auditor General, General Counsel, Inspector General 20 and Attorney General upon request. 21 § 564. Record of certain actions. 22 The purchasing agency shall maintain a record listing all 23 contracts made under sections 514 (relating to small 24 procurements), 515 (relating to sole source procurement) and 516 25 (relating to emergency procurement) for a minimum of three years 26 from the date of final payment under the contract. The record 27 shall contain: 28 (1) Each contractor's name. 29 (2) The amount and type of each contract. 30 (3) A listing of the supplies, services or construction 19970S0005B1478 - 59 -
1 procured under each contract. 2 CHAPTER 7 3 (Reserved) 4 CHAPTER 9 5 PROCUREMENT OF CONSTRUCTION AND DESIGN 6 PROFESSIONAL SERVICES 7 Sec. 8 901. Definitions. 9 902. Bid or proposal security. 10 903. Contract performance SECURITY and payment bonds. <-- 11 904. Copies of bonds. 12 905. Procurement of design professional services. 13 § 901. Definitions. 14 The following words and phrases when used in this chapter 15 shall have the meanings given to them in this section unless the 16 context clearly indicates otherwise: 17 "Design professional services." Those professional services 18 within the scope of the practice of architecture, geology, 19 engineering, landscape architecture or land surveying, including 20 studies, investigations, surveying, mapping, tests, evaluations, 21 consultations, comprehensive planning, program management, 22 conceptual design, plans and specifications, value engineering, 23 maintenance manuals and other related services associated with 24 research, planning, development, design, construction, 25 alteration or repair of real property. THE TERM INCLUDES <-- 26 SERVICES PROVIDED UNDER THE SUPERVISION OF A PROFESSIONAL 27 ENGINEER TO DEVELOP ENGINEERING SOFTWARE WHICH WILL AID DESIGN 28 PROFESSIONALS IN PERFORMING THEIR WORK. The term does not 29 include those services which are not exclusively within the 30 scope of architecture, geology, engineering or landscape <-- 19970S0005B1478 - 60 -
1 architecture, but which are related to capital improvements such
2 as, but not limited to, environmental hygienics, construction
3 management as described in section 322 (relating to specific
4 construction powers, duties and procedures), exhibit design,
5 fine arts or lesser arts and crafts, even though an architect,
6 geology GEOLOGIST, engineer or landscape architect may provide <--
7 such services.
8 § 902. Bid or proposal security.
9 (a) Requirement for bid security.--Bidders or offerors may
10 be required to provide bid or proposal security for construction
11 contracts. Bid or proposal security shall be in the form of a
12 certified or bank check or a bond provided by a surety company
13 authorized to do business in this Commonwealth or another form
14 of security as specified in the invitation for bids or request
15 for proposals.
16 (b) Amount of bid or proposal security.--Bid security shall
17 be at least in the minimum amount or percentage of the amount of
18 the bid as shall be specified in the advertisement, the
19 invitation for bids or the request for proposals.
20 (c) Rejection of bids or proposals.--When the invitation for
21 bids or the request for proposals requires security,
22 noncompliance with the instructions in the invitation for bids
23 or the request for proposals requires that the bid or proposal
24 be rejected unless it is determined that the bid or proposal
25 fails to comply with the security requirements in a
26 nonsubstantial manner.
27 (d) Withdrawal of bids.--After the bids are opened, they
28 shall be irrevocable for the period specified in the invitation
29 for bids except as provided in section 512(f) (relating to
30 competitive sealed bidding). If a bidder is permitted to
19970S0005B1478 - 61 -
1 withdraw its bid before award, no action shall be had against 2 the bidder or the bid security. 3 § 903. Contract performance and payment bonds. <-- 4 (a) When required and amounts.--When a construction contract 5 is awarded in excess of $250,000, the following bonds or 6 security shall be delivered to the purchasing agency and shall 7 be binding on the parties upon the execution of the contract: 8 § 903. CONTRACT PERFORMANCE SECURITY AND PAYMENT BONDS. <-- 9 (A) WHEN REQUIRED AND AMOUNTS.--FOR CONSTRUCTION CONTRACTS 10 AWARDED FOR AMOUNTS BETWEEN $25,000 AND $100,000, THE PURCHASING 11 AGENCY SHALL REQUIRE CONTRACT PERFORMANCE SECURITY, IN AN AMOUNT 12 EQUAL TO AT LEAST 50% OF THE CONTRACT PRICE, AS THE PURCHASING 13 AGENCY, IN ITS DISCRETION, DETERMINES NECESSARY TO PROTECT THE 14 INTERESTS OF THE COMMONWEALTH. WHEN A CONSTRUCTION CONTRACT IS 15 AWARDED IN EXCESS OF $100,000, THE FOLLOWING BONDS SHALL BE 16 DELIVERED TO THE PURCHASING AGENCY AND SHALL BE BINDING ON THE 17 PARTIES UPON THE EXECUTION OF THE CONTRACT: 18 (1) A performance bond, executed by a surety company 19 authorized to do business in this Commonwealth and made 20 payable to the Commonwealth, in an amount equal to 100% of 21 the price specified in the contract and conditioned upon the 22 faithful performance of the contract in accordance with the 23 plans, specifications and conditions of the contract. 24 (2) A payment bond, executed by a surety company 25 authorized to do business in this Commonwealth and made 26 payable to the Commonwealth, in an amount equal to 100% of 27 the price specified in the contract and conditioned upon the 28 prompt payment for all materials furnished or labor supplied 29 or performed in the prosecution of the work. Labor or 30 materials include public utility services and reasonable 19970S0005B1478 - 62 -
1 rentals of equipment for the periods when the equipment is 2 actually used at the site. 3 (b) Protection.--A performance bond shall be solely for the 4 protection of the purchasing agency which awarded the contract. 5 A payment bond shall be solely for the protection of claimants 6 supplying labor or materials to the prime contractor to whom the 7 contract was awarded or to any of its subcontractors in the 8 prosecution of the work provided for in the contract, whether or 9 not the labor or materials constitute a component part of the 10 construction. 11 (c) Authority to require additional bonds.--Nothing in this 12 section shall be construed to limit the authority of the 13 Commonwealth agency to require a performance bond, payment bond 14 or other security in addition to those bonds or in circumstances 15 other than specified in subsection (a). 16 (d) Actions on payment bonds.-- 17 (1) Subject to paragraph (2), any claimant who has 18 performed labor or furnished material in the prosecution of 19 the work provided for in any contract for which a payment 20 bond has been given under subsection (a) and who has not been 21 paid in full before the expiration of 90 days after the day 22 on which the claimant performed the last of the labor or 23 furnished the last of the materials for which it claims 24 payments may bring an action on the payment bond in its own 25 name, in assumpsit, to recover any amount due it for the 26 labor or material and may prosecute the action to final 27 judgment and have execution on the judgment. 28 (2) Any claimant who has a direct contractual 29 relationship with any subcontractor of the prime contractor 30 who gave the payment bond but has no contractual 19970S0005B1478 - 63 -
1 relationship, express or implied, with the prime contractor 2 may bring an action on the payment bond only if it has given 3 written notice to the contractor within 90 days from the date 4 on which the claimant performed the last of the labor or 5 furnished the last of the materials for which it claims 6 payment, stating with substantial accuracy the amount and the 7 name of the person for whom the work was performed or to whom 8 the material was furnished. 9 (3) Notice shall be served by registered mail in an 10 envelope addressed to the contractor at any place where its 11 office is regularly maintained for the transaction of 12 business or served in any manner in which legal process may 13 be served in the manner provided by law for the service of a 14 summons except that the service need not be made by a public 15 officer. 16 (e) Adjustment of threshold amount.--The dollar threshold of <-- 17 $250,000 THRESHOLDS set forth in subsection (a) shall be <-- 18 adjusted annually by the department to reflect the annual 19 percentage change in the Composition Construction Cost Index of 20 the United States Department of Commerce occurring in the one- 21 year period ending on December 31 of each year. 22 § 904. Copies of bonds. 23 (a) Copies of bonds.--The purchasing agency shall furnish a 24 copy of any payment bond and the contract for which the bond was 25 given to any person who makes an application for the copy. 26 (b) Fee for copies.--Each applicant shall pay for each copy 27 of any payment bond a fee fixed by the purchasing agency to 28 cover the actual cost of the preparation of the copy. 29 (c) Evidence.--A copy of any payment bond and of the 30 contract for which the bond was given constitutes prima facie 19970S0005B1478 - 64 -
1 evidence of the contents, execution and delivery of the original 2 of the bond and contract. 3 § 905. Procurement of design professional services. 4 (a) Applicability.--Design professional services shall be 5 procured as provided in this section except as authorized by 6 sections 514 (relating to small procurements), 515 (relating to 7 sole source procurement) and 516 (relating to emergency 8 procurement). 9 (b) Policy.--It is the policy of this Commonwealth to 10 publicly announce all requirements for design professional 11 services and to award contracts for design professional services 12 on the basis of demonstrated competence and qualification for 13 the types of services required. There shall be a committee to 14 review the qualifications, experience and work of design 15 professionals seeking contracts with purchasing agencies. 16 (c) Selection committees for Department of Transportation, 17 Department of Environmental Protection, Department of 18 Conservation and Natural Resources and instrumentalities STATE- <-- 19 AFFILIATED ENTITIES.--Where they are authorized by law to act as 20 purchasing agency for design professional services, the 21 Department of Transportation, the Department of Environmental 22 Protection, the Department of Conservation and Natural Resources 23 and instrumentalities STATE-AFFILIATED ENTITIES shall each <-- 24 establish a selection committee and a procedure for selection of <-- 25 committee members. None of the members of these committees shall 26 hold any elective office or office in any political party. AS <-- 27 MANY SELECTION COMMITTEES AS THE DEPARTMENT DEEMS APPROPRIATE 28 AND A PROCEDURE FOR THE SELECTION OF COMMITTEE MEMBERS. 29 (d) Selection committee for all other Commonwealth 30 agencies.--Except as provided for in subsection (c), all 19970S0005B1478 - 65 -
1 purchasing agencies shall use the selection committee appointed 2 by the Governor which shall be composed of five members, none of 3 whom shall be employees of the Commonwealth or hold any elective 4 office or office in any political party. The members shall be 5 architects, engineers or other persons knowledgeable in 6 construction. The members shall serve for terms of two years and 7 shall not be removed except for cause. Of the original members, 8 three shall serve for terms of two years and two for terms of 9 one year. Thereafter, all terms shall be for two years. Each 10 member shall be reimbursed for reasonable travel and other 11 expenses incurred incident to attendance at meetings and to 12 assigned duties and also a per diem allowance in accordance with 13 Commonwealth travel policies. 14 (e) Procedure for selection committees.--The selection 15 committees shall use the procedure set forth in this subsection: 16 (1) The committee shall give public notice of projects 17 requiring design services and publicly recommend to the 18 purchasing agency three qualified design professionals for 19 each project. 20 (2) If desired, the committee may conduct discussions 21 with three or more professionals regarding anticipated design 22 concepts and proposed methods of approach to the assignment. 23 The committee shall select, based upon criteria established 24 by the head of the purchasing agency, no less than three 25 design professionals deemed to be the most highly qualified 26 to provide the services required. In exercising its 27 responsibility, the committee shall consider the following 28 factors: 29 (i) An equitable distribution of contracts to design 30 professionals. 19970S0005B1478 - 66 -
1 (ii) Particular capability to perform the design or 2 construction services for the contract being considered. 3 (iii) Geographic proximity of the design 4 professional to the proposed facility. 5 (iv) The design professional selected has the 6 necessary available personnel to perform the services 7 required by the project. 8 (v) Any other relevant circumstances peculiar to the 9 proposed contract. 10 (f) Design professionals.--Except as provided for in 11 subsection (g), the head of the purchasing agency shall select 12 design professionals as follows: 13 (1) Where the amount of the base construction allocation 14 is less than $20,000,000, the head of the purchasing agency 15 shall choose one of the three firms approved by the selection 16 committee. The fee to be paid to the appointed design 17 professional may be established by the selection committee or 18 may be negotiated at the discretion of the head of the 19 purchasing agency. The $20,000,000 threshold shall be 20 adjusted by the department to reflect the annual percentage 21 change in the Composite Construction Cost Index of the United 22 States Department of Commerce occurring in the one-year 23 period ending December 31 each year. 24 (2) Where the amount of base construction allocation is 25 in excess of or equal to $20,000,000, as annually adjusted, 26 the head of the purchasing agency shall choose one of the 27 three firms approved by the selection committee to begin 28 contract negotiations. The fee to be paid to the design 29 professional and the terms of the contract between the design 30 professional and the department shall be negotiated by the 19970S0005B1478 - 67 -
1 head of the purchasing agency. In negotiating the contract 2 and the fee, the head of the purchasing agency shall take 3 into account the estimated value, scope, complexity, 4 uniqueness and the professional nature of the services to be 5 rendered. In the event the head of the purchasing agency is 6 unable to negotiate a satisfactory contract or fee with the 7 appointed design professional, negotiations with that design 8 professional shall be terminated and the head of the 9 purchasing agency shall commence negotiations with one of the 10 other firms chosen by the selection committee. In the event 11 the head of the purchasing agency is unable to negotiate a 12 satisfactory contract or fee with the second firm, the head 13 of the purchasing agency shall terminate negotiations with 14 the second design professional and commence negotiation with 15 the third firm. In the event the head of the purchasing 16 agency is unable to negotiate a satisfactory contract with 17 any of the selected firms, the selection committee shall 18 choose additional qualified firms and the head of the 19 purchasing agency shall continue negotiations in accordance 20 with this subsection until an agreement is reached. 21 (g) Selection method for Department of Transportation, 22 Department of Conservation and Natural Resources, Department of 23 Environmental Protection and instrumentalities STATE-AFFILIATED <-- 24 ENTITIES.--In the event the Department of Transportation, the 25 Department of Conservation and Natural Resources, the Department 26 of Environmental Protection or an instrumentality A STATE- <-- 27 AFFILIATED ENTITY otherwise authorized by law to use its own 28 selection committee requires the services of a design 29 professional, the head of the purchasing agency or 30 instrumentality A STATE-AFFILIATED ENTITY shall choose one of <-- 19970S0005B1478 - 68 -
1 the three firms approved by the selection committee. The head of
2 the purchasing agency or instrumentality A STATE-AFFILIATED <--
3 ENTITY shall negotiate with the firm determined to be the
4 highest qualified firm for design professional services at a fee
5 which is determined to be fair and reasonable to the
6 Commonwealth. In making this decision, the head of the
7 purchasing agency shall take into account the estimated value,
8 scope, complexity and professional nature of the services to be
9 rendered. Should the head of the purchasing agency be unable to
10 negotiate a satisfactory contract with the firm considered to be
11 the most qualified at a fee he determines to be fair and
12 reasonable to the Commonwealth, negotiations with that firm
13 shall be formally terminated. The head of the purchasing agency
14 shall then undertake negotiations with the firm he determines to
15 be the second highest qualified firm. Failing accord with the
16 second most qualified firm, the head of the purchasing agency
17 shall formally terminate negotiations and then undertake
18 negotiations with the third highest qualified firm. Should the
19 head of the purchasing agency be unable to negotiate a
20 satisfactory contract with any of the selected firms, the
21 committee shall select additional qualified firms, and the head
22 of the purchasing agency shall continue negotiations in
23 accordance with this section until an agreement is reached.
24 CHAPTER 11
25 (RESERVED)
26 CHAPTER 13
27 (Reserved)
28 CHAPTER 15
29 SUPPLY MANAGEMENT
30 Sec.
19970S0005B1478 - 69 -
1 1501. Definitions.
2 1502. Supply management regulations.
3 1503. Proceeds from sale or disposal of surplus supplies.
4 1504. EXCEPTION. <--
5 § 1501. Definitions.
6 The following words and phrases when used in this chapter
7 shall have the meanings given to them in this section unless the
8 context clearly indicates otherwise:
9 "Excess supplies." All nonexpendable supplies having a
10 remaining useful life but which are no longer required by the
11 using agency in possession of the supplies.
12 "Expendable supplies." All tangible supplies other than
13 nonexpendable supplies.
14 "Nonexpendable supplies." All tangible supplies having an
15 original acquisition cost of over $100 per unit and a probable
16 useful life of more than one year.
17 "Supplies." Supplies owned by Commonwealth agencies.
18 "Surplus supplies." Nonexpendable supplies no longer having
19 any use to any Commonwealth agency. The term includes obsolete
20 supplies, scrap materials and nonexpendable supplies that have
21 completed their useful life cycle. The term does not include
22 road or bridge materials or equipment that have been declared
23 surplus by the Department of Transportation under section 510 of
24 the act of April 9, 1929 (P.L.177, No.175), known as The
25 Administrative Code of 1929.
26 § 1502. Supply management regulations.
27 The FOR EXECUTIVE AND INDEPENDENT AGENCIES, THE department <--
28 shall establish policy and may promulgate regulations governing:
29 (1) The management of supplies during their entire life
30 cycle.
19970S0005B1478 - 70 -
1 (2) The sale, lease or disposal of surplus supplies by 2 public auction, competitive sealed bidding or other 3 appropriate method designated by the department. However, no 4 employee of the owning or disposing agency shall be entitled 5 to purchase any of these supplies except when the sale price 6 of the surplus supply is less than the amount established by 7 the department for permissible purchases by such employees. 8 (3) Transfer of excess supplies. 9 § 1503. Proceeds from sale or disposal of surplus supplies. 10 For all Commonwealth agencies and instrumentalities who <-- 11 receive funds through the State Treasury for the purchase of 12 supplies, the THE proceeds from the sale, lease or disposal of <-- 13 surplus supplies BY AN EXECUTIVE OR INDEPENDENT AGENCY shall be <-- 14 paid into the State Treasury and deposited in the fund out of 15 which the supplies sold was originally purchased by the 16 appropriate credit to the then-current appropriation. For <-- 17 Commonwealth agencies and instrumentalities who do not receive 18 funds through the State Treasury for the purchase of supplies, 19 the proceeds from any sale or disposal of surplus property shall 20 be paid to the agency or instrumentality. The costs incurred by 21 the department in advertising or selling the supplies shall be 22 deducted from the purchase price, and that amount shall be an 23 executively authorized augmentation to the appropriation from 24 which the costs were paid by the department. 25 § 1504. EXCEPTION. <-- 26 THIS CHAPTER SHALL NOT APPLY TO ACTIONS TAKEN BY THE OFFICE 27 OF ATTORNEY GENERAL UNDER 42 PA.C.S. CH. 68 (RELATING TO 28 CONTROLLED SUBSTANCES FORFEITURES). 29 CHAPTER 17 30 LEGAL AND CONTRACTUAL REMEDIES 19970S0005B1478 - 71 -
1 Subchapter 2 A. General Provisions 3 B. Prelitigation Resolution of Controversies 4 C. Board of Claims 5 D. Solicitations or Awards in Violation of Law 6 E. Interest 7 SUBCHAPTER A 8 GENERAL PROVISIONS 9 Sec. 10 1701. Definitions. 11 1702. Sovereign immunity. 12 § 1701. Definitions. 13 The following words and phrases when used in this chapter 14 shall have the meanings given to them in this section unless the 15 context clearly indicates otherwise: 16 "Claimant." A person filing a claim with the Board of 17 Claims. 18 § 1702. Sovereign immunity. 19 (a) General rule.--The General Assembly under section 11 of 20 Article I of the Constitution of Pennsylvania reaffirms 21 sovereign immunity, and, except as otherwise provided in this 22 chapter, no provision of this part shall constitute a waiver of 23 sovereign immunity for the purpose of 1 Pa.C.S. § 2310 (relating 24 to sovereign immunity reaffirmed; specific waiver) or otherwise. 25 (b) Exception.--The General Assembly under section 11 of 26 Article I of the Constitution of Pennsylvania does hereby waive 27 sovereign immunity as a bar to claims against Commonwealth 28 agencies arising under this chapter but only to the extent set 29 forth in this chapter. 30 SUBCHAPTER B 19970S0005B1478 - 72 -
1 PRELITIGATION RESOLUTION OF CONTROVERSIES 2 Sec. 3 1711. Authority to resolve protests of solicitations or 4 awards. 5 1712. Authority to resolve contract and breach of contract 6 controversies. 7 § 1711. Authority to resolve protests of solicitations or 8 awards. 9 (a) Right to protest.--An actual or prospective bidder, 10 offeror or contractor who is aggrieved in connection with the 11 solicitation or award of a contract may protest to the head of 12 the purchasing agency in writing. All protests under this 13 subsection must be made within seven days after the protestant 14 knows or should have known of the facts giving rise to the 15 protest. If a protest is submitted by a protestant who did not 16 submit a bid, the protest must be received by the head of the 17 purchasing agency prior to the bid opening time or the proposal 18 receipt date or it shall be considered untimely and can be 19 disregarded by the purchasing agency. 20 (b) Authority to resolve protests.--The head of the 21 purchasing agency shall have the authority to settle and resolve 22 a protest of an aggrieved bidder, offeror or contractor, actual 23 or prospective, concerning the solicitation or award of a 24 contract. 25 (c) Decision.--If the protest is not resolved by mutual 26 agreement, the head of the purchasing agency shall promptly, BUT <-- 27 IN NO EVENT LATER THAN 120 DAYS FROM THE FILING OF THE PROTEST, 28 issue a decision in writing. The decision shall: 29 (1) State the reasons for the action taken. 30 (2) Inform the protestant of his right to file an action 19970S0005B1478 - 73 -
1 in Commonwealth Court as provided in subsection (e). 2 (d) Notice of decision.--A copy of the decision under 3 subsection (c) shall be delivered by registered mail to the 4 protestant and any other person determined by the head of the 5 purchasing agency to be affected by the decision. 6 (e) Finality of decision.--A decision under subsection (c) 7 shall be final and conclusive unless a person adversely affected 8 by the decision files an action based on subsection (a) in 9 Commonwealth Court within 14 days of receipt of the decision. No 10 action may be commenced in Commonwealth Court under this 11 subsection until the protestant has exhausted the administrative 12 remedies provided for in this section. 13 (f) Stay of procurements during protests.--In the event of a 14 timely protest under subsection (a) and until the time has 15 elapsed for the protestant to file an action in Commonwealth 16 Court, the purchasing agency shall not proceed further with the 17 solicitation or with the award of the contract unless and until 18 the head of the purchasing agency, after consultation with the 19 head of the using agency, makes a written determination that the 20 protest is clearly without merit or that award of the contract 21 without delay is necessary to protect substantial interests of 22 the Commonwealth. 23 § 1712. Authority to resolve contract and breach of contract 24 controversies. 25 (a) Applicability.--This section applies to controversies 26 between a Commonwealth agency and a contractor which arise under 27 or by virtue of a contract between them, including controversies 28 based upon breach of contract, mistake, misrepresentation or 29 other cause for contract modification or rescission. Prior to 30 filing a claim under this section with the Board of Claims under 19970S0005B1478 - 74 -
1 the exclusive jurisdiction provided in the act of May 20, 1937 2 (P.L.728, No.193), referred to as the Board of Claims Act, the 3 claim must first be filed in writing with the contracting 4 officer within six months after it accrues and not thereafter. 5 (b) Authority.--The contracting officer is authorized to 6 settle and resolve a controversy described in subsection (a). 7 (c) Decision.--If the controversy is not resolved by mutual 8 agreement, the head of the purchasing agency shall promptly 9 issue a decision in writing. The decision shall: 10 (1) State the reasons for the action taken. 11 (2) Inform the contractor of its right to administrative 12 and judicial review as provided in this chapter. 13 (d) Notice of decision.--A copy of the decision under 14 subsection (c) shall be delivered by registered mail to the 15 contractor. 16 (e) Finality of decision.--The decision under subsection (c) 17 shall be final and conclusive unless the contractor files a 18 claim with the Board of Claims within 30 days of receipt of the 19 decision. 20 (f) Failure to render timely decision.--If the contracting 21 officer does not issue the written decision required under 22 subsection (c) within 120 days after written request for a final 23 decision or within a longer period as may be agreed upon by the 24 parties, then the contractor may proceed as if an adverse 25 decision had been received. 26 SUBCHAPTER C 27 BOARD OF CLAIMS 28 Sec. 29 1721. Function of Board of Claims. 30 1722. (Reserved). 19970S0005B1478 - 75 -
1 1723. (Reserved). 2 1724. (Reserved). 3 1725. Hearings, decisions and awards. 4 1726. Appeals. 5 § 1721. Function of Board of Claims. 6 The Board of Claims created under the act of May 20, 1937 7 (P.L.728, No.193), referred to as the Board of Claims Act, shall 8 be constituted and administered as provided in that act. 9 § 1722. (Reserved). 10 § 1723. (Reserved). 11 § 1724. (Reserved). 12 § 1725. Hearings, decisions and awards. 13 (a) General rule.--All hearings before the Board of Claims 14 under this part shall be in accordance with the procedure set 15 forth in the act of May 20, 1937 (P.L.728, No.193), referred to 16 as the Board of Claims Act. 17 (b) Hearing and decision.--All hearings before the Board of 18 Claims or hearings before a hearing panel shall be public and 19 the proceedings shall be de novo. Any prior determinations by 20 administrative officials shall not be final or conclusive except 21 as provided in section 561 (relating to finality of 22 determinations). The board or hearing panel shall make a 23 decision within a reasonable time from the date of the hearing. 24 The board shall promptly decide the contract or breach of 25 contract controversy and, if appropriate, make an award of a sum 26 that it determines the claimant is entitled to receive. 27 (c) Certification of award.--The Board of Claims shall 28 certify an award for the purpose of entering the same as a 29 judgment in any court of record. 30 (d) Public records.--All papers filed under this subchapter 19970S0005B1478 - 76 -
1 shall be a public record to the extent provided in the act of 2 June 21, 1957 (P.L.390, No.212), referred to as the Right-to- 3 Know Law, and shall be available to the public as provided in 4 that act. 5 § 1726. Appeals. 6 Any person, including a Commonwealth agency, aggrieved by a 7 decision of the Board of Claims may appeal to the Commonwealth 8 Court under 42 Pa.C.S. § 763(a)(1) (relating to direct appeals 9 from government agencies) within 30 days after certification of 10 the decision. 11 SUBCHAPTER D 12 SOLICITATIONS OR AWARDS IN VIOLATION OF LAW 13 Sec. 14 1741. Applicability. 15 1742. Remedies prior to execution of contract. 16 1743. Remedies after execution of contract. 17 § 1741. Applicability. 18 The provisions of this subchapter apply where it is 19 determined by the contracting officer or the court that a 20 solicitation or award of a contract is in violation of law. 21 § 1742. Remedies prior to execution of contract. 22 If prior to execution of a contract it is determined that a 23 solicitation or proposed award of a contract is in violation of 24 law, then the remedies are limited to cancellation of the 25 solicitation or proposed award or revision of the solicitation 26 or proposed award to comply with the law. 27 § 1743. Remedies after execution of contract. 28 If after the execution of a contract it is determined that a 29 solicitation or award of a contract is in violation of law, 30 then: 19970S0005B1478 - 77 -
1 (1) If the person awarded the contract has not acted 2 fraudulently or in bad faith: 3 (i) the contract may be ratified and affirmed 4 provided it is determined by the purchasing agency that 5 doing so is in the best interest of the Commonwealth; 6 (ii) the contract, with the consent of all parties, 7 may be modified to comply with the law; or 8 (iii) the contract may be terminated and the person 9 awarded the contract shall be compensated for the actual 10 expenses reasonably incurred under the contract prior to 11 the termination. Such compensation shall not include loss 12 of anticipated profit, loss of use of money or 13 administrative or overhead costs. 14 (2) If the person awarded the contract has acted 15 fraudulently or in bad faith: 16 (i) the contract may be declared void; 17 (ii) the contract, with the consent of all parties, 18 may be modified to comply with the law; or 19 (iii) the contract may be ratified and affirmed, 20 provided it is determined by the purchasing agency, if 21 that action is in the best interest of the Commonwealth 22 and without prejudice to the right of the Commonwealth 23 agency to damages as may be appropriate. 24 SUBCHAPTER E 25 INTEREST 26 Sec. 27 1751. Interest. 28 § 1751. Interest. 29 Interest on amounts ultimately determined to be due shall be 30 payable at the statutory rate applicable to judgments from the 19970S0005B1478 - 78 -
1 date the claim was filed with the contracting officer. Interest 2 on claims arising out of the provisions of section 1507 of the 3 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 4 Code, shall be payable as provided therein. 5 CHAPTER 19 6 INTERGOVERNMENTAL RELATIONS 7 Sec. 8 1901. Definitions. 9 1902. Cooperative purchasing authorized. 10 1903. Sale, acquisition or use of supplies by a public 11 procurement unit. 12 1904. Cooperative use of supplies or services. 13 1905. Joint use of facilities. 14 1906. Supply of personnel, information and technical services. 15 1907. Use of payments received by a supplying public 16 procurement unit. 17 1908. Compliance of public procurement units. 18 1909. Review of procurement requirements. 19 1910. Contract controversies. 20 1911. IMMUNITY. <-- 21 1912. INVESTMENT MANAGEMENT AGREEMENTS. 22 § 1901. Definitions. 23 The following words and phrases when used in this chapter 24 shall have the meanings given to them in this section unless the 25 context clearly indicates otherwise: 26 "Cooperative purchasing." Procurement conducted by or on 27 behalf of more than one public procurement unit or by a public 28 procurement unit with an external procurement activity. 29 "External procurement activity." A buying organization not 30 located in this Commonwealth which if located in this 19970S0005B1478 - 79 -
1 Commonwealth would qualify as a public procurement unit. An 2 agency of the United States is an external procurement activity. 3 "Local public procurement unit." A political subdivision, 4 public authority, educational, health or other institution and, 5 to the extent provided by law, any other entity, including a 6 council of governments or an area government, which expends 7 public funds for the procurement of supplies, services and 8 construction, any nonprofit corporation operating a charitable 9 hospital and any nonprofit fire company, nonprofit rescue 10 company and nonprofit ambulance company. 11 "Public procurement unit." A local public procurement unit 12 or a purchasing agency. 13 § 1902. Cooperative purchasing authorized. 14 A public procurement unit may either participate in, sponsor, 15 conduct or administer a cooperative purchasing agreement for the 16 procurement of any supplies, services or construction with one 17 or more public procurement units or external procurement 18 activities in accordance with an agreement entered into between 19 the participants. Cooperative purchasing may include, but is not 20 limited to, joint or multiparty contracts between public 21 procurement units and open-ended purchasing agency contracts 22 which are made available to local public procurement units. 23 § 1903. Sale, acquisition or use of supplies by a public 24 procurement unit. 25 A public procurement unit may sell to, acquire from or use 26 any supplies belonging to another public procurement unit or 27 external procurement activity independent of the requirements of 28 Chapters 5 (relating to source selection and contract formation) 29 and 15 (relating to supply management). 30 § 1904. Cooperative use of supplies or services. 19970S0005B1478 - 80 -
1 A public procurement unit may enter into an agreement, 2 independent of the requirements of Chapters 5 (relating to 3 source selection and contract formation) and 15 (relating to 4 supply management), with any other public procurement unit or 5 external procurement activity for the cooperative use of 6 supplies or services under the terms agreed upon between the 7 parties. 8 § 1905. Joint use of facilities. 9 Any public procurement unit may enter into agreements for the 10 common use or lease of warehousing facilities, capital equipment 11 and other facilities with another public procurement unit or an 12 external procurement activity under the terms agreed upon 13 between the parties. 14 § 1906. Supply of personnel, information and technical 15 services. 16 (a) Supply of personnel.--Upon written request from another 17 public procurement unit or external procurement activity, a 18 public procurement unit may provide personnel to the requesting 19 public procurement unit or external procurement activity. The 20 public procurement unit or external procurement activity making 21 the request shall compensate the public procurement unit 22 providing the personnel the direct and indirect cost of 23 furnishing the personnel in accordance with an agreement between 24 the parties. 25 (b) Supply of services.--The informational, technical and 26 other services of any public procurement unit may be made 27 available to any other public procurement unit or external 28 procurement activity. However, the requirements of the public 29 procurement unit tendering the services shall have precedence 30 over the requesting public procurement unit or external 19970S0005B1478 - 81 -
1 procurement activity. The requesting public procurement unit or 2 external procurement activity shall compensate for the expenses 3 of the services provided in accordance with an agreement between 4 the parties. 5 (c) Information services.--Upon request, the department may 6 make available to public procurement units or external 7 procurement activities the following services, among others: 8 (1) Standard forms. 9 (2) Printed manuals. 10 (3) Product specifications and standards. 11 (4) Quality assurance testing services and methods. 12 (5) Qualified products lists. 13 (6) Source information. 14 (7) Common use commodities listings. 15 (8) Supplier prequalification information. 16 (9) Supplier performance ratings. 17 (10) Debarred and suspended bidders lists. 18 (11) Forms for invitations for bids, requests for 19 proposals, instructions to bidders, general contract 20 provisions and other contract forms. 21 (12) Contracts or published summaries of contracts, 22 including price and time of delivery information. 23 (d) Technical services.--The department may provide the 24 following technical services, among others: 25 (1) Development of products specifications. 26 (2) Development of quality assurance test methods, 27 including receiving, inspection and acceptance procedures. 28 (3) Use of product testing and inspection facilities. 29 (4) Use of personnel training programs. 30 (e) Fees.--The department may enter into contractual 19970S0005B1478 - 82 -
1 arrangements and publish a schedule of fees for the services 2 provided under subsections (c) and (d). 3 § 1907. Use of payments received by a supplying public 4 procurement unit. 5 All payments from any public procurement unit or external 6 procurement activity received by a public procurement unit 7 supplying personnel or services shall be available to the 8 supplying public procurement unit. 9 § 1908. Compliance of public procurement units. 10 Where the public procurement unit or external procurement 11 activity administering a cooperative purchase complies with the 12 requirements of this part, any public procurement unit 13 participating in the purchase shall be deemed to have complied 14 with this part. Public procurement units may not enter into a 15 cooperative purchasing agreement for the purpose of 16 circumventing this part. 17 § 1909. Review of procurement requirements. 18 To the extent possible, the department may collect 19 information concerning the type, cost, quality and quantity of 20 commonly used supplies, services or construction being procured 21 or used by Commonwealth agencies. The department may also 22 collect this information from local procurement units. The 23 department may make this information available to any public 24 procurement unit upon request. 25 § 1910. Contract controversies. 26 (a) Public procurement unit subject to certain legal and 27 contractual remedies.--Under a cooperative purchasing agreement, 28 controversies arising between an administering public 29 procurement unit subject to Chapter 17 (relating to legal and 30 contractual remedies) and its bidders, offerors or contractors 19970S0005B1478 - 83 -
1 shall be resolved in accordance with Chapter 17. 2 (b) Local public procurement unit not subject to certain 3 legal and contractual remedies.--Any local public procurement 4 unit which is not subject to Chapter 17 is authorized to: 5 (1) Enter into an agreement with the Board of Claims to 6 use the board to resolve controversies between the local 7 public procurement unit and its contractors, whether or not 8 the controversy arose from a cooperative purchasing 9 agreement. 10 (2) Enter into an agreement with another local public 11 procurement unit or external procurement activity to 12 establish procedures or use existing procedures of the unit 13 or activity to resolve controversies with contractors, 14 whether or not the controversy arose under a cooperative 15 purchasing agreement. 16 § 1911. IMMUNITY. <-- 17 A PUBLIC PROCUREMENT UNIT WHICH PROVIDES PERSONNEL, PROPERTY, 18 SUPPLIES OR SERVICES TO ANOTHER PUBLIC PROCUREMENT UNIT SHALL BE 19 IMMUNE FROM LIABILITY FOR ANY DAMAGES WHICH ARISE OUT OF THE USE 20 OF SUCH ITEMS PROVIDED UNDER THIS CHAPTER. 21 § 1912. INVESTMENT MANAGEMENT AGREEMENTS. 22 THIS CHAPTER SHALL NOT APPLY TO ANY CONTRACT FOR INVESTMENT 23 MANAGEMENT SERVICES, OR ANY PROPOSED CONTRACT FOR SUCH SERVICES, 24 BETWEEN A LOCAL PUBLIC PROCUREMENT UNIT AND THE TREASURY 25 DEPARTMENT. 26 CHAPTER 21 27 SMALL AND DISADVANTAGED BUSINESSES 28 Sec. 29 2101. Policy. 30 2102. Definitions. 19970S0005B1478 - 84 -
1 2103. Regulations. 2 2104. Duties of department. 3 2105. Bonding and progress payments. 4 2106. Business assistance offices. 5 2107. Report to General Assembly. 6 2108. Compliance with Federal requirements. 7 § 2101. Policy. 8 The policy of this Commonwealth is to assist small and 9 disadvantaged businesses in learning how to do business with 10 Commonwealth agencies. The department shall implement this 11 policy in accordance with regulations promulgated by the 12 department. 13 § 2102. Definitions. 14 Subject to section 2103 (relating to regulations), the 15 following words and phrases when used in this chapter shall have 16 the meanings given to them in this section unless the context 17 clearly indicates otherwise: 18 "Disadvantaged business." A small business which is owned or 19 controlled by a majority of persons, not limited to members of 20 minority groups, who have been deprived of the opportunity to 21 develop and maintain a competitive position in the economy 22 because of social disadvantages. 23 "Small business." A business in the United States which is 24 independently owned and which, is not dominant in its field of <-- 25 operation or an affiliate or subsidiary of a business dominant <-- 26 in its field of operation. AND MEETS THE CRITERIA ESTABLISHED BY <-- 27 THE DEPARTMENT OF GENERAL SERVICES, BY REGULATION, FOR 28 QUALIFICATION AS A SMALL BUSINESS. THE DEPARTMENT, THROUGH 29 REGULATION, SHALL HAVE THE AUTHORITY TO ESTABLISH THE MAXIMUM 30 NUMBER OF PERSONS A COMPANY MAY EMPLOY TO QUALIFY AS A SMALL 19970S0005B1478 - 85 -
1 BUSINESS, WHICH NUMBER SHALL NOT EXCEED 50 PERSONS. 2 § 2103. Regulations. 3 The department shall establish policy FOR EXECUTIVE AND THOSE <-- 4 INDEPENDENT AGENCIES FOR WHICH THE DEPARTMENT ACTS AS PURCHASING 5 AGENCY and may promulgate regulations establishing detailed 6 definitions of the words and phrases defined in section 2102 7 (relating to definitions) using, in addition to the criteria set 8 forth in section 2102, other criteria as it deems appropriate, 9 including the number of employees and the dollar volume of 10 business. STATE-AFFILIATED ENTITIES SHALL IMPLEMENT THE POLICY <-- 11 FOR THEIR PROCUREMENT PROGRAMS. 12 § 2104. Duties of department. 13 The department shall have the following duties: 14 (1) Where feasible, provide appropriate staff who shall 15 be responsible to the department and who shall serve within 16 designated Commonwealth agencies to assist small and 17 disadvantaged businesses in this Commonwealth in learning how 18 to do business with Commonwealth agencies. 19 (2) Give special publicity to procurement procedures and 20 issue special publications designed to assist small and 21 disadvantaged businesses in learning how to do business with 22 Commonwealth agencies. 23 (3) Compile, maintain and make available source lists of 24 small and disadvantaged businesses for the purpose of 25 encouraging procurement from small and disadvantaged 26 businesses. 27 (4) Include small and disadvantaged businesses on 28 solicitation mailing lists. 29 (5) Assure that small and disadvantaged businesses are 30 solicited on each procurement for which the businesses may be 19970S0005B1478 - 86 -
1 suited. 2 (6) Develop special training programs to assist small 3 and disadvantaged businesses in learning how to do business 4 with Commonwealth agencies. 5 § 2105. Bonding and progress payments. 6 (a) Bonding.--Notwithstanding other provisions of this part, 7 a purchasing agency may reduce the level or change the types of 8 bonding normally required or accept alternative forms of 9 security to the extent reasonably necessary to encourage 10 procurement from small and disadvantaged businesses. 11 (b) Progress payments.--A purchasing agency may make special 12 provisions for progress payments as it deems reasonably 13 necessary to encourage procurement from small and disadvantaged 14 businesses. 15 § 2106. Business assistance offices. 16 The department shall establish, as it deems appropriate, 17 business assistance offices throughout this Commonwealth to 18 assist and carry out the provisions of this chapter. 19 § 2107. Report to General Assembly. 20 The department shall annually, before October 1, report in 21 writing to the General Assembly concerning the awarding of 22 contracts to small and disadvantaged businesses during the 23 preceding fiscal year. 24 § 2108. Compliance with Federal requirements. 25 If a procurement involves the expenditure of Federal 26 assistance or contract funds, the purchasing agency shall comply 27 with Federal law and authorized regulations which are 28 mandatorily applicable and which are not presently reflected in 29 this part. 30 CHAPTER 23 19970S0005B1478 - 87 -
1 ETHICS IN PUBLIC CONTRACTING 2 Subchapter 3 A. General Policy and Standards 4 B. Specific Standards 5 SUBCHAPTER A 6 GENERAL POLICY AND STANDARDS 7 Sec. 8 2301. Policy. 9 2302. General standards of ethical conduct. 10 2303. Reporting of breaches of ethical standards. 11 § 2301. Policy. 12 Public employment is a public trust. It is the policy of this 13 Commonwealth to promote and balance the objective of protecting 14 government integrity and the objective of facilitating the 15 recruitment and retention of personnel needed by this 16 Commonwealth. Implementation of this policy requires that public 17 employees discharge their duties impartially so as to assure 18 fair competitive access to Commonwealth agency procurement by 19 responsible contractors and that they conduct themselves in a 20 manner that fosters public confidence in the integrity of the 21 Commonwealth procurement process. It is also essential that 22 those doing business with the Commonwealth agencies observe high 23 standards of honesty and integrity. 24 § 2302. General standards of ethical conduct. 25 (a) Employees.--Any attempt to realize personal gain through 26 public employment by conduct inconsistent with the proper 27 discharge of the duties of the employee is a breach of a public 28 trust. In order to fulfill this general prescribed standard, 29 employees must avoid any conflict of interest or improper use of 30 confidential information. 19970S0005B1478 - 88 -
1 (b) Nonemployees.--Any effort to influence any employee to 2 breach the standards of ethical conduct set forth in this 3 section is also a breach of ethical standards. 4 § 2303. Reporting of breaches of ethical standards. 5 When any person has reason to believe that any breach of 6 standards set forth in this chapter has occurred, that person 7 shall report all relevant facts to the State Ethics Commission 8 and to the Attorney General for any appropriate action. 9 SUBCHAPTER B 10 SPECIFIC STANDARDS 11 Sec. 12 2311. Bonds. 13 § 2311. Bonds. 14 It is a breach of ethical standards and unlawful for any 15 employee in issuing an invitation for bids or requests for 16 proposals to require that any bond required by this part be 17 furnished by a particular surety company or through a particular 18 agent or broker. Any employee who violates this section commits 19 a misdemeanor of the first degree. 20 PART II 21 GENERAL PROCUREMENT PROVISIONS 22 Chapter 23 31. General Provisions 24 33. Prevention of Environmental Pollution 25 35. (Reserved) 26 37. Contract Clauses and Preference Provisions 27 39. Construction Contracts Over $50,000 28 41. Purchase of Surplus Federal Property 29 43. Public Facilities Concessions 30 45. Antibid-Rigging 19970S0005B1478 - 89 -
1 CHAPTER 31
2 GENERAL PROVISIONS
3 Sec.
4 3101. Application of part.
5 3102. Definitions.
6 § 3101. Application of part.
7 This part applies to government agencies. In the case of
8 Commonwealth agencies, this part shall be read in pari materia
9 with Part I (relating to Commonwealth Procurement Code).
10 § 3102. Definitions.
11 Subject to additional definitions contained in subsequent
12 provisions of this part which are applicable to specific
13 provisions of this part, the following words and phrases when
14 used in this part shall have the meanings given to them in this
15 section unless the context clearly indicates otherwise:
16 "Commonwealth agency." A Commonwealth agency as defined in
17 section 103 (relating to definitions).
18 "Government agency." Any Commonwealth agency, ANY <--
19 TRANSPORTATION AUTHORITY OR AGENCY CREATED BY STATUTE or any
20 political subdivision or municipal or other local authority, or
21 any officer or agency of any political subdivision or local <--
22 authority.
23 CHAPTER 33
24 PREVENTION OF ENVIRONMENTAL POLLUTION
25 Sec.
26 3301. Invitations for bids and requests for proposals.
27 3302. Additional work.
28 § 3301. Invitations for bids and requests for proposals.
29 All invitations for bids and requests for proposals for
30 construction projects issued by any government agency shall set
19970S0005B1478 - 90 -
1 forth any provision of Federal and State statutes, rules and 2 regulations dealing with the prevention of environmental 3 pollution and the preservation of public natural resources that 4 affect the projects. 5 § 3302. Additional work. 6 If the successful bidder or offeror must undertake additional 7 work due to the enactment of new or the amendment of existing 8 statutes, rules or regulations occurring after the submission of 9 the successful bid or proposal, the government agency shall 10 issue a change order setting forth the additional work that must 11 be undertaken, which shall not invalidate the contract. The cost 12 of a change order to the government agency shall be determined 13 in accordance with the provisions of the contract for change 14 orders or force accounts, or, if there is not a provision set 15 forth in the contract, then the cost to the government agency 16 shall be the costs to the contractor for wages, labor costs 17 other than wages, wage taxes, materials, equipment rentals, 18 insurance and subcontracts attributable to the additional 19 activity plus a reasonable sum for overhead and profit. 20 Additional costs to undertake work not specified in the 21 invitation for bids or requests for proposals shall not be 22 approved unless written authorization is given the successful 23 bidder or offeror prior to its undertaking the additional 24 activity. 25 CHAPTER 35 26 (RESERVED) 27 CHAPTER 37 28 CONTRACT CLAUSES AND PREFERENCE PROVISIONS 29 Subchapter 30 A. Labor 19970S0005B1478 - 91 -
1 B. Steel Products
2 C. Trade Practices
3 D. Motor Vehicles
4 E. Used Oil Products
5 F. Guaranteed Energy Savings Contracts
6 SUBCHAPTER A
7 LABOR
8 Sec.
9 3701. Contract provisions prohibiting discrimination.
10 3702. Contract provision requiring residents to be employed. <--
11 § 3701. Contract provisions prohibiting discrimination.
12 Each contract entered into by a government agency for the
13 construction, alteration or repair of any public building or
14 public work shall contain the following provisions by which the
15 contractor agrees that:
16 (1) In the hiring of employees for the performance of
17 work under the contract or any subcontract, no contractor,
18 subcontractor or any person acting on behalf of the
19 contractor or subcontractor shall by reason of gender, race,
20 creed or color discriminate against any citizen of this
21 Commonwealth who is qualified and available to perform the
22 work to which the employment relates.
23 (2) No contractor or subcontractor or any person on
24 their behalf shall in any manner discriminate against or
25 intimidate any employee hired for the performance of work
26 under the contract on account of gender, race, creed or
27 color.
28 (3) The contract may be canceled or terminated by the
29 government agency, and all money due or to become due under
30 the contract may be forfeited for a violation of the terms or
19970S0005B1478 - 92 -
1 conditions of that portion of the contract. 2 § 3702. Contract provision requiring residents to be employed. <-- 3 Each contract entered into by a government agency for the 4 construction, alteration or repair of any public works shall 5 contain a provision that laborers and mechanics employed on the 6 public works shall have been residents of this Commonwealth for 7 at least 90 days prior to their employment. Failure to comply 8 with this section shall be sufficient legal reason to refuse 9 payment of the contract price to the contractor. 10 SUBCHAPTER B 11 STEEL PRODUCTS 12 Sec. 13 3711. Short title of subchapter and general provisions. 14 3712. Definitions. 15 3713. Requirement of contract provision. 16 3714. Payments under contracts. 17 § 3711. Short title of subchapter and general provisions. 18 (a) Short title.--This subchapter shall be known and may be 19 cited as the Steel Products Procurement Act. 20 (b) Legislative findings.--It is hereby determined by the 21 General Assembly to reaffirm the legislative findings contained 22 in the act of March 3, 1978 (P.L.6, No.3), known as the Steel 23 Products Procurement Act, and codified in this chapter: 24 (1) This Commonwealth is one of the leading states in 25 the United States in the production of steel. 26 (2) The production of steel products constitutes a major 27 industry of this Commonwealth and, as such, provides the jobs 28 and family incomes of hundreds of thousands of the people of 29 this Commonwealth and, in turn, millions of persons in the 30 United States. 19970S0005B1478 - 93 -
1 (3) The taxes paid to the Commonwealth and its political 2 subdivisions by employers and employees engaged in the 3 production and sale of steel products are one of the largest 4 single sources of public revenues in this Commonwealth. 5 (4) It has, for many years, been the policy of this 6 Commonwealth to aid and support the development and expansion 7 of industry in this Commonwealth in order to foster the 8 economic well-being of this Commonwealth and its people. 9 (5) The economy and general welfare of this Commonwealth 10 and its people, as well as the economy, general welfare and 11 national security of the United States, are inseparably 12 related to the preservation and development of the steel 13 industry in this Commonwealth and in the other states of the 14 United States. The General Assembly therefore declares it to 15 be the policy of this Commonwealth that all public officers 16 and agencies should, at all times, aid and promote the 17 development of the steel industry of the United States in 18 order to stimulate and improve the economic well-being of 19 this Commonwealth and its people. 20 (c) Police power.--This chapter shall be deemed to be an 21 exercise of the police powers of this Commonwealth for the 22 protection of the health, safety and general welfare of the 23 people of this Commonwealth. 24 (d) Purpose of chapter.--This chapter is intended as 25 remedial legislation designed to promote the general welfare and 26 stimulate the economy of this Commonwealth and its people; each 27 and every provision of this chapter is intended to receive a 28 liberal construction as will best effectuate that purpose, and 29 no provision is intended to receive a strict or limited 30 construction. 19970S0005B1478 - 94 -
1 § 3712. Definitions. 2 The following words and phrases when used in this subchapter 3 shall have the meanings given to them in this section unless the 4 context clearly indicates otherwise: 5 "Steel products." Products rolled, formed, shaped, drawn, 6 extruded, forged, cast, fabricated or otherwise similarly 7 processed, or processed by a combination of two or more of these 8 operations, from steel made in the United States by the open 9 hearth, basic oxygen, electric furnace, Bessemer or other steel- 10 making process. The term includes cast iron products. The term 11 also includes machinery and equipment listed in United States 12 Department of Commerce Standard Industrial Classification 25 13 (furniture and fixture), 35 (machinery, except electrical) and 14 37 (transportation equipment) and made of, fabricated from or 15 containing steel components. If a product contains both foreign 16 and United States steel, the product shall be determined to be a 17 United States steel product only if at least 75% of the cost of 18 the articles, materials and supplies have been mined, produced 19 or manufactured, as the case may be, in the United States. 20 Transportation equipment shall be determined to be a United 21 States steel product if it complies with section 165 of the 22 Surface Transportation Assistance Act of 1982 (Public Law 97- 23 424, 96 Stat. 2097). 24 "United States." The United States of America, including all 25 territory, continental or insular, subject to the jurisdiction 26 of the United States. 27 § 3713. Requirement of contract provision. 28 (a) General rule.--Each construction contract in excess of 29 $250,000 which is entered into by a government agency shall 30 contain a provision that if any steel products are to be used or 19970S0005B1478 - 95 -
1 supplied in the performance of the contract, only steel products 2 as defined in this subchapter shall be used or supplied in the 3 performance of the contract or any subcontracts. The amount of 4 $250,000 shall be adjusted annually by the department to reflect 5 the annual percentage change in the Composite Construction Cost 6 Index of the United States Department of Commerce occurring in 7 the one-year period ending on December 31 of each year. 8 (b) Exception.--This section does not apply in any case 9 where the head of the government agency in writing determines 10 that steel products as defined in this subchapter are not 11 produced in the United States in sufficient quantities to meet 12 the requirements of the contract. 13 § 3714. Payments under contracts. 14 (a) Compliance with required contract provisions.--No 15 government agency shall authorize, provide for or make any 16 payments to any person under any contract containing the 17 provision required by section 3713 (relating to requirement of 18 contract provision) unless, when unidentified steel products are 19 supplied under a contract, the person has provided 20 documentation, including, but not limited to, invoices, bills of 21 lading and mill certification that the steel was melted and 22 manufactured in the United States, which establishes that the 23 person has fully complied with section 3713. If a steel product 24 is identifiable from its face, the person must submit 25 certification which satisfies the government agency that the 26 person has fully complied with section 3713. Any payments made 27 to any person by any government agency which should not have 28 been made as a result of this section shall be recoverable by 29 either the government agency or the Attorney General directly 30 from the contractor, subcontractor, manufacturer or supplier who 19970S0005B1478 - 96 -
1 did not comply with section 3713. 2 (b) Penalties.--In addition to the withholding of payments, 3 any person who willfully violates any of the provisions of this 4 subchapter shall be prohibited from submitting any bids to any 5 government agency for any contract for a period of three years 6 from the date of the determination that a violation has 7 occurred. In the event the person who violates the provisions of 8 section 3713 is a subcontractor, manufacturer or supplier, that 9 person shall be prohibited from performing any work or supplying 10 any materials to a government agency for a period of three years 11 from the date of the determination that a violation has 12 occurred. 13 (c) Application of Title 2.--Title 2 (relating to 14 administrative law and procedure) applies to decisions by 15 government agencies that a person has violated section 3713. 16 SUBCHAPTER C 17 TRADE PRACTICES 18 Sec. 19 3721. Short title of subchapter and general provisions. 20 3722. Definitions. 21 3723. Unlawful acts. 22 3724. Preference for aluminum and steel products made in 23 United States. 24 3725. Requirement to list discriminating countries. 25 3726. Procedure to determine discrimination. 26 3727. Foreign registry docket. 27 3728. Aluminum or steel products from a country listed on 28 foreign registry docket. 29 § 3721. Short title of subchapter and general provisions. 30 (a) Short title.--This subchapter shall be known and may be 19970S0005B1478 - 97 -
1 cited as the Trade Practices Act. 2 (b) Legislative findings.--It is hereby determined by the 3 General Assembly to reaffirm the legislative findings contained 4 in the act of July 23, 1968 (P.L.686, No.226), entitled "An act 5 equalizing trade practices in public works procurement; 6 authorizing the purchase by the Commonwealth, its political 7 subdivisions, and all public agencies, of aluminum and steel 8 products produced in a foreign country, provided the foreign 9 country does not prohibit or discriminate against the 10 importation to, sale or use in the foreign country of supplies, 11 material or equipment manufactured in this Commonwealth; 12 establishing procedures for determining whether foreign 13 countries discriminate against supplies, materials or equipment 14 manufactured in this Commonwealth; and imposing penalties and 15 providing for relief for violation of this act," and codified in 16 this chapter: 17 (1) It has long been the policy of this Commonwealth not 18 to purchase any supplies, equipment or materials manufactured 19 in any foreign country which prohibits the specification for 20 or use of supplies, equipment or materials manufactured in 21 this Commonwealth. 22 (2) Many world trading countries, directly or indirectly 23 by statute, regulation, policy, procedure or practice, grant 24 or bestow a preference for supplies, equipment or materials 25 manufactured in their country, thereby discriminating against 26 the use of supplies, equipment or materials manufactured in 27 this Commonwealth. The General Assembly therefore declares it 28 to be the policy of this Commonwealth that aluminum and steel 29 products made in the United States should be purchased by all 30 public agencies in preference to aluminum and steel products 19970S0005B1478 - 98 -
1 made in foreign countries which discriminate against 2 supplies, equipment or materials manufactured in this 3 Commonwealth. 4 (c) Purpose of subchapter.--This subchapter is intended as 5 remedial legislation designed to promote the general welfare and 6 stimulate the economy of this Commonwealth and its people; each 7 and every provision of this chapter is intended to receive a 8 liberal construction as will best effectuate the purpose, no 9 provision is intended to receive a strict or limited 10 construction. 11 § 3722. Definitions. 12 The following words and phrases when used in this subchapter 13 shall have the meanings given to them in this section unless the 14 context clearly indicates otherwise: 15 "Aluminum or steel products made in a foreign country." 16 Aluminum or steel products rolled, formed, shaped, drawn, 17 extruded, forged, cast, fabricated or otherwise similarly 18 processed, or processed by a combination of two or more of these 19 operations, from aluminum or steel not made in the United 20 States. 21 "Court." The Commonwealth Court. 22 "Discriminates." Any statute, regulation or policy of a 23 foreign country which directly or indirectly: 24 (1) Prevents the importation, sale or use of any 25 supplies, materials or equipment manufactured in this 26 Commonwealth. 27 (2) Grants or bestows a preference, discount or other 28 competitive advantage to supplies, materials or equipment 29 manufactured in the foreign country, the effect of which is 30 to place similar supplies, materials or equipment 19970S0005B1478 - 99 -
1 manufactured in this Commonwealth at a competitive 2 disadvantage. 3 (3) Restricts the opportunities for persons having a 4 business situs in this Commonwealth to bid on or compete for 5 government contracts, including, but not limited to, a 6 preference for residents of the foreign country. 7 (4) Solicits for awards or negotiates public works 8 contracts on a selective tender basis. 9 (5) Imposes discriminatory duties, tariffs or border 10 taxes on the importation of supplies, materials or equipment 11 not produced in the foreign country, the effect of which is 12 to place supplies, materials or equipment manufactured in 13 this Commonwealth at a competitive disadvantage with like 14 goods manufactured in any foreign country. 15 (6) Adopts or condones any other unfair method of 16 competition in international trade, including, but not 17 limited to, the exportation of aluminum or steel products 18 made in the foreign country through cartels or the 19 subsidization of aluminum or steel products. 20 "Importer." Any person registered and doing business in this 21 Commonwealth who engages in the receiving, storing, distributing 22 or other processing of aluminum or steel products made in a 23 foreign country or who engages in the solicitation or acceptance 24 of orders or contracts for the furnishing of or supplying of 25 aluminum or steel products made in a foreign country. 26 "Public works." Any structure, building, highway, waterway, 27 street, bridge, pier, transit car or system, airport or other 28 betterment, work or improvement, whether of a permanent or 29 temporary nature and whether for governmental or proprietary use 30 contracted for by any government agency or financed in whole or 19970S0005B1478 - 100 -
1 in part by any government agency. 2 § 3723. Unlawful acts. 3 It is unlawful for: 4 (1) Any government agency to specify, purchase or permit 5 to be furnished or used in any public works aluminum or steel 6 products made in a foreign country which has been determined 7 as discriminating by the court unless the amount of the 8 purchase or contract is equal to or less than $250,000. This 9 amount shall be adjusted annually by the department to 10 reflect the annual percentage charge in accordance with the 11 change in the Composite Construction Cost Index of the United 12 States Department of Commerce, occurring in the one-year 13 period ending on December 31 of each year. 14 (2) Any person to sell or offer for sale to any person 15 for use in any public works aluminum or steel products made 16 in a foreign country which has been determined as 17 discriminating by the court. 18 § 3724. Preference for aluminum and steel products made in 19 United States. 20 If all considerations in or affecting a bid or proposal or a 21 bidder or offeror are equal, each government agency shall give 22 preference to aluminum and steel products made in the United 23 States. 24 § 3725. Requirement to list discriminating countries. 25 In all its invitations for bids or requests for proposals, 26 schedules or purchase orders issued for public works exceeding 27 the amount established in section 3723 (relating to unlawful 28 acts), every government agency shall include a listing of the 29 foreign countries which have been found by the court to 30 discriminate. 19970S0005B1478 - 101 -
1 § 3726. Procedure to determine discrimination. 2 (a) Petition.--Any government agency, importer or taxpayer 3 of this Commonwealth may file with the court a petition 4 specifically setting forth alleged discrimination by a foreign 5 country and praying for a determination. A copy of the petition 6 to the court and notice of the time of hearing set by the court 7 shall be served by registered mail on the consular officer, if 8 any, of the country having an office in this Commonwealth and 9 upon a person in charge of the embassy of the foreign country in 10 Washington, D.C. 11 (b) Hearing.--Upon presentation of a petition filed pursuant 12 to subsection (a), the court shall make an order fixing a time 13 for a hearing. The hearing shall be fixed on a day not later 14 than 45 days after the filing of the petition. The 15 representative of the foreign country and any other interested 16 person may appear and present testimony at the hearing. At the 17 hearing, the court shall consider the statutes, regulations, 18 policies, procedures and practices of the foreign country 19 specified in the petition. 20 § 3727. Foreign registry docket. 21 (a) Entering name in docket.--If, after a hearing, the court 22 determines that the foreign country discriminates, it shall 23 direct the prothonotary of the court to enter the name of the 24 foreign country in a foreign registry docket maintained in the 25 office of the prothonotary. 26 (b) Striking name from docket.--Any foreign country 27 determined to be practicing discrimination may petition the 28 court to have its name stricken from the foreign registry 29 docket. The court shall grant the prayer of the petition if, 30 after hearing, it determines that the foreign country has 19970S0005B1478 - 102 -
1 discontinued and not engaged in discrimination for a period of 2 at least one year prior to the filing of the petition. Notice of 3 the filing of the petition shall be served upon the original 4 petitioner and all other parties to the original petition. 5 § 3728. Aluminum or steel products from a country listed on 6 foreign registry docket. 7 (a) General rule.--It is unlawful for any person in the 8 performance of a public works contract, subcontract or purchase 9 order to furnish aluminum or steel products made in a foreign 10 country that is listed on a foreign registry docket if the 11 amount exceeds the amount established in section 3723 (relating 12 to unlawful acts). The person or any organization, corporation, 13 partnership, business unit, association or joint venture in 14 which the person has a substantial interest shall not be 15 eligible to bid or submit an offer on or be awarded any contract 16 or subcontract or be issued a purchase order for public works 17 for a period of three years. 18 (b) Persons deemed not in violation.--Notwithstanding 19 subsection (a), a person shall not be held to have violated this 20 subchapter if he has not received notification of the listing as 21 provided in section 3725 (relating to requirement to list 22 discriminating countries) or solely because his subcontractor or 23 supplier of materials violates this subchapter if the person had 24 no knowledge of the violation. 25 SUBCHAPTER D 26 MOTOR VEHICLES 27 Sec. 28 3731. Short title of subchapter and general provisions. 29 3732. Definitions. 30 3733. Police power. 19970S0005B1478 - 103 -
1 3734. Contract provisions. 2 3735. Payment under contract and action to recover 3 unauthorized payments. 4 3736. Penalty. 5 § 3731. Short title of subchapter and general provisions. 6 (a) Short title.--This subchapter shall be known and may be 7 cited as the Motor Vehicle Procurement Act. 8 (b) Legislative findings.--It is hereby determined by the 9 General Assembly to reaffirm the legislative findings contained 10 in the act of April 4, 1984 (P.L.193, No.40), known as the Motor 11 Vehicle Procurement Act, and codified in this chapter: 12 (1) The production of motor vehicles and component parts 13 constitutes a major industry of this Commonwealth. It 14 provides employment for and incomes of hundreds of thousands 15 of the people of this Commonwealth and, in turn, millions of 16 persons in the United States. 17 (2) The taxes paid to the Commonwealth and its political 18 subdivisions by employers and employees engaged in the 19 production and sale of motor vehicles is one of the largest 20 single sources of public revenues in this Commonwealth. 21 (3) It has for many years been the policy of this 22 Commonwealth to aid and support the development and expansion 23 of industry here to foster the economic well-being of this 24 Commonwealth and its people. 25 (4) The economy and general welfare of this Commonwealth 26 and its citizens, as well as the economy, general welfare and 27 national security of the United States, are inseparably 28 related in the preservation and development of the motor 29 vehicle industry in this Commonwealth and in other states of 30 the United States. 19970S0005B1478 - 104 -
1 (5) The production of motor vehicles and motor vehicle 2 components in Canada involves the use of a substantial amount 3 of resources from the United States, including labor and 4 materials. The General Assembly declares it to be the policy 5 of the Commonwealth of Pennsylvania that public officers and 6 agencies should aid and promote the development of the motor 7 vehicle industry of North America to stimulate and improve 8 the economic well-being of this Commonwealth and its 9 citizens. 10 (c) Purpose of subchapter.--This subchapter is intended as 11 remedial legislation designed to promote the general welfare and 12 stimulate the economy of this Commonwealth and its people. Each 13 provision shall receive a liberal construction to effectuate 14 that intention. None of the provisions of this subchapter shall 15 receive a strict or limited construction. 16 § 3732. Definitions. 17 The following words and phrases when used in this subchapter 18 shall have the meanings given to them in this section unless the 19 context clearly indicates otherwise: 20 "Motor vehicle." A vehicle which is self-propelled except 21 one which is propelled solely by human or animal power. The term 22 includes those vehicles designed primarily for use in 23 construction or agriculture or road maintenance such as tractors 24 and earth-moving equipment. 25 "North America." The United States and Canada. The United 26 States includes all territory, continental or insular, subject 27 to the jurisdiction of the United States. 28 "Procure." To acquire by purchase, lease or rent. The term 29 does not include any rentals or leases where the term thereof is 30 less than one month. 19970S0005B1478 - 105 -
1 § 3733. Police power. 2 This subchapter shall be deemed to be an exercise of the 3 police power of this Commonwealth for the protection of the 4 health, safety and general welfare of its citizens. 5 § 3734. Contract provisions. 6 (a) Motor vehicles to be manufactured in North America.--All 7 government agencies shall procure only motor vehicles which are 8 manufactured in North America. A motor vehicle is manufactured 9 in North America if a substantial majority of the principal 10 components are assembled into the final product in an assembly 11 plant in North America. Contract documents for the procurement 12 of motor vehicles shall contain a provision that the vehicles 13 procured by the government agency shall be manufactured in North 14 America. 15 (b) Exception.--This section shall not apply where the head 16 of the government agency states in writing that it is 17 inconsistent with the public interest or that the cost is 18 unreasonable. 19 § 3735. Payment under contract and action to recover 20 unauthorized payments. 21 A government agency shall not authorize, provide for or make 22 a payment to a person under a contract containing the provision 23 required by section 3734 (relating to contract provisions) 24 unless the government agency is satisfied that the person has 25 complied with the provision. The payment made to a person by a 26 government agency which should not have been made shall be 27 recoverable directly from the supplier of the motor vehicle who 28 did not comply with section 3734 by the government agency or the 29 Attorney General by appropriate legal action. Nothing in this 30 section shall authorize any government agency to initiate a 19970S0005B1478 - 106 -
1 legal action independently of the Attorney General unless 2 otherwise authorized under the act of October 15, 1980 (P.L.950, 3 No.164), known as the Commonwealth Attorneys Act. 4 § 3736. Penalty. 5 In addition to the withholding of payments, any person who 6 willfully violates any of the provisions of this subchapter may 7 be prohibited by any government agency from participation in 8 contracts awarded by the government agency for a period of five 9 years from the date of the determination that a violation has 10 occurred. 11 SUBCHAPTER E 12 USED OIL PRODUCTS 13 Sec. 14 3741. Preference. 15 § 3741. Preference. 16 As provided for in the act of April 9, 1982 (P.L.314, No.89), 17 known as the Pennsylvania Used Oil Recycling Act, government 18 agencies and persons holding contracts with government agencies 19 shall encourage and, to the extent possible, require the 20 procurement and purchase of recycled oil products as 21 substantially equivalent to products made from new oil. 22 SUBCHAPTER F 23 GUARANTEED ENERGY SAVINGS CONTRACTS 24 Sec. 25 3751. Definitions. 26 3752. Selection process. 27 3753. Award of single contract. 28 § 3751. Definitions. 29 The following words and phrases when used in this subchapter 30 shall have the meanings given to them in this section unless the 19970S0005B1478 - 107 -
1 context clearly indicates otherwise: 2 "Energy conservation measure." A training program or 3 facility alteration designed to reduce energy consumption or 4 operating costs. The term shall include, without limitation: 5 (1) Insulation of the building structure or systems 6 within the building. 7 (2) Storm windows or doors, caulking or weather 8 stripping, multiglazed windows or doors, heat-absorbing or 9 heat-reflective glazed and coated window or door systems, 10 additional glazing, reductions in glass area or other window 11 and door system modifications that reduce energy consumption. 12 (3) Automated or computerized energy control systems. 13 (4) Heating, ventilating or air-conditioning system 14 modifications or replacements. 15 (5) Replacement or modification of lighting fixtures to 16 increase the energy efficiency of the lighting system without 17 increasing the overall illumination of a facility unless an 18 increase in illumination is necessary to conform to 19 applicable State or local building codes for the lighting 20 system after the proposed modifications are made. 21 (6) Energy recovery systems. 22 (7) Systems that produce steam or forms of energy such 23 as heat, as well as electricity, for use within a building or 24 complex of buildings. 25 (8) Energy conservation measures that provide operating 26 cost reductions based on life-cycle cost analysis. 27 "Guaranteed energy savings contract." A contract for the 28 evaluation and recommendation of energy conservation measures 29 and for implementation of one or more such measures. 30 § 3752. Selection process. 19970S0005B1478 - 108 -
1 In connection with the letting of any guaranteed energy 2 savings contract, Commonwealth agencies shall have the power to 3 waive the process for the selection of design professionals 4 prescribed under section 905 (relating to procurement of design 5 professionals). 6 § 3753. Award of single contract. 7 Notwithstanding section 905 (relating to procurement of 8 design professionals), the Commonwealth agencies may enter into 9 a single guaranteed energy savings contract for the design and 10 complete implementation of the energy conservation measures 11 involved in a project. 12 CHAPTER 39 13 CONSTRUCTION CONTRACTS OVER $50,000 14 Subchapter 15 A. Preliminary Provisions 16 B. General Provisions 17 C. Retainage 18 D. Prompt Payment Schedules 19 E. Substantial/final Payment 20 SUBCHAPTER A 21 PRELIMINARY PROVISIONS 22 Sec. 23 3901. Application and purpose of chapter. 24 3902. Definitions. 25 § 3901. Application and purpose of chapter. 26 (a) Application.--Except as otherwise specifically provided 27 in this chapter, this chapter applies to contracts entered into 28 by a government agency through competitive sealed bidding or 29 competitive sealed proposals. 30 (b) Purpose of chapter.--The purpose of this chapter is to 19970S0005B1478 - 109 -
1 establish a uniform and mandatory system governing public 2 contracts to the extent of the requirements set forth in this 3 chapter and shall be construed to effectuate such purpose. The 4 provisions of this chapter shall in no way affect the provisions 5 of the act of August 15, 1961 (P.L.987, No.442), known as the 6 Pennsylvania Prevailing Wage Act, nor the regulations 7 promulgated under that act, nor shall any requirements of this 8 chapter affect any provisions of a contract to be awarded 9 pursuant to any Federal law or regulations containing specific 10 provisions which are different from the public contract 11 requirements of this chapter. 12 § 3902. Definitions. 13 The following words and phrases when used in this chapter 14 shall have the meanings given to them in this section unless the 15 context clearly indicates otherwise: 16 "Contract." A contract exceeding $50,000 for construction as 17 defined in section 103 (relating to definitions), including 18 heating or plumbing contracts but excluding Department of 19 Transportation contracts for highway and airport, vertical <-- 20 construction. UNDER SECTION 301(C)(1) (RELATING TO PROCUREMENT <-- 21 RESPONSIBILITY). 22 "Contractor." A person who enters into a contract with a 23 government agency. 24 "Deficiency item." Work performed but which the design 25 professional, the contractor or the inspector will not certify 26 as being completed according to the contract. 27 "Design professional services." Those professional services <-- 28 within the scope of the practice of architecture, geology 29 engineering, landscape architecture or land surveying, including 30 studies, investigations, surveying, mapping, tests, evaluations, 19970S0005B1478 - 110 -
1 consultations, comprehensive planning, program management, 2 conceptual design, plans and specifications, value engineering, 3 maintenance manuals and other related services associated with 4 research, planning, development, design, construction, 5 alteration or repair of real property. 6 "DESIGN PROFESSIONAL." PERSONS PERFORMING PROFESSIONAL <-- 7 SERVICES AS DEFINED IN SECTION 901 (RELATING TO DEFINITIONS). 8 "Government agency." Includes any State-aided institutions. 9 "Inspector." The person authorized or engaged by the 10 government agency to inspect the work performed and materials 11 furnished pursuant to a contract to determine whether the work 12 completed is in compliance with the contract. 13 "Local government unit." Any county, city, borough, 14 incorporated town, township, school district, vocational school 15 district, county institution, local authority or any joint or 16 cooperative body of local government units or any 17 instrumentality, authority or corporation thereof which has 18 authority to enter into a contract. 19 "State-aided institution." Any institution which receives 20 State funds directly or indirectly for construction. <-- 21 "Subcontractor." A person who has contracted to furnish 22 labor or materials to or has performed labor for a contractor or 23 another subcontractor in connection with a contract. 24 "Substantial completion." Construction that is sufficiently 25 completed in accordance with the contract and certified by the 26 architect or engineer of the government agency, as modified by 27 change orders agreed to by the parties, so that the project can 28 be used, occupied or operated for its intended use. In no event 29 shall a project be certified as substantially complete until at 30 least 90% of the work on the project is completed. 19970S0005B1478 - 111 -
1 SUBCHAPTER B 2 GENERAL PROVISIONS 3 Sec. 4 3911. Time for awarding contract. 5 3912. Time for executing contract. 6 3913. Release of successful bidder. 7 § 3911. Time for awarding contract. 8 (a) General rule.--In the case of a contract to be entered 9 into by a government agency through competitive sealed bidding, 10 the contract shall be awarded to the lowest responsible and 11 responsive bidder within 60 days of the bid opening, or all bids 12 shall be rejected except as otherwise provided in this section. 13 (b) Delay.--If the award is delayed by the required approval 14 of another government agency, the sale of bonds or the award of 15 a grant, the contract shall be awarded to the lowest responsible 16 and responsive bidder within 120 days of the bid opening, or all 17 bids shall be rejected. 18 (c) Extensions.--Extensions of the date for the award may be 19 made by the mutual written consent of the government agency and 20 the lowest responsible and responsive bidder. 21 (d) List of bidders.--All government agencies shall be 22 required to provide a list of the bidders and their bid amount 23 on each contract within ten working days of the bid opening to 24 interested parties for a fee to be determined by the government 25 agency to cover the cost of developing such list. This 26 requirement shall not apply to the contracting bodies of any 27 political subdivision or local authority which has the authority 28 to enter into a contract. 29 § 3912. Time for executing contract. 30 In the case of a contract entered into by a government agency 19970S0005B1478 - 112 -
1 through competitive sealed bidding, the contract shall be 2 executed by the government agency within 60 days of the date 3 that the contract is awarded. 4 § 3913. Release of successful bidder. 5 Failure of the government agency to comply with the 6 requirements of sections 3911 (relating to time for awarding 7 contract) and 3912 (relating to time for executing contract) 8 shall, unless the successful bidder waives the noncompliance by 9 written notice to the government agency, release the successful 10 bidder from any liability in respect to its bid or contract and 11 entitle all bidders to the immediate return of any bonds or 12 security deposits posted in connection with the bid or contract. 13 SUBCHAPTER C 14 RETAINAGE 15 Sec. 16 3921. Retainage. 17 3922. Payment of retainage to subcontractors. 18 § 3921. Retainage. 19 (a) Contract provision.--A contract may include a provision 20 for the retainage of a portion of the amount due the contractor 21 to insure the proper performance of the contract except that the 22 sum withheld by the government agency from the contractor shall 23 not exceed 10% of the amount due the contractor until 50% of the 24 contract is completed. When the contract is 50% completed, one- 25 half of the amount retained by the government agency shall be 26 returned to the contractor. However, the architect or engineer 27 must approve the application for payment. The contractor must be 28 making satisfactory progress, and there must be no specific 29 cause for greater withholding. The sum withheld by the 30 government agency from the contractor after the contract is 50% 19970S0005B1478 - 113 -
1 completed shall not exceed 5% of the value of completed work
2 based on monthly progress payment requests. In the event a
3 dispute arises between the government agency and any prime
4 contractor, which dispute is based upon increased costs claimed
5 by one prime contractor occasioned by delays or other actions of
6 another prime contractor, additional retainage in the sum of one
7 and one-half times the amount of any possible liability may be
8 withheld until a SUCH time as a final resolution is agreed to by <--
9 all parties directly or indirectly involved unless the
10 contractor causing the additional claim furnishes a bond
11 satisfactory to the government agency to indemnify the agency
12 against the claim. All money retained by the government agency
13 may be withheld from the contractor until substantial completion
14 of the contract.
15 (b) Department of General Services.--Notwithstanding
16 subsection (a), when the Department of General Services is the
17 government agency, the contract may include a provision for the
18 retainage of a portion of the amount due the contractor to
19 insure the proper performance of the contract except that the
20 sum withheld by the department for the contractor shall not
21 exceed 6% of the then total estimates until 50% of the contract
22 is satisfactorily completed. The sum withheld by the department
23 from the contractor after the contract is 50% satisfactorily
24 completed shall not exceed 3% of the original contract amount.
25 § 3922. Payment of retainage to subcontractors.
26 In the absence of sufficient reason, within 20 days of the
27 receipt of payment by the contractor, the contractor shall pay
28 all subcontractors with which it has contracted their earned
29 share of the payment the contractor received.
30 SUBCHAPTER D
19970S0005B1478 - 114 -
1 PROMPT PAYMENT SCHEDULES 2 Sec. 3 3931. Performance by contractor or subcontractor. 4 3932. Government agency's progress payment obligations. 5 3933. Contractors' and subcontractors' payment obligations. 6 3934. Withholding of payment for good faith claims. 7 3935. Penalty and attorney fees. 8 3936. Contracts involving Federal aid. 9 3937. Certain provisions unenforceable. 10 3938. Applicability. 11 3939. Claims by innocent parties. 12 § 3931. Performance by contractor or subcontractor. 13 (a) Entitlement of contractor to payment.--Performance by a 14 contractor in accordance with the provisions of a contract shall 15 entitle the contractor to payment by the government agency. 16 (b) Entitlement of subcontractor to payment.--Performance by 17 a subcontractor in accordance with the provisions of a contract 18 shall entitle the subcontractor to payment from the contractor 19 with whom the subcontractor has contracted. 20 § 3932. Government agency's progress payment obligations. 21 (a) Payments in accordance with contract.--The government 22 agency shall pay the contractor or design professional strictly 23 in accordance with the contract. 24 (b) Application for progress payments.--If the contract does 25 not contain a term governing the time for payment, the 26 contractor or design professional shall be entitled to make 27 application for payment from the government agency for progress 28 payments, and the government agency shall make payment less the 29 applicable retainage amount as authorized in section 3921 30 (relating to retainage) to the contractor or design professional 19970S0005B1478 - 115 -
1 within 45 calendar days of the date the application for payment 2 is received. 3 (c) Interest on progress payments not timely made.--Except 4 as otherwise agreed by the parties, if any progress payment less 5 the applicable retainage amount as authorized in section 3921 is 6 not made to a contractor or design professional by the due date 7 established in the contract or in subsection (b), the government 8 agency shall pay to the contractor or design professional, in 9 addition to the amount due, interest on the amount due, and the 10 interest shall be computed at the rate determined by the 11 Secretary of Revenue for interest payments on overdue taxes or 12 the refund of taxes as provided in sections 806 and 806.1 of the 13 act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 14 Code. 15 (d) When interest payment not required.--In the event that 16 the contract does not contain a grace period and if a contractor 17 or design professional is not paid by the payment date required 18 by subsection (b), no interest penalty payment required under 19 this section shall be paid if payment is made on or before the 20 15th calendar day after the payment date required under this 21 subchapter. 22 § 3933. Contractors' and subcontractors' payment obligations. 23 (a) Performance by subcontractor entitles subcontractor to 24 payment.--Performance by a subcontractor in accordance with the 25 provisions of the contract shall entitle the subcontractor to 26 payment from the party with whom the subcontractor has 27 contracted. For purposes of this section, the contract between 28 the contractor and subcontractor is presumed to incorporate the 29 terms of the contract between the contractor and the government 30 agency. 19970S0005B1478 - 116 -
1 (b) Disclosure of progress payment due dates.--A contractor 2 or subcontractor shall disclose to a subcontractor, before a 3 subcontract is executed, the due date for receipt of progress 4 payments from the government agency. Notwithstanding any other 5 provisions of this subchapter, if a contractor or a 6 subcontractor fails to accurately disclose the due date to a 7 subcontractor, the contractor or subcontractor shall be 8 obligated to pay the subcontractor as though the due dates 9 established in subsection (c) were met by the government agency. 10 This subsection shall not apply to a change in due dates because 11 of conditions outside of the contractor's control, including, 12 but not limited to, design changes, change orders or delays in 13 construction due to weather conditions. 14 (c) Payment.--When a subcontractor has performed in 15 accordance with the provisions of the contract, a contractor 16 shall pay to the subcontractor, and each subcontractor shall in 17 turn pay to its subcontractors, the full or proportional amount 18 received for each such subcontractor's work and material, based 19 on work completed or services provided under the subcontract, 14 20 days after receipt of a progress payment. Payment shall be made 21 under this section unless it is being withheld under section 22 3934 (relating to withholding of payment for good faith claims). 23 (d) Interest due when progress payment not timely.--If any 24 progress payment is not made to a subcontractor by the due date 25 established in the contract or in subsection (c), the contractor 26 shall pay to the subcontractor, in addition to the amount due, 27 interest as computed in section 3932(c) (relating to government 28 agency's progress payment obligations). 29 (e) When interest payment not required.--In the event that 30 the contract does not contain a grace period and if a 19970S0005B1478 - 117 -
1 subcontractor is not paid by the payment date required by
2 subsection (c), no interest penalty payment required under this
3 section shall be paid if payment is made on or before the 15th
4 calendar day after the payment date required under this
5 subchapter.
6 § 3934. Withholding of payment for good faith claims.
7 (a) When government agency may withhold payment.--The
8 government agency may withhold payment for deficiency items
9 according to terms of the contract. The government agency shall
10 pay the contractor according to the provisions of this
11 subchapter for all other items which appear on the application
12 for payment and have been satisfactorily completed. The
13 contractor may withhold payment from any subcontractor
14 responsible for a deficiency item. The contractor shall pay any
15 subcontractor according to the provisions of this subchapter for
16 any item which appears on the application for payment and has
17 been satisfactorily completed.
18 (b) Notification when payment withheld for deficiency
19 item.--If a government agency withholds payment from a
20 contractor for a deficiency item, it shall notify the contractor
21 of the deficiency item within the time period specified in the
22 contract or 15 calendar days of the date that the application
23 for payment is received. If a contractor withholds payment from
24 a subcontractor for a deficiency item, it must notify the
25 subcontractor or supplier and the government agency of the
26 reason within 15 calendar days of the date after receipt of the
27 notice of the deficiency item from the owner GOVERNMENT AGENCY. <--
28 § 3935. Penalty and attorney fees.
29 (a) Penalty.--If arbitration or a claim with the Board of
30 Claims or a court of competent jurisdiction is commenced to
19970S0005B1478 - 118 -
1 recover payment due under this subchapter and it is determined 2 that the government agency, contractor or subcontractor has 3 failed to comply with the payment terms of this subchapter, the 4 arbitrator, the Board of Claims or the court may award, in 5 addition to all other damages due, a penalty equal to 1% per 6 month of the amount that was withheld in bad faith. An amount 7 shall be deemed to have been withheld in bad faith to the extent 8 that the withholding was arbitrary or vexatious. An amount shall 9 not be deemed to have been withheld in bad faith to the extent 10 it was withheld pursuant to section 3934 (relating to 11 withholding of payment for good faith claims). 12 (b) Attorney fees.--Notwithstanding any agreement to the 13 contrary, the prevailing party in any proceeding to recover any 14 payment under this subchapter may be awarded a reasonable 15 attorney fee in an amount to be determined by the Board of 16 Claims, court or arbitrator, together with expenses, if it is 17 determined that the government agency, contractor or 18 subcontractor acted in bad faith. An amount shall be deemed to 19 have been withheld in bad faith to the extent that the 20 withholding was arbitrary or vexatious. 21 § 3936. Contracts involving Federal aid. 22 If any provision of this subchapter CHAPTER conflicts with a <-- 23 Federal statute or regulation or with conditions attached to the 24 receipt of Federal aid, this subchapter CHAPTER shall not <-- 25 operate to prevent receipt of the Federal aid in accordance with 26 any Federal statute or regulation. 27 § 3937. Certain provisions unenforceable. 28 A provision in the contract making it subject to the laws of 29 another state or requiring that any litigation, arbitration or 30 other dispute resolution process on the contract occurs in 19970S0005B1478 - 119 -
1 another state shall be unenforceable. 2 § 3938. Applicability. 3 (a) Not applicable in certain situations.--This subchapter 4 shall not apply in the following situations: 5 (1) Section 3932 (relating to government agency's 6 progress payment obligations) shall not apply when the State <-- 7 government unit's COMMONWEALTH AGENCY'S nonpayment on a <-- 8 particular project is caused by the failure of the General 9 Assembly to enact a budget for the fiscal year of payment. 10 (2) Section 3932 shall not apply when a local government 11 unit's nonpayment on a particular project is caused by 12 failure of the Federal or State Government to pay funds due 13 and payable to the local government unit. 14 (3) Section 3932 shall not apply when government 15 agency's nonpayment on a particular project is caused by the 16 failure of the General Assembly to enact an operating budget 17 for the fiscal year of payment or a capital budget for the 18 capital project or by failure of the Federal, State or local 19 government to pay funds designated or to be designated for 20 the specific project. 21 (4) Nothing in this subchapter shall be construed to 22 require payment of interest penalties by the Federal or State 23 Government if the municipality LOCAL GOVERNMENT UNIT is <-- 24 liable for such THE interest. <-- 25 (b) Not applicable to following entities.--This act CHAPTER <-- 26 shall not apply to any of the following: 27 (1) A municipality determined to be distressed under the 28 act of July 10, 1987 (P.L.246, No.47), known as the 29 Municipalities Financial Recovery Act. 30 (2) A school district which has been determined to be a 19970S0005B1478 - 120 -
1 distressed school district under section 691 of the act of
2 March 10, 1949 (P.L.30, No.14), known as the Public School
3 Code of 1949.
4 (3) A city of the first class that has entered into an
5 intergovernmental cooperation agreement under the act of June
6 5, 1991 (P.L.9, No.6), known as the Pennsylvania
7 Intergovernmental Cooperation Authority Act for Cities of the
8 First Class, for so long as any deficit-reducing bonds issued
9 by the authority pursuant to section 301(b)(1) of that act
10 are outstanding and payable.
11 (4) Any A corporate entity or school district as defined <--
12 in the Pennsylvania Intergovernmental Cooperation Authority
13 Act for Cities of the First Class.
14 (5) A TRANSPORTATION AUTHORITY ORGANIZED OR OPERATING <--
15 UNDER 74 PA.C.S. CH. 17 (RELATING TO METROPOLITAN
16 TRANSPORTATION AUTHORITIES).
17 § 3939. Claims by innocent parties.
18 (a) No obligation to third parties.--The government agency
19 shall have no obligation to any third parties for any claim.
20 (b) Barred claims.--Once a contractor has made payment to
21 the subcontractor according to the provisions of this
22 subchapter, future claims for payment against the contractor or
23 the contractor's surety by parties owed payment from the
24 subcontractor which has been paid shall be barred.
25 SUBCHAPTER E
26 SUBSTANTIAL/FINAL PAYMENT
27 Sec.
28 3941. Substantial/final payment under contract.
29 3942. Arbitration.
30 § 3941. Substantial/final payment under contract.
19970S0005B1478 - 121 -
1 (a) Contract containing provision for retainage.--A contract
2 containing a provision for retainage as provided in section 3921
3 (relating to retainage) shall contain a provision requiring the
4 architect or engineer to make final inspection within 30 days of
5 receipt of the request of the contractor for final inspection
6 and application for final payment. If the work is substantially
7 completed, the architect or engineer shall issue a certificate
8 of completion and a final certificate for payment, and the
9 government agency shall make payment in full within 45 days
10 except as provided in section 3921, less only one and one-half
11 times the amount as is required to complete any then-remaining <--
12 uncompleted minor items, which amount shall be certified by the
13 architect or engineer and, upon receipt by the government agency
14 of any guarantee bonds which may be required, in accordance with
15 the contract, to insure proper workmanship for a designated
16 period of time. The certificate given by the architect or
17 engineer shall list in detail each uncompleted item and a
18 reasonable cost of completion. Final payment of any amount
19 withheld for the completion of the minor items shall be paid
20 upon completion of the items in the certificate of the engineer
21 or architect.
22 (b) Interest.--The final payment due the contractor from the
23 government agency after substantial completion of the contract
24 shall bear interest at a rate of 6% PER ANNUM for all contracts <--
25 without provisions for retainage and at a rate of 10% PER ANNUM <--
26 for all contracts with provisions for retainage, the interest to
27 begin after the date that such payment becomes due and payable
28 to the contractor. However, where the government agency has
29 issued bonds to finance the project, interest shall be payable
30 to the contractor at the rate of interest of the bond issue or
19970S0005B1478 - 122 -
1 at the rate of 10% PER ANNUM, whichever is less, but in no event <-- 2 shall the interest payable to the contractor be at a rate of 3 interest less than the legal rate of interest. 4 § 3942. Arbitration. 5 If a dispute should arise between the contractor and the 6 government agency over the payment of retainages and final 7 payment, then the dispute shall be arbitrated under the 8 applicable terms of the contract. If the contract contains no 9 provision for arbitration, then both parties may mutually agree 10 to arbitrate the dispute under the rules of the American 11 Arbitration Association or in accordance with 42 Pa.C.S. Ch. 73 12 (relating to arbitration). In any event, either party shall have 13 the right of appeal from any decision and award as provided by 14 law. 15 CHAPTER 41 16 PURCHASE OF SURPLUS FEDERAL PROPERTY 17 Sec. 18 4101. Contracts with United States. 19 4102. Bids and down payments. 20 § 4101. Contracts with United States. 21 Any government agency may enter into a contract with the 22 Federal Government for the purchase, lease or other acquisition, 23 including the warehousing and distribution, of any surplus real 24 or personal Federal property without complying with any 25 requirement of law as to specifications, advertising, award of 26 contract or approval by another government agency. However, any <-- 27 Commonwealth AN EXECUTIVE OR INDEPENDENT agency may only enter <-- 28 into a contract authorized by this section through the 29 Department of General Services. 30 § 4102. Bids and down payments. 19970S0005B1478 - 123 -
1 Any government agency authorized to enter into a contract 2 under section 4101 (relating to contracts with United States) 3 may designate by appropriate order an officeholder or employee 4 of its own to enter a bid in its behalf at any sale of any 5 surplus real or personal Federal property and may authorize the 6 designee to make any down payment or payment in full required in 7 connection with the bidding. 8 CHAPTER 43 9 PUBLIC FACILITIES CONCESSIONS 10 Sec. 11 4301. Short title of chapter and general provisions. 12 4302. Definitions. 13 4303. Terms of contracts. 14 § 4301. Short title of chapter and general provisions. 15 (a) Short title.--This chapter shall be known and may be 16 cited as the Public Facilities Concession Regulation Act. 17 (b) Legislative findings.--It is hereby determined by the 18 General Assembly to reaffirm the legislative findings contained 19 in the act of November 26, 1978 (P.L.1303, No.315), known as the 20 Public Facilities Concession Regulation Act, and codified in 21 this chapter: 22 (1) It is and has been the policy of this Commonwealth 23 to require and encourage public agencies to own and operate a 24 variety of public facilities for the conduct of public 25 business and for the health, education, protection, 26 transportation, recreation, entertainment and cultural 27 advancement of the people of this Commonwealth. 28 (2) It is and has been the policy of this Commonwealth 29 to promote the public welfare by permitting the operation, 30 within these public facilities, of various concessions to 19970S0005B1478 - 124 -
1 provide goods and services to the public. 2 (3) Due to the nature, configuration and location of 3 many public facilities, members of the public utilizing the 4 facilities must either patronize the concessionaires 5 operating therein or undergo great expense, inconvenience and 6 hardship. 7 (4) The general welfare of the people of this 8 Commonwealth requires that concessionaires operating in 9 public facilities offer to the public goods and services of 10 good quality at reasonable prices. The General Assembly 11 therefore declares it to be the policy of this Commonwealth 12 that all public officers and agencies should, at all times, 13 make efforts to see that concessionaires in public facilities 14 provide goods and services of high quality, at reasonable 15 prices, in order to protect the public and encourage use of 16 public facilities. 17 (c) Police power.--This chapter shall be deemed to be an 18 exercise of the police powers of this Commonwealth for the 19 protection of the health, safety and general welfare of the 20 people of this Commonwealth. 21 (d) Purpose of chapter.--This chapter is intended as 22 remedial legislation designed to promote the general welfare, 23 protect the public and encourage full and proper use of public 24 facilities. Each provision of this chapter is intended to 25 receive a liberal construction as will best effectuate those 26 purposes, and no provision is intended to receive a strict or 27 limited construction. 28 (e) Certain rights preserved.--This chapter is not intended 29 to limit or deny any other rights previously enjoyed by any 30 government agency. 19970S0005B1478 - 125 -
1 § 4302. Definitions. 2 The following words and phrases when used in this chapter 3 shall have the meanings given to them in this section unless the 4 context clearly indicates otherwise: 5 "Public facility." Any building, airport, school, park, 6 hospital or other structure, grounds or place owned or operated 7 by a government agency, whether for governmental or proprietary 8 use. 9 § 4303. Terms of contracts. 10 (a) General rule.--Each government agency shall require that 11 every contract granting any concession, license, permit or right 12 to sell, lease, contract for or otherwise make available for 13 consideration goods or services to the public in any public 14 facility contains provisions giving the government agency the 15 right to regulate the kinds, quality and prices of the goods and 16 services, upon terms and conditions as may be appropriate. 17 (b) Exceptions.--This section is not intended to apply in 18 any of the following cases: 19 (1) Where the right to regulate price or quality is 20 vested exclusively in or has been preempted by the United 21 States or any of its agencies or another government agency. 22 (2) Where the head of the government agency determines 23 in writing that the retention of the right to regulate is not 24 necessary to protect the general welfare. 25 CHAPTER 45 26 ANTIBID-RIGGING 27 Sec. 28 4501. Short title of chapter. 29 4502. Definitions. 30 4503. Prohibited activities. 19970S0005B1478 - 126 -
1 4504. Civil action and damages. 2 4505. Suspension or debarment. 3 4506. Liability for increased costs. 4 4507. Noncollusion affidavits. 5 4508. Responsibility for enforcement. 6 4509. Investigation. 7 § 4501. Short title of chapter. 8 This chapter shall be known and may be cited as the Antibid- 9 Rigging Act. 10 § 4502. Definitions. 11 The following words and phrases when used in this chapter 12 shall have the meanings given to them in this section unless the 13 context clearly indicates otherwise: 14 "Bid-rigging." The concerted activity of two or more persons 15 to determine in advance the winning bidder of a contract let or 16 to be let for competitive bidding by a government agency. The 17 term includes, but is not limited to, any one or more of the 18 following: 19 (1) Agreeing to sell items or services at the same 20 price. 21 (2) Agreeing to submit identical bids. 22 (3) Agreeing to rotate bids. 23 (4) Agreeing to share profits with a contractor who does 24 not submit the low bid. 25 (5) Submitting prearranged bids, agreed-upon higher or 26 lower bids or other complementary bids. 27 (6) Agreeing to set up territories to restrict 28 competition. 29 (7) Agreeing not to submit bids. 30 "Government agency." The Commonwealth and any of its 19970S0005B1478 - 127 -
1 departments, boards, agencies, authorities and commissions, any 2 political subdivision, municipal or other local authority or any 3 officer or agency of any political subdivision or local 4 authority. 5 "Person." An individual, corporation or partnership or any 6 other entity capable of submitting a bid to the Commonwealth. 7 § 4503. Prohibited activities. 8 (a) Bid-rigging unlawful.--It is unlawful for any person to 9 conspire, collude or combine with another in order to commit or 10 attempt to commit bid-rigging involving: 11 (1) A contract for the purchase of equipment, goods, 12 services or materials or for construction or repair let or to 13 be let by a government agency. 14 (2) A subcontract for the purchase of equipment, goods, 15 services or materials or for construction or repair with a 16 prime contractor or proposed prime contractor for a 17 government agency. 18 (b) Simultaneous bids.--Notwithstanding other provisions of 19 this chapter, it is not unlawful for the same person to 20 simultaneously submit bids for the same work, or a portion 21 thereof, as a proposed prime contractor and subcontractor. 22 (c) Fines and imprisonment.--Any person who violates this 23 section commits a felony of the third degree and shall, upon 24 conviction, be sentenced to pay a fine of not more than 25 $1,000,000, if an entity other than an individual, or a fine of 26 not more than $50,000, if an individual, or to serve a term of 27 imprisonment for not more than three years, or both. 28 (d) Alternative civil penalty.--In lieu of criminal 29 prosecution for violation of this section, the Attorney General 30 may bring an action for a civil penalty. In this action, a 19970S0005B1478 - 128 -
1 person found by a court to have violated this section shall be 2 liable for a civil penalty of not more than $100,000. 3 (e) Disposition of fines and penalties.--Criminal fines and 4 civil penalties collected under subsections (c) and (d) shall be 5 paid into the State Treasury and deposited in the appropriate 6 fund. 7 (f) Factors to be considered in determining fines, 8 imprisonment or civil penalties.--In determining the appropriate 9 sanctions to be imposed for a violation of this section, the 10 court shall consider at least the following three factors: 11 (1) The prior record and the number of previous 12 violations. 13 (2) The net worth of the person. 14 (3) The size and amount of the contract involved. 15 (g) Civil action not barred.--A conviction or civil penalty 16 imposed under this section shall not bar a government agency 17 from pursuing additional civil action and administrative 18 sanctions. 19 (h) Limitation on prosecution.--No criminal prosecution 20 under this section shall be brought against a person who has 21 been previously charged by information or indictment with a 22 criminal violation of the Federal antitrust laws, based upon the 23 same allegedly unlawful conduct upon which a criminal 24 prosecution under this chapter could be based, where jeopardy 25 has attached under the Federal prosecution. 26 § 4504. Civil action and damages. 27 (a) Government agency to have right of action.--Any 28 government agency entering into a contract which is or has been 29 the subject of activities prohibited by section 4503 (relating 30 to prohibited activities) shall have a right of action against 19970S0005B1478 - 129 -
1 the participants in the prohibited activities to recover 2 damages. 3 (b) Options.--The government agency shall have the option to 4 proceed jointly and severally in a civil action against any one 5 or more of the participants for recovery of the full amount of 6 the damages. There shall be no right to contribution among 7 participants not named defendants by the government agency. 8 (c) Measure of damages.--The measure of damages recoverable 9 under this section shall be the actual damages, which damages 10 shall be trebled plus the cost of suit, including reasonable 11 attorney fees. 12 (d) When cause of action arises.--The cause of action shall 13 arise at the time the government agency which entered into the 14 contract discovered, or should have discovered, the conduct 15 amounting to the unlawful offense. The action shall be brought 16 within four years of the date that the cause of action arose. No 17 civil action shall be maintained after the expiration of ten 18 years from the date the contract was signed by the parties. 19 (e) Conviction to be dispositive of liability.--Any 20 conviction under section 4503 shall be dispositive of the 21 liability of the participants with the only issues for trial 22 being the fact and amount of damages. 23 § 4505. Suspension or debarment. 24 (a) Maximum suspension or debarment.--A government agency 25 proceeding under its rules and regulations to exclude or render 26 ineligible a person from participation in contracts or 27 subcontracts based upon conduct prohibited by section 4503 28 (relating to prohibited activities) shall limit the exclusion or 29 ineligibility to a period not to exceed the following: 30 (1) Three years in the case of a person found for the 19970S0005B1478 - 130 -
1 first time to have engaged in this conduct. 2 (2) Five years in the case of a person found to have 3 engaged in this conduct for a second or subsequent time. 4 (b) Lists of persons excluded.--A government agency that 5 lets a contract by competitive bidding shall maintain a current 6 list of persons excluded or ineligible by reason of suspension 7 or debarment for participation in contracts or subcontracts with 8 that agency and shall furnish a copy of the list upon request to 9 a person considering the submission of a bid as a prime 10 contractor or as a subcontractor. 11 § 4506. Liability for increased costs. 12 A person who enters into a contract with a government agency, 13 either directly as a contractor or indirectly as a 14 subcontractor, during a period of suspension or debarment 15 imposed upon that person by that agency under its rules and 16 regulations shall be liable to the government agency and to an 17 eligible contractor for increased costs incurred as a result of 18 replacing the excluded or ineligible person. 19 § 4507. Noncollusion affidavits. 20 Noncollusion affidavits may be required by rule or regulation 21 of any government agency for all persons. Any requirement for 22 noncollusion affidavits shall be set forth in the invitation to 23 bid. Failure of any person to provide a required affidavit to 24 the government agency may be grounds for disqualification of his 25 bid. Any required noncollusion affidavit shall state whether or 26 not the person has been convicted or found liable for any act 27 prohibited by Federal or State law in any jurisdiction involving 28 conspiracy or collusion with respect to bidding on any public 29 contract within the last three years. The form for any required 30 noncollusion affidavit shall provide that the person's statement 19970S0005B1478 - 131 -
1 on the affidavit that he has been convicted or found liable for 2 any act prohibited by Federal or State law in any jurisdiction 3 involving conspiracy or collusion with respect to bidding on any 4 public contract within the last three years does not prohibit a 5 government agency from accepting a bid from or awarding a 6 contract to that person, but it may be grounds for 7 administrative suspension or debarment in the discretion of the 8 government agency under the rules and regulations of that agency 9 or, in the case of a government agency with no administrative 10 suspension or debarment regulations or procedures, may be 11 grounds for consideration on the question of whether the agency 12 should decline to award a contract to that person on the basis 13 of lack of responsibility. The provisions of this section are in 14 addition to and not in derogation of any other powers and 15 authority of any government agency. 16 § 4508. Responsibility for enforcement. 17 (a) Criminal prosecution.--The Office of Attorney General 18 and the district attorneys of the several counties shall have 19 concurrent jurisdiction for the investigation and prosecution of 20 violations of section 4503 (relating to prohibited activities). 21 (b) Civil action.--The Office of Attorney General shall have 22 the authority to bring civil action under section 4504 (relating 23 to civil action and damages) on behalf of the Commonwealth and 24 any of its departments, boards, agencies, authorities and 25 commissions. Political subdivisions or municipal or other local 26 authorities or any officer or agency of any such political 27 subdivision or local authority shall have the right to bring a 28 civil action under section 4504. Upon the filing of a complaint, 29 a copy shall be served on the Attorney General. The plaintiff, 30 at any time, may request the Attorney General to act on its 19970S0005B1478 - 132 -
1 behalf. The Attorney General, upon determining that it is in the 2 best interest of the Commonwealth, shall have the authority to 3 intervene on behalf of the Commonwealth in these actions. 4 § 4509. Investigation. 5 (a) Required attendance.--Whenever the Office of Attorney 6 General believes that a person may be in possession, custody or 7 control of documentary material or may have information relevant 8 to the subject matter of a civil investigation for the purpose 9 of ascertaining whether a person is or has been engaged in a 10 violation of this chapter, the Attorney General may require the 11 attendance and testimony of witnesses and the production of 12 books, accounts, papers, records, documents and files relating 13 to the civil investigation. For this purpose, the Attorney 14 General or his representatives may sign subpoenas, administer 15 oaths or affirmations, examine witnesses and receive evidence 16 during the investigation. A request for information shall state 17 the subject matter of the investigation, the conduct 18 constituting the alleged violation which is under investigation 19 and the provisions of this chapter applicable to the alleged 20 violation. A request for documentary material shall describe the 21 material to be produced with reasonable particularity so as to 22 fairly identify the documents demanded, provide a return date 23 within which the material is to be produced and identify the 24 member of the Attorney General's staff to whom the material 25 shall be given. In case of disobedience of a subpoena or the 26 contumacy of a witness appearing before the Attorney General or 27 his representative, the Attorney General or his representative 28 may invoke the aid of a court of record of this Commonwealth, 29 and the court may issue an order requiring the person subpoenaed 30 to obey the subpoena or to give evidence or to produce books, 19970S0005B1478 - 133 -
1 accounts, papers, records, documents and files relative to the 2 matter in question. Failure to obey an order of the court may be 3 punished by the court as a contempt. 4 (b) Confidentiality.--No information or documentary material 5 produced under a demand under this section shall, unless 6 otherwise ordered by a court for good cause shown, be produced 7 for inspection or copying by, nor shall the contents be 8 disclosed to, a person other than the Attorney General or his 9 representative without the consent of the person who produced 10 the information or material. However, the Attorney General or 11 his representative shall disclose information or documentary 12 material produced under this section or information derived 13 therefrom to officials of a government agency affected by the 14 alleged violation, for use by that agency in connection with an 15 investigation or proceeding within its jurisdiction and 16 authority, upon the prior certification of an appropriate 17 official of the agency that the information shall be maintained 18 in confidence other than use for official purposes. Under 19 reasonable terms and conditions as the Attorney General or his 20 representative shall prescribe, the documentary material shall 21 be available for inspection and copying by the person who 22 produced the material or a duly authorized representative of 23 that person. The Attorney General or his representative may use 24 the documentary material or information or copies as he 25 determines necessary in the civil enforcement of this chapter, 26 including presentation before any court. Material which contains 27 trade secrets or other highly confidential matter shall not be 28 presented except with the approval of the court in which a 29 proceeding is pending after adequate notice to the person 30 furnishing the material. 19970S0005B1478 - 134 -
1 (c) Limitation on use.--No criminal prosecution under 2 section 4503 (relating to prohibited activities) may be brought 3 by either the Attorney General or a district attorney based 4 solely upon information or documents obtained in a civil 5 investigation under this section. 6 Section 2. Section 2310 of Title 1 is amended to read: 7 § 2310. Sovereign immunity reaffirmed; specific waiver. 8 Pursuant to section 11 of Article 1 of the Constitution of 9 Pennsylvania, it is hereby declared to be the intent of the 10 General Assembly that the Commonwealth, and its officials and 11 employees acting within the scope of their duties, shall 12 continue to enjoy sovereign immunity and official immunity and 13 remain immune from suit except as the General Assembly shall 14 specifically waive the immunity. When the General Assembly 15 specifically waives sovereign immunity, a claim against the 16 Commonwealth and its officials and employees shall be brought 17 only in such manner and in such courts and in such cases as 18 directed by the provisions of Title 42 (relating to judiciary 19 and judicial procedure) or 62 (relating to procurement), unless 20 otherwise specifically authorized by statute. 21 Section 3. Section 763(a) of Title 42 is amended to read: 22 § 763. Direct appeals from government agencies. 23 (a) General rule.--Except as provided in subsection (c), the 24 Commonwealth Court shall have exclusive jurisdiction of appeals 25 from final orders of government agencies in the following cases: 26 (1) All appeals from Commonwealth agencies under 27 Subchapter A of Chapter 7 of Title 2 (relating to judicial 28 review of Commonwealth agency action) or otherwise and 29 including appeals from the Board of Claims, the Environmental 30 Hearing Board, the Pennsylvania Public Utility Commission, 19970S0005B1478 - 135 -
1 the Unemployment Compensation Board of Review and from any 2 other Commonwealth agency having Statewide jurisdiction. 3 (2) All appeals jurisdiction of which is vested in the 4 Commonwealth Court by any statute hereafter enacted. 5 * * * 6 Section 4. Except as otherwise provided, this act is 7 intended to provide a complete and exclusive procedure to govern 8 the procurement by Commonwealth agencies of supplies, services 9 and construction, including the disposal of surplus supplies. 10 Section 5. The terms of office of the present members of the 11 selection committee appointed pursuant to section 2401.1(19) of 12 the act of April 9, 1929 (P.L.177, No.175), known as The 13 Administrative Code of 1929, repealed by this act, shall not be 14 affected by 62 Pa.C.S. § 905(d). 15 Section 6. (a) The following acts and parts of acts are 16 repealed: 17 Act of May 4, 1876 (P.L.99, No.68), entitled "A supplement to 18 an act, entitled 'An act to carry out the provisions of section 19 twelve, article three of the constitution, relative to contracts 20 for supplies for the legislature and various departments of the 21 state government.'" 22 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to 23 carry out the provisions of section twelve, article three, of 24 the constitution, relative to contracts for supplies for the 25 legislature and the various departments of the state 26 government." 27 Act of June 25, 1895 (P.L.269, No.182), entitled "An act 28 providing that none but citizens of the United States shall be 29 employed in any capacity in the erection, enlargement or 30 improvement of any public building or public work within this 19970S0005B1478 - 136 -
1 Commonwealth." 2 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 3 regulating the time for advertising for and receiving proposals 4 for furnishing paper, cardboard, cuts, plates, and other 5 supplies for the use of the Commonwealth for executing the 6 public printing, and the time contracts for furnishing such 7 supplies shall run." 8 Act of May 1, 1919 (P.L.103, No.79), referred to as the State 9 Art Commission Law. 10 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 11 providing for and regulating the public printing and binding, 12 the editing for publication and the distribution of all 13 documents, reports, bulletins, and other publications for the 14 use of the Commonwealth, the several departments, boards, 15 commissions, and other agencies engaged in the legislative, 16 judicial, and administrative work of the State Government; the 17 sale of waste paper; the appointment of a director and other 18 employes; and repealing inconsistent and conflicting 19 legislation." 20 Sections 478, 2401.1(19), 2403(a), (b), (c) and (g), 2405, 21 2406(g), 2408, 2409, 2409.1, 2410, 2412, 2413 and 2414 of the 22 act of April 9, 1929 (P.L.177, No.175), known as The 23 Administrative Code of 1929. 24 Section 1809 of the act of June 24, 1931 (P.L.1206, No.331), 25 known as The First Class Township Code. 26 Act of January 2, 1934 (Sp.Sess., 1933 P.L.200, No.41), 27 entitled "An act authorizing officers, departments, boards and 28 commissions of any political subdivision of the Commonwealth, 29 and cities, counties, boroughs, incorporated towns, townships, 30 school districts, to make adjustments with certain supply 19970S0005B1478 - 137 -
1 contractors to reimburse losses sustained in performance of 2 contracts under certain circumstances." 3 Act of July 18, 1935 (P.L.1173, No.382), entitled "An act to 4 prohibit discrimination on account of race, creed or color in 5 employment under contracts for public buildings or public 6 works." 7 Act of July 19, 1935 (P.L.1321, No.414), entitled "An act 8 requiring specifications for the construction, alteration, or 9 repair of public works of the Commonwealth, county, 10 municipality, or other subdivisions of the Commonwealth, to 11 contain a provision that the laborers or mechanics employed 12 thereon shall have been residents of this Commonwealth for at 13 least ninety days prior to their employment; and prescribing 14 penalties." 15 Act of April 12, 1945 (P.L.220, No.99), entitled "An act 16 authorizing the Commonwealth and any administrative department, 17 boards, and commissions thereof acting through the Department of 18 Property and Supplies, and political subdivisions of the 19 Commonwealth, including municipal authorities, to enter into 20 contracts with the United States of America, or any agency 21 thereof, for the purchase, lease, or other acquisition of 22 property, real or personal, offered for sale pursuant to the 23 Surplus Property Act of one thousand nine hundred forty-four, 24 without complying with any requirement of existing law as to 25 specifications, advertising, award of contract, and approval of 26 purchases by a State agency receiving competitive bids, or the 27 delivery of property purchased before payment therefor." 28 Sections 404, 405 and 405.1 of the act of June 1, 1945 <-- 29 (P.L.1242, No.428), known as the State Highway Law. 30 Act of June 10, 1947 (P.L.493, No.223), entitled "An act 19970S0005B1478 - 138 -
1 further prescribing the bonds required of foreign corporations 2 contracting for public buildings, public works or projects." 3 Sections 754 and 755 of the act of March 10, 1949 (P.L.30, 4 No.14), known as the Public School Code of 1949. 5 Section 11 of the act of March 31, 1949 (P.L.372, No.34), 6 known as The General State Authority Act of one thousand nine 7 hundred forty-nine. 8 Section 1408 of the act of February 1, 1966 (1965 P.L.1656, 9 No.581), known as The Borough Code. 10 Act of July 23, 1968 (P.L.686, No.226), entitled "An act 11 equalizing trade practices in public works procurement; 12 authorizing the purchase by the Commonwealth, its political 13 subdivisions, and all public agencies, of aluminum and steel 14 products produced in a foreign country, provided the foreign 15 country does not prohibit or discriminate against the 16 importation to, sale or use in the foreign country of supplies, 17 material or equipment manufactured in this Commonwealth; 18 establishing procedures for determining whether foreign 19 countries discriminate against supplies, materials or equipment 20 manufactured in this Commonwealth; and imposing penalties and 21 providing for relief for violation of this act." 22 Act of October 26, 1972 (P.L.1017, No.247), entitled "An act 23 relating to the prevention of environment pollution and the 24 preservation of public natural resources in construction 25 projects." 26 Act of March 3, 1978 (P.L.6, No.3), known as the Steel 27 Products Procurement Act. 28 Act of November 26, 1978 (P.L.1303, No.315), known as the 29 Public Facilities Concession Regulation Act. 30 Act of November 26, 1978 (P.L.1309, No.317), entitled "An act 19970S0005B1478 - 139 -
1 regulating the awarding and execution of certain public 2 contracts; providing for contract provisions relating to the 3 retention, interest, and payment of funds payable under the 4 contracts; and repealing inconsistent acts." 5 Act of October 28, 1983 (P.L.176, No.45), known as the 6 Antibid-Rigging Act. 7 Act of April 4, 1984 (P.L.193, No.40), known as the Motor 8 Vehicle Procurement Act. 9 Act of November 28, 1986 (P.L.1465, No.146), known as the 10 Reciprocal Limitations Act. 11 (b) The following acts and parts of acts are repealed 12 insofar as they relate to Commonwealth agencies as defined in 62 13 Pa.C.S. § 103: 14 Act of December 20, 1967 (P.L.869, No.385), known as the 15 Public Works Contractors' Bond Law of 1967. 16 Act of January 23, 1974 (P.L.9, No.4), entitled "An act 17 prescribing the procedure, after the opening of bids, for the 18 withdrawal of bids on certain public contracts, setting forth 19 the rights of the parties involved and providing penalties," 20 except insofar as the act applies to the leases of real 21 property. 22 Act of May 10, 1996 (P.L.153 No.29), known as the Guaranteed 23 Energy Savings Act. 24 (c) The following acts and parts of acts are repealed 25 insofar as they are inconsistent with this act: 26 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to 27 carry out the provisions of section twelve, article three, of 28 the constitution, relative to contracts for supplies for the 29 legislature and the various departments of the state 30 government." 19970S0005B1478 - 140 -
1 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 2 regulating the time for advertising for and receiving proposals 3 for furnishing paper, cardboard, cuts, plates, and other 4 supplies for the use of the Commonwealth for executing the 5 public printing, and the time contracts for furnishing such 6 supplies shall run." 7 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 8 providing for and regulating the public printing and binding, 9 the editing for publication and the distribution of all 10 documents, reports, bulletins, and other publications for the 11 use of the Commonwealth, the several departments, boards, 12 commissions, and other agencies engaged in the legislative, 13 judicial, and administrative work of the State Government; the 14 sale of waste paper; the appointment of a director and other 15 employes; and repealing inconsistent and conflicting 16 legislation." 17 Sections 507, 508, 510 and 511 of the act of April 9, 1929 18 (P.L.177, No.175), known as The Administrative Code of 1929. 19 Act of June 23, 1931 (P.L.1181, No.321), entitled "An act 20 authorizing persons, co-partnerships, associations, and 21 corporations, who, whether as sub-contractor or otherwise, have 22 furnished material or supplied or performed labor in connection 23 with any public work or improvement, to intervene in or 24 institute actions on certain bonds given to the Commonwealth or 25 to municipal corporations in connection with the performance of 26 public contracts; fixing the time within which such actions must 27 be brought, and the amounts recoverable therein; and providing 28 for distribution of amounts recovered; and prescribing 29 procedure." 30 Section 6 of the act of May 20, 1937 (P.L.728, No.193), 19970S0005B1478 - 141 -
1 referred to as the Board of Claims Act only insofar as it is 2 inconsistent with the procedure provided for in 62 Pa.C.S. § 3 1712 regarding the resolution of a contract controversy by the 4 head of a purchasing agency. 5 Section 10 of the act of July 5, 1947 (P.L.1217, No.498), 6 known as the State Public School Building Authority Act. 7 Section 12 of the act of December 6, 1967 (P.L.678, No.318), 8 known as The Pennsylvania Higher Educational Facilities 9 Authority Act of 1967. 10 Section 4 of the act of November 20, 1968 (P.L.1075, No.329), 11 entitled "An act providing for the growth and development of 12 noncommercial educational television; creating the Pennsylvania 13 Public Television Network Commission as an independent 14 commission and defining its powers and duties." 15 (d) Nothing in this act shall repeal, modify or supplant the 16 following acts and parts of acts: 17 Section 516 of the act of April 9, 1929 (P.L.177, No.175), 18 known as The Administrative Code of 1929. 19 SECTION 303 OF THE ACT OF APRIL 9, 1929 (P.L.343, NO.176), <-- 20 KNOWN AS THE FISCAL CODE. 21 Act of July 19, 1957 (P.L.1017, No.451), known as the State 22 Adverse Interest Act. 23 Act of February 11, 1976 (P.L.14, No.10), known as the 24 Pennsylvania Rural and Intercity Common Carrier Surface 25 Transportation Assistance Act. 26 ACT OF APRIL 3, 1992 (P.L.28, NO.11), KNOWN AS THE TUITION <-- 27 ACCOUNT PROGRAM AND COLLEGE SAVINGS BOND ACT. 28 (e) All other acts and parts of acts are repealed insofar as 29 they are inconsistent with this act. 30 Section 7. This act shall apply to contracts solicited or 19970S0005B1478 - 142 -
1 entered into on or after the effective date of this act unless 2 the parties agree to its application to a contract solicited or 3 entered into prior to the effective date of this act. 4 Section 8. This act shall take effect in 180 days. L11L62JLW/19970S0005B1478 - 143 -