PRINTER'S NO. 1328
No. 1000 Session of 2005
INTRODUCED BY TOMLINSON, CONTI, WONDERLING, BOSCOLA, PILEGGI, STACK, ERICKSON, LAVALLE AND FONTANA, NOVEMBER 14, 2005
REFERRED TO CONSUMER PROTECTION AND PROFESSIONAL LICENSURE, NOVEMBER 14, 2005
AN ACT 1 Providing for the regulation of home improvement contracts and 2 for the registration of certain contractors; prohibiting 3 certain acts; and providing for penalties. 4 The General Assembly of the Commonwealth of Pennsylvania 5 hereby enacts as follows: 6 Section 1. Short title. 7 This act shall be known and may be cited as the Home 8 Improvement Consumer Protection Act. 9 Section 2. Definitions. 10 The following words and phrases when used in this act shall 11 have the meanings given to them in this section unless the 12 context clearly indicates otherwise: 13 "Bureau." The Bureau of Consumer Protection in the Office of 14 Attorney General. 15 "Contractor." Any person, including a subcontractor or 16 employee of another contractor, who owns and operates a home 17 improvement business or who undertakes, offers to undertake or 18 agrees to perform any home improvement. The term does not
1 include a person for whom the total cash value of all of that 2 person's home improvements is less than $5,000 during any period 3 of 12 consecutive months. 4 "Home improvement." 5 (1) The term includes all of the following done in 6 connection with land or a portion of the land adjacent to a 7 private residence or a building or a portion of the building 8 which is used or designed to be used as a private residence 9 for which the total cash price of all work agreed upon 10 between the contractor and owner is more than $200. 11 (i) Repair, replacement, remodeling, demolition, 12 removal, renovation, installation, alteration, 13 conversion, modernization, improvement, rehabilitation or 14 sandblasting. 15 (ii) Construction, replacement, installation or 16 improvement of driveways, swimming pools, pool houses, 17 porches, garages, roofs, siding, insulation, solar energy 18 systems, security systems, flooring, patios, fences, 19 gazebos, sheds, cabanas, landscaping of a type that is 20 not excluded under paragraph (2)(vi), painting, doors and 21 windows and waterproofing. 22 (iii) Without regard to affixation, the installation 23 of central heating or air conditioning or storm windows 24 or awnings. 25 (iv) The conversion of existing commercial 26 structures into residential or noncommercial structures. 27 (2) The term does not include: 28 (i) The construction of a new home. 29 (ii) The sale of goods or materials by a seller who 30 neither arranges to nor performs, directly or indirectly, 20050S1000B1328 - 2 -
1 any work or labor in connection with the installation or 2 application of the goods or materials. 3 (iii) The sale of services furnished for commercial 4 or business use or for resale, if the service takes place 5 somewhere other than at a private residence. 6 (iv) The sale of appliances, including stoves, 7 refrigerators, freezers, room air conditioners and others 8 which are designed for and are easily removable from the 9 premises without material alteration the cost of which is 10 more than $200. 11 (v) Any work performed without compensation by the 12 owner of the owner's private residence or residential 13 rental property. 14 (vi) Any work performed by a landscaper certified by 15 the Department of Agriculture under the act of December 16 16, 1992 (P.L.1228, No.162), known as the Plant Pest Act, 17 except to the extent that the work involves any of the 18 following at a private residence: 19 (A) The construction, replacement, installation 20 or improvement of buildings, driveways, swimming 21 pools, porches, garages, roofs, siding, insulation, 22 solar energy systems, security systems, flooring, 23 patios, nondecorative fences, doors, lighting 24 systems, concrete walkways and windows. 25 (B) The placement of retaining walls, fountains 26 or drainage systems. 27 "Home improvement contract." An agreement between a 28 contractor, subcontractor or salesperson and an owner for the 29 performance of a home improvement which includes all agreements 30 for labor, services and materials to be furnished and performed 20050S1000B1328 - 3 -
1 under the contract. 2 "Owner." 3 (1) The term includes any of the following: 4 (i) An owner of a private residence, including any 5 person authorized by an owner to act on the owner's 6 behalf to order, contract for or purchase a home 7 improvement. 8 (ii) A person entitled to the performance of the 9 work of a contractor pursuant to a home improvement 10 contract. 11 (2) An owner of a private residence shall not be 12 required to reside in the residence to be deemed an owner 13 under this act. 14 (3) A person who owns three or more private residences 15 in this Commonwealth shall not be deemed an owner except with 16 respect to the person's primary residence or the part of the 17 building which houses the primary residence of the owner. 18 "Person." An individual, partnership, limited partnership, 19 limited liability company, joint venture or corporation. 20 "Private residence." Any of the following: 21 (1) A single family dwelling. 22 (2) A multifamily dwelling consisting of not more than 23 three units. 24 (3) A single unit located within any multifamily 25 dwelling, including condominiums and co-op units. 26 "Special order material." Materials that, prior to their 27 delivery to the worksite, meet all of the following 28 requirements: 29 (1) Require processing by a manufacturer to meet the 30 designated specifications of a particular home improvement 20050S1000B1328 - 4 -
1 project. 2 (2) Cannot be returned to the supplier for a refund or 3 credit because of features that limit their use to the 4 particular home improvement project. 5 (3) Have no value in the performance of another home 6 improvement project other than the particular home 7 improvement project they were procured for. 8 "Specifications." The plans, detailed drawings, lists of 9 materials, stated allowances or other methods customarily used 10 in the home improvement industry as a whole to describe with 11 particularity the work, workmanship, materials and quality of 12 materials for each home improvement. 13 "Tenant." A person who has entered into a lease or other 14 contractual arrangement with the owner. 15 Section 3. Registration of contractors. 16 (a) General rule.--No person shall hold himself out as a 17 contractor nor shall a person perform any home improvement 18 without first registering with the bureau as provided for in 19 this act. 20 (b) Liability.--No business entity registered pursuant to 21 this act shall be relieved of responsibility under this act for 22 the conduct and acts of its agents, employees, officers or 23 directors, nor shall any person be relieved of responsibility 24 under this act by reason of his employment or relationship with 25 such business entity. 26 (c) Public access to registration information.--The bureau 27 shall maintain a toll-free telephone number from which a caller 28 can obtain information as to whether a contractor is registered 29 with the bureau pursuant to this act. 30 (d) Nongrant or renewal of license.--The Department of 20050S1000B1328 - 5 -
1 Banking shall not grant or renew a license to any person 2 registered, or required to be registered, as a home improvement 3 contractor pursuant to any of the following: 4 (1) The act of December 12, 1980 (P.L.1179, No.219), 5 known as the Secondary Mortgage Loan Act. 6 (2) The act of December 22, 1989 (P.L.687, No.90), known 7 as the Mortgage Bankers and Brokers and Consumer Equity 8 Protection Act. 9 Section 4. Procedures for registration as a contractor. 10 (a) Application.--A person shall apply to the bureau in 11 writing on a form provided by the bureau. The application shall 12 include the following information: 13 (1) For an individual applicant, the name, home address, 14 home telephone number and driver's license identification 15 number of the applicant, as well as the individual's business 16 name, address and telephone number if different, and all 17 prior business names and addresses of home improvement 18 businesses. 19 (2) For a partnership applicant, the name, home address, 20 home telephone number and driver's license identification 21 number of each partner as well as the partnership name, 22 address and telephone number. 23 (3) For a corporation, limited liability company or 24 limited partnership applicant, the name, home address, home 25 telephone number and driver's license identification number 26 of each officer, each director or each individual holding 27 greater than a 5% stake in the business, as well as the 28 entity's business name, address and telephone number. 29 (4) For an out-of-State corporation, limited liability 30 or limited partnership, the name and address of the entity's 20050S1000B1328 - 6 -
1 resident agent or registered office provider within this 2 Commonwealth and any registration number or license number 3 issued to the entity by its home state or political 4 subdivision of such other state, if applicable. 5 (5) For a joint venture applicant, the name, address and 6 telephone number of the joint venture, as well as the name, 7 address and telephone number of each party to the joint 8 venture. When the parties to a joint venture include business 9 entities, the information required from such entities 10 pursuant to paragraphs (2) and (3) shall also be provided. 11 (6) A complete description of the nature of the 12 contracting business of the applicant. 13 (7) A statement whether: 14 (i) The individual or individuals making 15 application, even if doing so as part of a business 16 entity application, has ever been convicted of a criminal 17 offense related to a home improvement transaction, fraud, 18 theft, a crime of deception or a crime involving 19 fraudulent business practices, as well as a statement 20 whether the applicant has ever had a civil judgment 21 entered against the applicant or businesses in which the 22 applicant held an interest that was related to a home 23 improvement transaction. 24 (ii) The applicant's certificate or the certificate 25 of a business with which the person making application 26 held an interest has ever been revoked or suspended 27 pursuant to an order issued by a court of competent 28 jurisdiction in this Commonwealth or any other state or 29 political subdivision thereof. 30 (8) Whether within the last ten years the applicant has 20050S1000B1328 - 7 -
1 ever been suspended or debarred from participating in any 2 Federal, State or local program through which funding or 3 other assistance is provided to consumers for home 4 improvements. 5 (b) Reporting of multiple registrations or licensures.--Any 6 registered contractor in this Commonwealth who is registered or 7 licensed as a home improvement contractor in any other state, or 8 political subdivision thereof, shall report this information to 9 the bureau on the initial registration and biennial registration 10 application. Any disciplinary action taken in such other 11 jurisdiction shall be reported to the bureau on the initial 12 registration application or, if such action occurred subsequent 13 to submission of an initial application, on the biennial 14 registration application or within 90 days of final disposition, 15 whichever is sooner. Multiple registrations or licensures shall 16 be noted by the bureau on the contractor's registration, and 17 such state, or political subdivision thereof, shall be notified 18 by the bureau of any disciplinary actions taken against such 19 contractor in this Commonwealth. 20 Section 5. Application fees. 21 Each application for a certificate for a home improvement 22 contractor or renewal of that certificate shall be accompanied 23 by a fee of $50. Renewals shall be on a biennial basis. 24 Section 6. Home improvement contracts. 25 (a) Requirements.--No home improvement contract shall be 26 valid or enforceable against an owner unless it: 27 (1) Is in writing and legible. 28 (2) Is signed by all of the following: 29 (i) The owner, his agent or other contracted party. 30 (ii) The contractor or a salesperson on behalf of a 20050S1000B1328 - 8 -
1 contractor. 2 (3) Contains the entire agreement between the owner and 3 the contractor, including attached copies of all required 4 notices. 5 (4) Contains the date of the transaction. 6 (5) Contains the name, address and telephone number of 7 the contractor. For the purposes of this paragraph, a post 8 office box number alone shall not be considered an address. 9 (6) Contains the approximate starting date and 10 completion date. 11 (7) Includes a description of the work to be performed, 12 the materials to be used and a set of specifications that 13 cannot be changed without a written change order signed by 14 the owner and contractor. 15 (8) Includes the total sales price due under the 16 contract. 17 (9) Includes the amount of down payment. 18 (10) Includes the names, addresses and telephone numbers 19 of all subcontractors on the project. For the purposes of 20 this paragraph, a post office box number alone shall not be 21 considered an address. 22 (11) Includes a statement that any holder of the 23 contract is subject to all claims and defenses which the 24 owner could assert against the contractor and that recovery 25 may not be more than the total contract price. 26 (12) Includes proof of liability insurance covering 27 personal injury in an amount not less than $50,000 and 28 insurance covering property damage caused by the work of a 29 home improvement contractor in an amount not less than 30 $50,000. 20050S1000B1328 - 9 -
1 (b) Right of rescission.--Without regard to the location of 2 the transaction, all home improvement contracts shall be subject 3 to section 7 of the act of December 17, 1968 (P.L.1224, No.387), 4 known as the Unfair Trade Practices and Consumer Protection Law. 5 (c) Copy to be provided.--A contractor or salesperson shall 6 provide and deliver to the owner, without charge, a completed 7 copy of the home improvement contract at the time the contract 8 is executed which shall contain all required notices. 9 (d) Voidable clauses.--If a home improvement contract 10 contains any of the following clauses, the home improvement 11 contract shall be voidable: 12 (1) A hold harmless clause. 13 (2) A waiver of Federal, State or local health, life, 14 safety or building code requirements. 15 (3) A confession of judgment clause. 16 (4) A waiver of any right to a jury trial in any action 17 brought by or against the owner. 18 (5) A mandatory arbitration clause. 19 (6) An assignment of or order for payment of wages or 20 other compensation for services. 21 (7) A provision by which the owner agrees not to assert 22 any claim or defense arising out of the contract. 23 (8) A provision that the contractor may be awarded 24 attorney fees and costs. 25 (9) A clause by which the owner relieves the contractor 26 from liability for acts committed by the contractor or the 27 contractor's agents in the collection of any payments or in 28 the repossession of any goods. 29 (10) A waiver of any rights provided under this act. 30 (11) A provision providing for the automatic or 20050S1000B1328 - 10 -
1 recurring renewal of any provisions of the agreement, unless: 2 (i) the contract establishes a procedure by which 3 the consumer can choose not to renew the provision or 4 provisions, thereby avoiding any new fees or charges, by 5 providing written notice to the contractor via first 6 class mail postmarked no later than three business days 7 prior to any renewal; 8 (ii) such procedure is clearly and conspicuously 9 disclosed in the agreement; and 10 (iii) the contract includes a provision requiring 11 the contractor to notify the consumer of any automatic or 12 recurring renewal, and the consumer's option to cancel 13 such renewal, by mail not earlier than 20 days and not 14 later than ten days prior to the date of any such 15 renewal. 16 (e) Contractor's recovery right.--Nothing in this section 17 shall preclude a contractor who has complied with subsection (a) 18 from the recovery of payment for work performed based on the 19 reasonable value of services which were requested by the owner 20 if a court determines that it would be inequitable to deny such 21 recovery. 22 Section 7. Home improvement fraud. 23 (a) Offense defined.--A person commits the offense of home 24 improvement fraud if, with intent to defraud or injure anyone or 25 with knowledge that he is facilitating a fraud or injury to be 26 perpetrated by anyone, the actor: 27 (1) makes a false or misleading statement to induce, 28 encourage or solicit a person to enter into any written or 29 oral agreement for home improvement services or provision of 30 home improvement materials or to justify an increase in the 20050S1000B1328 - 11 -
1 previously agreed upon price; 2 (2) receives any advance payment for performing home 3 improvement services or providing home improvement materials, 4 fails to perform or provide such services or materials within 5 the date specified in the agreement taking into account any 6 force majeure or unforeseen labor strike that would extend 7 the time frame or unless extended by agreement with the 8 consumer and fails to return the payment received for such 9 services or materials which were not provided by that date; 10 (3) while soliciting a person to enter into an agreement 11 for home improvement services or materials, misrepresents or 12 conceals the contractor's or salesperson's real name, the 13 name of the contractor's business, the contractor's business 14 address or any other identifying information; 15 (4) damages a person's property with the intent to 16 induce, encourage or solicit that person to enter into a 17 written or oral agreement for performing home improvement 18 services or providing home improvement materials; 19 (5) misrepresents himself or another as an employee or 20 agent of the Federal, Commonwealth or municipal government, 21 any other governmental unit or any public utility, with the 22 intent to cause a person to enter into any agreement for 23 performing home improvement services or providing home 24 improvement materials; 25 (6) alters a home improvement agreement, mortgage, 26 promissory note or other document incident to performing or 27 selling a home improvement without the consent of the 28 consumer; or 29 (7) directly or indirectly publishes a false or 30 deceptive advertisement in violation of State law governing 20050S1000B1328 - 12 -
1 advertising about home improvement. 2 (b) Grading.-- 3 (1) A violation of subsection (a)(1), (3), (4), (5), (6) 4 or (7) constitutes: 5 (i) a felony of the third degree if the amount 6 involved exceeds $2,000; or 7 (ii) a misdemeanor of the first degree if the amount 8 involved is $2,000 or less or if the amount involved 9 cannot be satisfactorily ascertained. 10 (2) A violation of subsection (a)(2) constitutes: 11 (i) a felony of the third degree if the amount of 12 the payment retained exceeds $2,000; or 13 (ii) a misdemeanor of the first degree if the amount 14 of the payment retained is $2,000 or less or if the 15 amount of the payment cannot be satisfactorily 16 ascertained. 17 (3) Amounts involved pursuant to one scheme or course of 18 conduct, whether involving one or more victims, may be 19 aggregated in determining the grade of the offense pursuant 20 to subsection (a). 21 (4) Where a person commits an offense under subsection 22 (a) and the victim is 60 years of age or older, the grading 23 of the offense shall be one grade higher than specified in 24 paragraphs (1), (2) and (3). This paragraph shall not be 25 applicable to persons whose sentence would be enhanced 26 pursuant to paragraph (5). 27 (5) Notwithstanding any other provisions of this 28 section, where a person commits a second or subsequent 29 offense described in subsection (a), the offense will 30 constitute a felony of the second degree regardless of the 20050S1000B1328 - 13 -
1 amount of money involved. For this paragraph to be 2 applicable, the second or subsequent offense must have 3 occurred after the first conviction. Paragraph (4) shall not 4 be applicable to persons whose sentences would be enhanced 5 pursuant to this paragraph. 6 (6) In addition to any other penalty imposed by this 7 act, the court may revoke or suspend the certificate of 8 registration issued under section 3. At the time of 9 sentencing, the court shall state the reasons for such 10 revocation or suspension. 11 (c) Jurisdiction.-- 12 (1) The district attorneys of the several counties shall 13 have the authority to investigate and to institute criminal 14 proceedings for any violation of this section. 15 (2) In addition to the authority conferred upon the 16 Attorney General by the act of October 15, 1980 (P.L.950, 17 No.164), known as the Commonwealth Attorneys Act, the 18 Attorney General shall have the authority to investigate and 19 institute criminal proceedings for any violation of this 20 section or any series of such violations involving more than 21 one county of this Commonwealth or involving any county of 22 this Commonwealth and another state. No person charged with a 23 violation of this section by the Attorney General shall have 24 standing to challenge the authority of the Attorney General 25 to investigate or prosecute the case, and, if any such 26 challenge is made, the challenge shall be dismissed and no 27 relief shall be available in the courts of this Commonwealth 28 to the person making the challenge. 29 Section 8. Prohibited acts. 30 No person shall: 20050S1000B1328 - 14 -
1 (1) Fail to register as required by this act. 2 (2) Fail to refund the amount paid for a home 3 improvement within ten days of either the acceptance and 4 execution of a return receipt for certified mail containing a 5 written request for a refund or the refusal to accept the 6 certified mail sent to the contractor's last known address if 7 all of the following apply: 8 (i) No substantial portion of the contracted work 9 has been performed at the time of the request. 10 (ii) More than 30 days have elapsed since the 11 starting date specified in the written contract. 12 (3) Accept a municipal certificate of occupancy or other 13 proof that performance of a home improvement contract is 14 complete or satisfactorily concluded with knowledge that the 15 document or proof is false and the performance is incomplete. 16 (4) Utter, offer or use a completion certificate or 17 other proof that a home improvement contract is complete or 18 satisfactorily concluded when the person knows or has reason 19 to know that the document or proof is false and is made to 20 accomplish any of the following: 21 (i) Make or accept an assignment or negotiation of 22 the right to receive payment under a home improvement 23 contract. 24 (ii) Get or grant credit or a loan on security of 25 the right to receive payment under a home improvement 26 contract. 27 (5) Abandon or fail to perform, without justification, 28 any home improvement contract or project engaged in or 29 undertaken by a contractor. For the purposes of this 30 paragraph, the term "justification" shall include nonpayment 20050S1000B1328 - 15 -
1 by the owner as required under the contract or any other 2 violation of the contract by the owner. 3 (6) Deviate from or disregard plans or specifications, 4 in any material respect, without a written change order dated 5 and signed by both the contractor and owner, which contains 6 the accompanying price changes for each deviation. 7 (7) Prepare, arrange, accept or participate in arranging 8 a mortgage, promissory note or other evidence of debt for 9 performing or selling a home improvement with knowledge that 10 the evidence of debt states a greater monetary obligation 11 than the consideration, including a time sale price, for a 12 home improvement. 13 (8) Advertise or offer, by any means, to perform a home 14 improvement if the person does not intend to do any of the 15 following: 16 (i) Accept a home improvement contract. 17 (ii) Perform the home improvement. 18 (iii) Charge for the home improvement at the price 19 advertised or offered. 20 (9) Demand or receive any payment for a home improvement 21 before the home improvement contract is signed. 22 (10) For a home improvement contract in which the total 23 price is more than $1,000, receive a deposit in excess of the 24 greater of any of the following: 25 (i) One-third of the home improvement contract 26 price. 27 (ii) The cost of any special-order materials or 28 merchandise purchased or to be purchased under the home 29 improvement contract. 30 (11) While acting as a salesperson, fail to account for 20050S1000B1328 - 16 -
1 or remit to the contractor whom the salesperson represents a 2 payment received in connection with a home improvement. 3 Section 9. Unfair Trade Practices and Consumer Protection Law. 4 A violation of any of the provisions of this act shall be 5 deemed a violation of the act of December 17, 1968 (P.L.1224, 6 No.387), known as the Unfair Trade Practices and Consumer 7 Protection Law. 8 Section 10. Regulations. 9 The bureau may adopt rules and regulations necessary to carry 10 out the provisions of this act. 11 Section 11. Exemptions. 12 This act shall not apply to any of the following persons or 13 organizations: 14 (1) The Commonwealth, or any of its political 15 subdivisions. 16 (2) The Federal Government. 17 Section 20. Effective date. 18 This act shall take effect in 180 days. J26L12RLE/20050S1000B1328 - 17 -