PRINTER'S NO. 1524
No. 1291 Session of 1983
INTRODUCED BY McVERRY, OLIVER, SPENCER, SWEET, MARMION, WAMBACH, STEVENS, WOGAN, MICHLOVIC, COLAFELLA, MADIGAN, R. C. WRIGHT, GAMBLE, BURD, CESSAR, BOOK, KENNEDY, RICHARDSON, GREENWOOD, BOWSER, WACHOB, ARTY, SEMMEL, PISTELLA, FARGO, E. Z. TAYLOR, MORRIS, SAURMAN, PETERSON, BUNT, HAGARTY AND POTT, JUNE 29, 1983
REFERRED TO COMMITTEE ON JUDICIARY, JUNE 29, 1983
AN ACT 1 Amending Titles 1 (General Provisions), 42 (Judiciary and 2 Judicial Procedure) and 62 (Procurement) of the Pennsylvania 3 Consolidated Statutes, adding provisions relating to 4 procurement; and making repeals. 5 TABLE OF CONTENTS 6 TITLE 62 7 PROCUREMENT 8 PART I. COMMONWEALTH PROCUREMENT CODE 9 Chapter 1. General Provisions 10 § 101. Short title of part. 11 § 102. Application of part. 12 § 103. Definitions. 13 § 104. General principles of law otherwise applicable. 14 § 105. Determinations. 15 § 106. Public access to procurement information. 16 § 107. Reciprocal limitations. 17 Chapter 3. Procurement Organization
1 Subchapter A. Organization of Public Procurement 2 § 301. Procurement responsibility. 3 Subchapter B. Commonwealth Procurement Policy Office 4 § 311. Composition and administrative support. 5 § 312. Powers and duties. 6 § 313. Procurement regulations. 7 Subchapter C. Powers and Duties of Department 8 § 321. Powers and duties. 9 Subchapter D. Coordination, Training and Education 10 § 331. Collection of data concerning public procurement. 11 § 332. Advisory groups. 12 Chapter 5. Source Selection and Contract Formation 13 Subchapter A. Definitions 14 § 501. Definitions. 15 Subchapter B. Methods of Source Selection 16 § 511. Methods of source selection. 17 § 512. Competitive sealed bidding. 18 § 513. Competitive sealed proposals. 19 § 514. Small purchases. 20 § 515. Sole source procurement. 21 § 516. Emergency procurement. 22 § 517. Multiple awards. 23 § 518. Competitive selection procedures for certain services. 24 § 519. Selection procedure for insurance and bonds. 25 § 520. Handicapped-made supplies and services. 26 Subchapter C. Cancellation of Invitations for Bids or 27 Request for Proposals 28 § 521. Cancellation of invitations for bids or requests for 29 proposals. 30 Subchapter D. Qualifications and Duties 19830H1291B1524 - 2 -
1 § 531. Debarment or suspension. 2 § 532. Prequalification of bidders and offerors. 3 § 533. Responsibility of bidders and offerors. 4 § 534. Bid security and performance bonds. 5 § 535. Cost or pricing data. 6 § Subchapter E. Types of Contracts 7 § 541. Restrictions on contracts. 8 § 542. Approval of accounting system. 9 § 543. Multiterm contracts. 10 Subchapter F. Inspection of Plant and Audit of Records 11 § 551. Right to inspect plant. 12 § 552. Right to audit records. 13 Subchapter G. Determinations and Reports 14 § 561. Finality of determinations. 15 § 562. Anti-competitive practices. 16 § 563. Retention of procurement records. 17 § 564. Record of certain actions. 18 Chapter 7. Specifications 19 § 701. Purpose and scope. 20 § 702. Duties of policy office. 21 § 703. Duties of department. 22 § 704. Exempted items. 23 § 705. Relationship with using agencies. 24 § 706. Wage specifications. 25 Chapter 9. Procurement of Construction, Architect, Engineer 26 and Land Surveying Services 27 § 901. Definitions. 28 § 902. Selection of method of construction contracting. 29 § 903. Bid security. 30 § 904. Contract performance and payment bonds. 19830H1291B1524 - 3 -
1 § 905. Bond forms and copies. 2 § 906. Contract clauses and their administration. 3 § 907. Fiscal responsibility. 4 § 908. Architect, engineer and land surveying services. 5 Chapter 11. Modification and Termination of Contracts for 6 Supplies and Services 7 § 1101. Contract clauses and their administration. 8 Chapter 13. Cost Principles 9 § 1301. Cost principles regulations required. 10 Chapter 15. Supply Management 11 § 1501. Definitions. 12 § 1502. Supply management regulations required. 13 § 1503. Proceeds from sale or disposal of surplus supplies. 14 Chapter 17. Legal and Contractual Remedies 15 Subchapter A. General Provisions 16 § 1701. Definitions. 17 § 1702. Sovereign immunity. 18 Subchapter B. Prelitigation Resolution of Controversies 19 § 1711. Authority to resolve protests of solicitations or 20 awards. 21 § 1712. Authority to resolve contract and breach of contract 22 controversies. 23 Subchapter C. Board of Claims 24 § 1721. Composition. 25 § 1722. Hearing panels. 26 § 1723. Administrative matters. 27 § 1724. Jurisdiction. 28 § 1725. Procedure. 29 § 1726. Appeals. 30 Subchapter D. Solicitations or Awards in Violation of Law 19830H1291B1524 - 4 -
1 § 1741. Applicability. 2 § 1742. Remedies prior to an award. 3 § 1743. Remedies after the award. 4 Subchapter E. Interest 5 § 1751. Interest. 6 Chapter 19. Intergovernmental Relations 7 § 1901. Definitions. 8 § 1902. Cooperative purchasing authorized. 9 § 1903. Sale, acquisition or use of supplies by a public 10 procurement unit. 11 § 1904. Cooperative use of supplies or services. 12 § 1905. Joint use of facilities. 13 § 1906. Supply of personnel, information and technical 14 services. 15 § 1907. Use of payments received by a supplying public 16 procurement unit. 17 § 1908. Compliance of public procurement units. 18 § 1909. Review of procurement requirements. 19 § 1910. Contract controversies. 20 Chapter 21. Small and Disadvantaged Businesses 21 § 2101. Policy. 22 § 2102. Definitions. 23 § 2103. Regulations. 24 § 2104. Duties of department. 25 § 2105. Bonding and progress payments. 26 § 2106. Business assistance offices. 27 § 2107. Report to policy office and General Assembly. 28 § 2108. Compliance with Federal requirements. 29 Chapter 23. Ethics in Public Contracting 30 Subchapter A. General Policy and Standards 19830H1291B1524 - 5 -
1 § 2301. Policy. 2 § 2302. General standards of ethical conduct. 3 § 2303. Reporting of breaches of ethical standards. 4 Subchapter B. Specific Standards 5 § 2311. Bonds. 6 PART II. GENERAL PROCUREMENT PROVISIONS 7 Chapter 31. General Provisions 8 § 3101. Application of part. 9 § 3102. Definitions. 10 Chapter 33. Prevention of Environmental Pollution 11 § 3301. Invitations for bids and requests for proposals. 12 § 3302. Additional work. 13 § 3303. Arbitration of disputes. 14 Chapter 35. Foreign Corporations 15 § 3501. Condition precedent to release of bond. 16 Chapter 37. Contract Clauses and Preference Provisions 17 Subchapter A. Labor 18 § 3701. Contract provisions prohibiting discrimination. 19 § 3702. Contract provision requiring United States citizens to 20 be employed. 21 § 3703. Contract provision requiring residents to be employed. 22 Subchapter B. Steel Products 23 § 3711. Short title of subchapter. 24 § 3712. Definitions. 25 § 3713. Required contract provisions. 26 § 3714. Payments under contracts. 27 Subchapter C. Trade Practices 28 § 3721. Short title of subchapter. 29 § 3722. Definitions. 30 § 3723. Unlawful acts. 19830H1291B1524 - 6 -
1 § 3724. Preference. 2 § 3725. Listing discriminating countries. 3 § 3726. Determining discrimination. 4 § 3727. Foreign registry docket. 5 § 3728. Aluminum or steel products from a discriminating 6 country. 7 Subchapter D. Used Oil Products 8 § 3741. Preference. 9 Chapter 39. Construction Contracts Over $50,000 10 § 3901. Application of chapter. 11 § 3902. Definitions. 12 § 3903. Time for awarding contract. 13 § 3904. Time for executing contract. 14 § 3905. Release of successful bidder. 15 § 3906. Retainage. 16 § 3907. Payment of retainage to subcontractors. 17 § 3908. Final payment under contract. 18 § 3909. Arbitration. 19 Chapter 41. Purchase of Surplus Federal Property 20 § 4101. Contracts with United States. 21 § 4102. Bids and down payments. 22 Chapter 43. Public Facilities Concessions 23 § 4301. Short title of chapter. 24 § 4302. Definitions. 25 § 4303. Terms of contracts. 26 The General Assembly of the Commonwealth of Pennsylvania 27 hereby enacts as follows: 28 Section 1. Section 2310 of Title 1 of the Pennsylvania 29 Consolidated Statutes is amended to read: 30 § 2310. Sovereign immunity reaffirmed; specific waiver. 19830H1291B1524 - 7 -
1 Pursuant to section 11 of Article 1 of the Constitution of 2 Pennsylvania, it is hereby declared to be the intent of the 3 General Assembly that the Commonwealth, and its officials and 4 employees acting within the scope of their duties, shall 5 continue to enjoy sovereign immunity and official immunity and 6 remain immune from suit except as the General Assembly shall 7 specifically waive the immunity. When the General Assembly 8 specifically waives sovereign immunity, a claim against the 9 Commonwealth and its officials and employees shall be brought 10 only in such manner and in such courts and in such cases as 11 directed by the provisions of Title 42 (relating to judiciary 12 and judicial procedure) or 62 (relating to procurement), unless 13 otherwise specifically authorized by statute. 14 Section 2. Section 763(a) of Title 42 is amended to read: 15 § 763. Direct appeals from government agencies. 16 (a) General rule.--Except as provided in subsection (c), the 17 Commonwealth Court shall have exclusive jurisdiction of appeals 18 from final orders of government agencies in the following cases: 19 (1) All appeals from Commonwealth agencies under 20 Subchapter A of Chapter 7 of Title 2 (relating to judicial 21 review of Commonwealth agency action) or otherwise and 22 including appeals from the Board of Claims, the Environmental 23 Hearing Board, the Pennsylvania Public Utility Commission, 24 the Unemployment Compensation Board of Review and from any 25 other Commonwealth agency having Statewide jurisdiction. 26 (2) All appeals jurisdiction of which is vested in the 27 Commonwealth Court by any statute hereafter enacted. 28 * * * 29 Section 3. Title 62 is amended by adding parts to read: 30 TITLE 62 19830H1291B1524 - 8 -
1 PROCUREMENT 2 Part 3 I. Commonwealth Procurement Code 4 II. General Procurement Provisions 5 PART I 6 COMMONWEALTH PROCUREMENT CODE 7 Chapter 8 1. General Provisions 9 3. Procurement Organization 10 5. Source Selection and Contract Formation 11 7. Specifications 12 9. Procurement of Construction, Architect, Engineer and Land 13 Surveying Services 14 11. Modification and Termination of Contracts for Supplies 15 and Services 16 13. Cost Principles 17 15. Supply Management 18 17. Legal and Contractual Remedies 19 19. Intergovernmental Relations 20 21. Small and Disadvantaged Businesses 21 23. Ethics in Public Contracting 22 CHAPTER 1 23 GENERAL PROVISIONS 24 Sec. 25 101. Short title of part. 26 102. Application of part. 27 103. Definitions. 28 104. General principles of law otherwise applicable. 29 105. Determinations. 30 106. Public access to procurement information. 19830H1291B1524 - 9 -
1 107. Reciprocal limitations. 2 § 101. Short title of part. 3 This part shall be known and may be cited as the Commonwealth 4 Procurement Code. 5 § 102. Application of part. 6 (a) Application to Commonwealth procurement.--This part 7 applies to every expenditure of funds other than the investment 8 of funds by Commonwealth agencies under any contract, 9 irrespective of their source, including Federal assistance 10 moneys except as specified in section 2108 (relating to 11 compliance with Federal requirements). This part does not apply 12 to grants or contracts between Commonwealth agencies or between 13 the Commonwealth and its political subdivisions, or other 14 governments except as provided in Chapter 19 (relating to 15 intergovernmental relations). Nothing in this part or in 16 accompanying regulations shall prevent any Commonwealth agency 17 or political subdivision from complying with the terms and 18 conditions of any grant, gift, bequest or cooperative agreement. 19 (b) Application to disposal of Commonwealth supplies.--This 20 part applies to the disposal of supplies of Commonwealth 21 agencies. 22 (c) Application to local agencies.--Any political 23 subdivision or other local public agency may specifically or by 24 reference adopt all or any part of this part and its 25 accompanying regulations. 26 § 103. Definitions. 27 Subject to additional definitions contained in subsequent 28 provisions of this part which are applicable to specific 29 provisions of this part, the following words and phrases when 30 used in this part shall have the meanings given to them in this 19830H1291B1524 - 10 -
1 section unless the context clearly indicates otherwise: 2 "Change order." A written order signed by the procurement 3 officer directing the contractor to make changes which the 4 changes clause of the contract authorizes the procurement 5 officer to order without the consent of the contractor. 6 "Commonwealth agency." Any executive or independent agency. 7 "Construction." The process of building, altering, 8 repairing, improving or demolishing any public structure or 9 building or other public improvements of any kind to any public 10 real property. The term does not include the routine operation, 11 repair or maintenance of existing structures, buildings or real 12 property. 13 "Contract." Any type of written agreement, regardless of 14 what it may be called, for the procurement or disposal of 15 supplies, services or construction. 16 "Contract modification." Any written alteration in 17 specifications, delivery point, rate of delivery, period of 18 performance, price, quantity or other provisions of any 19 contract, accomplished by mutual action of the parties to the 20 contract. 21 "Department." The Department of General Services of the 22 Commonwealth. 23 "Employee." An individual drawing a salary from a 24 Commonwealth agency, whether elected or not, and any 25 noncompensated individual performing personal services for any 26 Commonwealth agency. 27 "Executive agency." The Governor and the departments, 28 boards, commissions, authorities and other officers and agencies 29 of the Commonwealth government. The term does not include any 30 court or other officer or agency of the unified judicial system, 19830H1291B1524 - 11 -
1 the General Assembly and its officers and agencies or any 2 independent agency. 3 "Grant." The furnishing of assistance by the Commonwealth, 4 Federal Government or any person, whether financial or 5 otherwise, to any person to support a program authorized by law. 6 The term does not include an award whose primary purpose is to 7 procure an end product, whether in the form of supplies, 8 services or construction. A contract resulting from such an 9 award is not a grant but a procurement contract. 10 "Independent agency." Boards, commissions, authorities and 11 other agencies and officers of the Commonwealth government which 12 are not subject to the policy supervision and control of the 13 Governor. The term does not include any court or other officer 14 or agency of the unified judicial system or the General Assembly 15 and its officers and agencies. 16 "Policy office." The Commonwealth Procurement Policy Office. 17 "Procurement." Buying, purchasing, renting, leasing or 18 otherwise acquiring any supplies, services or construction. The 19 term also includes all functions that pertain to the obtaining 20 of any supply, service or construction, including description of 21 requirements, selection and solicitation of sources, preparation 22 and award of contract and all phases of contract administration. 23 "Procurement officer." Any person authorized to enter into 24 and administer contracts and make written determinations with 25 respect to contracts. 26 "Purchasing agency." Any Commonwealth agency authorized by 27 this part to enter into contracts. 28 "Regulation." A regulation as defined in 45 Pa.C.S. § 501 29 (relating to definitions). 30 "Services." The furnishing of labor, time or effort by a 19830H1291B1524 - 12 -
1 contractor, not involving the delivery of a specific end product 2 other than reports which are merely incidental to the required 3 performance. The term does not include employment agreements, 4 collective bargaining agreements, the rendering of professional 5 legal services or agreements with litigation consultants. 6 "Specification." Any description of the physical or 7 functional characteristics or the nature of a supply, service or 8 construction item, including a description of any requirement 9 for inspecting, testing or preparing a supply, service or 10 construction item for delivery. 11 "Supplies." Any property including, but not limited to, 12 equipment, materials, printing, insurance and leases of personal 13 and real property, excluding land or a permanent interest in 14 land. 15 "Using agency." Any Commonwealth agency which utilizes any 16 supplies, services or construction procured under this part. 17 § 104. General principles of law otherwise applicable. 18 Unless displaced by the particular provisions of this part, 19 existing Pennsylvania law, including Title 13 (relating to 20 commercial code), shall supplement the provisions of this part. 21 § 105. Determinations. 22 Written determinations required by this part shall be 23 retained in the appropriate official contract file. 24 § 106. Public access to procurement information. 25 Except for information to which there is a right of 26 nondisclosure under section 533(b) (relating to responsibility 27 of bidders and offerors) or information resulting from an 28 inspection under section 551 (relating to right to inspect 29 plant) or an audit under section 552 (relating to right to audit 30 records), procurement information shall be a public record to 19830H1291B1524 - 13 -
1 the extent provided in the act of June 21, 1957 (P.L.390, 2 No.212), referred to as the Right-to-Know Law, and shall be 3 available to the public as provided in that act. 4 § 107. Reciprocal limitations. 5 No Commonwealth agency may purchase any supplies or specify 6 for or permit to be used in construction any supplies 7 manufactured in a state which prohibits the purchase of supplies 8 or the specification or use in construction of supplies not 9 manufactured in that state. 10 CHAPTER 3 11 PROCUREMENT ORGANIZATION 12 Subchapter 13 A. Organization of Public Procurement 14 B. Commonwealth Procurement Policy Office 15 C. Powers and Duties of Department 16 D. Coordination, Training and Education 17 SUBCHAPTER A 18 ORGANIZATION OF PUBLIC PROCUREMENT 19 Sec. 20 301. Procurement responsibility. 21 § 301. Procurement responsibility. 22 (a) General organization.--Formulation of procurement policy 23 governing the procurement, management, control and disposal of 24 supplies, services and construction for Commonwealth agencies 25 shall be the responsibility of the policy office as provided for 26 in Subchapter B (relating to Commonwealth procurement policy 27 office). The procurement and supervision of the procurement of 28 supplies, services and construction for Commonwealth agencies 29 shall be the responsibility of the department as provided for in 30 Subchapter C (relating to powers and duties of department). 19830H1291B1524 - 14 -
1 (b) Emergency procurement.--For the purpose of making an 2 emergency procurement under section 516 (relating to emergency 3 procurement), any Commonwealth agency may act as a purchasing 4 agency and contract on its own behalf for the supply, service or 5 construction. 6 (c) Contracting for certain services.--For the purpose of 7 procuring the services specified in section 518 (relating to 8 competitive selection procedures for certain services), any 9 Commonwealth agency may act as a purchasing agency and contract 10 on its own behalf for the specified services. The purchasing 11 agency may consult with the department when procuring these 12 services. 13 (d) Exceptions.--The following supplies, services and 14 construction need not be procured through the department, but 15 shall nevertheless be procured by the appropriate purchasing 16 agency, subject to the requirements of this part and regulations 17 promulgated by the policy office: 18 (1) Bridge, highway, dam, airport, railroad or other 19 heavy or specialized construction. 20 (2) Works of art for museum and public display. 21 (3) Published books, maps, periodicals and technical 22 pamphlets. 23 (4) Architect, engineer and land surveying services as 24 defined in section 901 (relating to definitions). 25 SUBCHAPTER B 26 COMMONWEALTH PROCUREMENT POLICY OFFICE 27 Sec. 28 311. Composition and administrative support. 29 312. Powers and duties. 30 313. Procurement regulations. 19830H1291B1524 - 15 -
1 § 311. Composition and administrative support. 2 (a) Membership.--The Commonwealth Procurement Policy Office 3 shall consist of the Secretary of General Services, who shall be 4 chairman, the Secretary of Environmental Resources and the 5 Secretary of Transportation. 6 (b) Quorum.--Two members of the policy office, one of whom 7 must be the chairman, shall constitute a quorum. 8 (c) Executive director.--The department shall provide an 9 executive director who shall be responsible for the 10 administrative work of the policy office. The executive director 11 shall be an employee of the department and may be a deputy 12 secretary. 13 § 312. Powers and duties. 14 Except as otherwise provided in this part, the policy office 15 may promulgate regulations governing the procurement, 16 management, control and disposal of any and all supplies, 17 services and construction to be procured by Commonwealth 18 agencies. The policy office shall consider and decide matters of 19 policy within the provisions of this part. The policy office may 20 audit and monitor the implementation of its regulations and the 21 requirements of this part, but shall not exercise authority over 22 the award or administration of any particular contract or over 23 any dispute, claim or litigation. 24 § 313. Procurement regulations. 25 Regulations shall be promulgated by the policy office as 26 provided in 45 Pa.C.S. Part II (relating to publication and 27 effectiveness of Commonwealth documents). The policy office may 28 not delegate its power to promulgate regulations. No regulation 29 shall change any commitment, right or obligation of any 30 Commonwealth agency or of a contractor under a contract in 19830H1291B1524 - 16 -
1 existence on the effective date of the regulation. 2 SUBCHAPTER C 3 POWERS AND DUTIES OF DEPARTMENT 4 Sec. 5 321. Powers and duties. 6 § 321. Powers and duties. 7 Except as otherwise specifically provided in this part, the 8 department shall have the following powers and duties, in 9 accordance with regulations promulgated by the policy office: 10 (1) Procure or supervise the procurement of all 11 supplies, services and construction needed by Commonwealth 12 agencies. 13 (2) Exercise general supervision and control over all 14 inventories of supplies belonging to Commonwealth agencies. 15 (3) Sell, trade or otherwise dispose of surplus supplies 16 belonging to Commonwealth agencies. 17 (4) Establish and maintain programs for the inspection, 18 testing and acceptance of supplies, services and 19 construction. 20 (5) Establish and maintain a central office where 21 businesses operating in this Commonwealth may obtain 22 information pertaining to the procurement needs of 23 Commonwealth agencies. 24 SUBCHAPTER D 25 COORDINATION, TRAINING AND EDUCATION 26 Sec. 27 331. Collection of data concerning public procurement. 28 332. Advisory groups. 29 § 331. Collection of data concerning public procurement. 30 The department shall cooperate with the Office of the Budget 19830H1291B1524 - 17 -
1 and the Department of the Auditor General in the preparation of 2 statistical data concerning the procurement, usage and 3 disposition of all supplies, services and construction and 4 employ such trained personnel as may be necessary to carry out 5 this function. All using agencies shall furnish reports as the 6 department may require concerning usage, needs and stock on hand 7 and the department may prescribe forms to be used by the using 8 agencies in requisitioning, ordering and reporting supplies, 9 services and construction. 10 § 332. Advisory groups. 11 (a) Procurement Advisory Council.--The policy office may 12 establish a Procurement Advisory Council and allocate funds for 13 it that may be available and the policy office deems 14 appropriate. If created, the council, upon adequate public 15 notice, shall meet at least once a year for the discussion of 16 problems and recommendations for improvement of the procurement 17 process. When requested by the policy office, the council may 18 conduct studies, research and analyses and make reports and 19 recommendations with respect to subjects or matters within the 20 jurisdiction of the policy office. The council may consist of 21 any qualified persons the policy office deems desirable. 22 (b) Other advisory groups.--The department may appoint 23 advisory groups to assist with respect to specifications or 24 procurement in specific areas and with respect to any other 25 matters within the authority of the department. 26 (c) Reimbursement of expenses.--Members of the council and 27 other advisory groups may be reimbursed for expenses incurred in 28 the performance of their duties, subject to expenditure 29 limitations prescribed by the policy office. 30 CHAPTER 5 19830H1291B1524 - 18 -
1 SOURCE SELECTION AND CONTRACT FORMATION 2 Subchapter 3 A. Definitions 4 B. Methods of Source Selection 5 C. Cancellation of Invitations for Bids or Request for 6 Proposals 7 D. Qualifications and Duties 8 E. Types of Contracts 9 F. Inspection of Plant and Audit of Records. 10 G. Determinations and Reports 11 SUBCHAPTER A 12 DEFINITIONS 13 Sec. 14 501. Definitions. 15 § 501. Definitions. 16 The following words and phrases when used in this chapter 17 shall have the meanings given to them in this section unless the 18 context clearly indicates otherwise: 19 "Cost-reimbursement contract." A contract under which a 20 contractor is reimbursed for costs which are allowable and 21 allocable in accordance with the contract terms and the 22 provisions of this part, and a fee, if any. 23 "Established catalogue price." The price included in a 24 catalogue, price list, schedule or other form that: 25 (1) is regularly maintained by a manufacturer or 26 contractor; 27 (2) is either published or otherwise available for 28 inspection by customers; and 29 (3) states prices at which sales are currently or were 30 last made to a significant number of any category of buyers 19830H1291B1524 - 19 -
1 or buyers constituting the general buying public for the 2 supplies or services involved. 3 "Invitation for bids." All documents, whether attached or 4 incorporated by reference, used for soliciting bids. 5 "Life cycle cost." The total cost of the supply in terms of 6 purchase, installation, maintenance, energy, supply and other 7 costs. 8 "Purchase description." The words used in a solicitation to 9 describe the supplies, services or construction to be purchased. 10 The term includes specifications attached to or made part of the 11 solicitation. 12 "Request for proposals." All documents, whether attached or 13 incorporated by reference, used for soliciting proposals. 14 "Responsible bidder or offeror." A person who has the 15 capability in all respects to perform fully the contract 16 requirements and the integrity and reliability which will assure 17 good faith performance. 18 "Responsive bidder." A person who has submitted a bid which 19 conforms in all material respects to the invitation for bids. 20 SUBCHAPTER B 21 METHODS OF SOURCE SELECTION 22 Sec. 23 511. Methods of source selection. 24 512. Competitive sealed bidding. 25 513. Competitive sealed proposals. 26 514. Small purchases. 27 515. Sole source procurement. 28 516. Emergency procurement. 29 517. Multiple awards. 30 518. Competitive selection procedures for certain services. 19830H1291B1524 - 20 -
1 519. Selection procedure for insurance and bonds. 2 520. Handicapped-made supplies and services. 3 § 511. Methods of source selection. 4 Unless otherwise authorized by law, all Commonwealth agency 5 contracts shall be awarded by competitive sealed bidding under 6 section 512 (relating to competitive sealed bidding), except as 7 provided in: 8 Section 513 (relating to competitive sealed proposals). 9 Section 514 (relating to small purchases). 10 Section 515 (relating to sole source procurement). 11 Section 516 (relating to emergency procurement). 12 Section 517 (relating to multiple awards). 13 Section 518 (relating to competitive selection procedures 14 for certain services). 15 Section 519 (relating to selection procedure for 16 insurance and bonds). 17 Section 520 (relating to handicapped-made supplies and 18 services). 19 Section 908 (relating to architect, engineer and land 20 surveying services). 21 § 512. Competitive sealed bidding. 22 (a) Conditions for use.--Contracts shall be awarded by 23 competitive sealed bidding, except as otherwise provided in 24 section 511 (relating to methods of source selection). 25 (b) Invitation for bids.--An invitation for bids shall be 26 issued and shall include a purchase description and all 27 contractual terms and conditions applicable to the procurement. 28 (c) Public notice.--Adequate public notice of the invitation 29 for bids shall be given a reasonable time prior to the date set 30 for the opening of bids, in accordance with regulations 19830H1291B1524 - 21 -
1 promulgated by the policy office. The notice may include 2 publication in a newspaper of general circulation a reasonable 3 time before bid opening. The notice may also include 4 advertisement as provided for in 45 Pa.C.S. § 306 (relating to 5 use of trade publications). 6 (d) Bid opening.--Bids shall be opened publicly in the 7 presence of one or more witnesses at the time and place 8 designated in the invitation for bids. The amount of each bid 9 and any other relevant information as may be specified by 10 regulation, together with the name of each bidder, shall be 11 recorded. The record and each bid shall be open to public 12 inspection. 13 (e) Bid acceptance and evaluation.--Bids shall be 14 unconditionally accepted without alteration or modification, 15 except as authorized in this part. Bids shall be evaluated based 16 on the requirements set forth in the invitation for bids, which 17 may include criteria to determine acceptability such as 18 inspection, testing, quality, workmanship, delivery and 19 suitability for a particular purpose. Those criteria that will 20 affect the bid price and be considered in evaluation for award 21 shall be objectively measurable, such as discounts, 22 transportation costs and total or life cycle costs. The 23 invitation for bids shall set forth the evaluation criteria to 24 be used. No criteria may be used in bid evaluation that are not 25 set forth in the invitation for bids. 26 (f) Modification or withdrawal of bids.-- 27 (1) Bids may be modified or withdrawn by written notice 28 or in person by a bidder or his authorized representative, if 29 his identity is made known and he signs a receipt for the 30 bid, prior to the exact hour and date set for the opening of 19830H1291B1524 - 22 -
1 bids. Withdrawals and modifications of bids received after 2 the exact hour and date specified for the opening of bids 3 shall not be considered. 4 (2) Withdrawal of erroneous bids after bid opening but 5 before award based on bid mistakes shall be permitted by the 6 written determination of the head of the purchasing agency: 7 (i) When the head of the purchasing agency knows or 8 has reason to know that an obvious error had been made. 9 (ii) When the bidder requests relief and presents 10 credible evidence that the reason for the lower bid price 11 was a clerical mistake as opposed to a judgment mistake 12 and was actually due to an unintentional arithmetical 13 error or an unintentional omission of a substantial 14 quantity of work, labor, material or services made 15 directly in the compilation of the bid. 16 (g) Award.--The contract shall be awarded within 60 days of 17 the bid opening by written notice to the lowest responsible and 18 responsive bidder whose bid meets the requirements and criteria 19 set forth in the invitation for bids. Thirty-day extensions of 20 the date for the award may be made by mutual written consent of 21 the head of the purchasing agency and the lowest responsible and 22 responsive bidder. Before the award of the contract, the head of 23 the purchasing agency may return the bid security to all but the 24 lowest and next to lowest responsible and responsive bidders. 25 All unsuccessful bidders shall be given notice in accordance 26 with regulations promulgated by the policy office. 27 (h) Multistep sealed bidding.--When it is considered 28 impractical to prepare initially a purchase description to 29 support an award based on price, an invitation for bids may be 30 issued requesting the submission of unpriced offers, to be 19830H1291B1524 - 23 -
1 followed by an invitation for bids limited to those bidders 2 whose offers have been qualified under the criteria set forth in 3 the first solicitation. 4 § 513. Competitive sealed proposals. 5 (a) Conditions for use.--When, under regulations promulgated 6 by the policy office, the head of a purchasing agency or a 7 designee above the level of the procurement officer determines 8 in writing that the use of competitive sealed bidding is either 9 not practicable or advantageous to the Commonwealth, a contract 10 may be entered into by competitive sealed proposals. The policy 11 office may provide by regulation that it is either not 12 practicable or advantageous to the Commonwealth to procure 13 specified types of supplies, services or construction by 14 competitive sealed bidding. 15 (b) Request for proposals.--Proposals shall be solicited 16 through a request for proposals. 17 (c) Public notice.--Public notice of the request for 18 proposals shall be given in the same manner as provided in 19 section 512(c) (relating to competitive sealed bidding). 20 (d) Receipt of proposals.--Offerors shall submit their 21 proposal in two separate sealed envelopes. One envelope shall 22 contain a technical description of the supply or construction 23 which is being offered in response to the request for proposals. 24 The other envelope shall contain the price. 25 (e) Evaluation factors.--The request for proposals shall 26 state the relative importance of technical, price and other 27 evaluation factors. 28 (f) Discussion with responsible offerors and revision of 29 proposals.--As provided in the request for proposals and under 30 regulations promulgated by the policy office, discussions may be 19830H1291B1524 - 24 -
1 conducted with responsible offerors who submit proposals 2 determined to be reasonably susceptible of being selected for 3 award for the purpose of clarification to assure full 4 understanding of and responsiveness to the solicitation 5 requirements. Offerors shall be accorded fair and equal 6 treatment with respect to any opportunity for discussion and 7 revision of proposals. Revisions may be permitted after 8 submissions and prior to award for the purpose of obtaining best 9 and final offers. In conducting discussions, there shall be no 10 disclosure of any information derived from proposals submitted 11 by competing offerors. 12 (g) Award.--After the date and time fixed for submission of 13 a proposal, a committee of employees with technical, managerial 14 or other appropriate expertise and experience in negotiation and 15 costing, previously selected by the purchasing agency, shall 16 proceed to open all envelopes containing the technical submittal 17 of the supply or construction which is being offered in response 18 to the request for proposals. The committee shall then review 19 the description and assign a point value to it using the 20 evaluation factors developed prior to opening the envelopes. The 21 committee shall then open all envelopes containing the prices 22 and assign to them a point value. The purchasing agency shall 23 then enter into a contract with the responsible offeror whose 24 proposal is determined in writing by the committee to be the 25 most advantageous to the Commonwealth based on the total point 26 value obtained from the technical and price evaluation factors. 27 No other factors or criteria shall be used in the evaluation. 28 § 514. Small purchases. 29 If the procurement is not the subject of a requirements 30 contract between the purchasing agency and a contractor, the 19830H1291B1524 - 25 -
1 department may authorize in writing any Commonwealth agency to 2 make purchases without formal bid procedures in the field, not 3 exceeding the amount established by regulations promulgated by 4 the policy office. Procurement requirements shall not be 5 artificially divided so as to constitute a small purchase under 6 this section. Records of all small purchases shall be 7 transmitted to the department. 8 § 515. Sole source procurement. 9 A contract may be awarded for a supply, service or 10 construction item without competition when, under regulations 11 promulgated by the policy office, the head of a purchasing 12 agency or a designee above the level of the procurement officer 13 determines in writing that there is only one source for the 14 required supply, service or construction item. If the sole 15 source procurement is of a supply, service or construction item 16 under section 301(c) or (d) (relating to procurement 17 responsibility), the purchasing agency shall transmit a record 18 of the procurement to the department. 19 § 516. Emergency procurement. 20 The head of a purchasing agency may make or authorize others 21 to make an emergency procurement when there exists a threat to 22 public health, welfare or safety or the urgency of the need does 23 not permit the delay involved in using more formal competitive 24 methods. Whenever practical, at least two bids shall be 25 solicited. A written determination of the basis for the 26 emergency and for the selection of the particular contractor 27 shall be included in the contract file. Records of all emergency 28 procurements shall be transmitted to the department. 29 § 517. Multiple awards. 30 (a) Conditions for use.--The department under regulations 19830H1291B1524 - 26 -
1 promulgated by the policy office may procure supplies on a 2 multiple award basis if one or more of the following criteria is 3 applicable: 4 (1) It is administratively or economically impractical 5 to develop or modify specifications for a myriad of related 6 supplies because of rapid technological changes. 7 (2) The subjective nature in the use of certain supplies 8 and the fact that recognizing this need creates a more 9 efficient use of the item. 10 (3) It is administratively or economically impractical 11 to develop or modify specifications because of the 12 heterogeneous nature of the product lines. 13 (4) There is a need for compatibility with existing 14 systems. 15 (b) Invitation for bids.--Invitations to bid shall be issued 16 for the supplies to be purchased. 17 (c) Public notice.--Public notice of the invitation for bids 18 shall be given in the same manner as provided in section 512(c) 19 (relating to competitive sealed bidding). 20 (d) Bid opening.--Bids shall be opened in the same manner as 21 provided in section 512(d). 22 (e) Award.--Bids shall be accepted and awards made to the 23 lowest responsible and responsive bidder for supplies of each 24 designated manufacturer. The contract shall cover the periodic 25 requirements of Commonwealth agencies for supplies of each 26 particular manufacturer. The number of supplies purchased from a 27 particular contractor shall be determined by the actual 28 requirements of the Commonwealth agencies as defined by the 29 functional needs and space limitations of the using agency and a 30 comparison with prices of corresponding supplies offered by 19830H1291B1524 - 27 -
1 other prospective contractors. 2 (f) Issuance of order.--When a Commonwealth agency has a 3 need for a particular supply which is the subject of a contract, 4 the Commonwealth agency shall issue an order to the vendor 5 offering the particular supply which the Commonwealth agency 6 desires. 7 § 518. Competitive selection procedures for certain services. 8 (a) Conditions for use.--The services of accountants, 9 clergy, physicians and dentists shall be procured in accordance 10 with this section, except as authorized under section 514 11 (relating to small purchases), 515 (relating to sole source 12 procurement) or 516 (relating to emergency procurement). 13 (b) Statement of qualifications.--Persons engaged in 14 providing the types of services specified in subsection (a) may 15 submit statements of qualifications and expressions of interest 16 in providing these services. The procurement officer may specify 17 a uniform format for statements of qualifications. Persons may 18 amend these statements at any time by filing a new statement. 19 (c) Request for proposals.--Adequate notice of the need for 20 the services specified in subsection (a) shall be given by the 21 purchasing agency through a request for proposals. The request 22 for proposals shall describe the services required, list the 23 type of information and data required of each offeror and state 24 the relative importance of particular qualifications. 25 (d) Discussions.--The head of a purchasing agency may 26 conduct discussions with any offeror who has submitted a 27 proposal to determine the offeror's qualifications for further 28 consideration. Discussions shall not disclose any information 29 derived from proposals submitted by other offerors. 30 (e) Award.--Award shall be made to the offeror determined in 19830H1291B1524 - 28 -
1 writing by the head of the purchasing agency to be best 2 qualified based on the evaluation factors set forth in the 3 request for proposals. Fair and reasonable compensation shall be 4 determined through negotiation. If compensation cannot be agreed 5 upon with the best qualified offeror, then negotiations will be 6 formally terminated with the selected offeror. If proposals were 7 submitted by one or more other offerors determined to be 8 qualified, negotiations may be conducted with the other offeror 9 or offerors in the order of their respective qualification 10 ranking. The contract may be awarded to the offeror then ranked 11 as best qualified if the amount of compensation is determined to 12 be fair and reasonable. 13 § 519. Selection procedure for insurance and bonds. 14 (a) Conditions for use.--Insurance and bonds shall be 15 procured in accordance with this section, except as authorized 16 under section 515 (relating to sole source procurement) or 516 17 (relating to emergency procurement). 18 (b) Statement of qualifications.--Insurance and bond 19 carriers may submit statements of qualifications and expressions 20 of interest in providing insurance or bonds. The department may 21 specify a uniform format for statements of qualifications. 22 (c) Request for proposals.--Adequate notice of the need for 23 insurance or bond coverage shall be given through a request for 24 proposals. The request for proposals shall describe the type of 25 insurance or bond coverage required and list the type of 26 information and data required of each offeror. 27 (d) Receipt of proposals.--Offerors shall submit their 28 proposals prior to the time and date specified. 29 (e) Discussions with responsible offerors and revision to 30 proposals.--Discussions and negotiations may be conducted with 19830H1291B1524 - 29 -
1 responsible offerors who submit proposals determined to be 2 reasonably susceptible of being selected for award. Offerors 3 shall be accorded fair and equal treatment with respect to any 4 opportunity for discussion, negotiation and revision of 5 proposals. Revisions may be permitted after submissions and 6 prior to award for the purpose of obtaining best and final 7 offers. 8 (f) Award.--Award shall be made to the offeror whose 9 proposal is determined in writing by the department to be the 10 most advantageous to the Commonwealth based on criteria 11 determined by the department, including the coverage offered and 12 the cost of the premium. 13 § 520. Handicapped-made supplies and services. 14 (a) General rule.--Handicapped-made supplies and services 15 shall be procured by a purchasing agency in accordance with this 16 section. 17 (b) Fair market price.--The department shall determine the 18 fair market price of any handicapped-made supply or service 19 which has been offered for sale to any Commonwealth agency by an 20 agency for the handicapped. The department shall also revise the 21 prices in accordance with changing market conditions and 22 promulgate regulations regarding specifications, time of 23 delivery and other relevant matters. 24 (c) Distribution.--At the request of the department, the 25 Department of Public Welfare or a nonprofit agency with the 26 approval of the Department of Public Welfare shall facilitate 27 the distribution of orders for supplies and services among 28 agencies for the handicapped. 29 (d) Procurement of handicapped-made supplies and services.-- 30 Except as provided in subsection (e), all handicapped-made 19830H1291B1524 - 30 -
1 supplies or services shall be procured in accordance with 2 regulations promulgated by the policy office and in accordance 3 with specifications under Chapter 7 (relating to specifications) 4 from any agency for the handicapped, whenever the supplies and 5 services are available at a price determined to be the fair 6 market price. The head of a purchasing agency shall annually 7 discuss its needs for supplies or services with agencies for the 8 handicapped. 9 (e) Procurement from Commonwealth agency.--If any 10 handicapped-made supply or service offered for sale is available 11 for procurement from any Commonwealth agency and this part or 12 any other statute requires the procurement of the supply or 13 service from the Commonwealth agency, then the procurement of 14 the supply or service shall be made in accordance with the other 15 provisions. 16 (f) Definitions.--As used in this section the following 17 words and phrases shall have the meanings given to them in this 18 subsection: 19 "Agency for the handicapped." Any charitable nonprofit 20 agency incorporated under the laws of this Commonwealth and 21 approved by the department through which handicapped persons 22 manufacture supplies and provide services in this Commonwealth. 23 "Blind." A condition in which central visual acuity does not 24 exceed 20/200 in the better eye with correcting lenses or in 25 which the widest diameter of the visual field subtends an angle 26 no greater than 20 degrees. 27 "Handicapped person." A person who is blind, mentally 28 retarded or physically handicapped. 29 "Handicapped-made supply or service." Any supply 30 manufactured or service rendered in this Commonwealth by a 19830H1291B1524 - 31 -
1 handicapped person. The term does not include any service the 2 practice of which is licensed under the laws of this 3 Commonwealth. 4 "Mentally retarded." Subaverage general intellectual 5 functioning which originates during the developmental period and 6 is associated with impairment of maturation, learning or social 7 adjustment. 8 "Physically handicapped." A limitation of most activities 9 and functioning by virtue of a severe impairment of the various 10 bodily systems which cannot be eliminated, modified or 11 substantially reduced by the usual rehabilitation services and 12 which precludes competitive employment. 13 SUBCHAPTER C 14 CANCELLATION OF INVITATIONS FOR BIDS OR 15 REQUESTS FOR PROPOSALS 16 Sec. 17 521. Cancellation of invitations for bids or requests for 18 proposals. 19 § 521. Cancellation of invitations for bids or requests for 20 proposals. 21 An invitation for bids, a request for proposals or other 22 solicitation may be cancelled, or any or all bids or proposals 23 may be rejected in whole or in part as may be specified in the 24 solicitation, when it is in the best interests of the 25 Commonwealth in accordance with regulations promulgated by the 26 policy office. The reasons for the cancellation or rejection 27 shall be made part of the contract file. 28 SUBCHAPTER D 29 QUALIFICATIONS AND DUTIES 30 Sec. 19830H1291B1524 - 32 -
1 531. Debarment or suspension. 2 532. Prequalification of bidders and offerors. 3 533. Responsibility of bidders and offerors. 4 534. Bid security and performance bonds. 5 535. Cost or pricing data. 6 § 531. Debarment or suspension. 7 (a) Authority.--After reasonable notice to the person 8 involved and reasonable opportunity for that person to be heard, 9 the head of a purchasing agency, after consultation with the 10 head of the using agency, shall have authority to debar a person 11 for cause from consideration for award of contracts for a period 12 of not more than three years or to suspend a person from 13 consideration for award of contracts if there is probable cause 14 for debarment for a period not exceeding three months. 15 (b) Causes for debarment or suspension.--The causes for 16 debarment or suspension include: 17 (1) Conviction, including a plea of guilty or nolo 18 contendere, for commission of a criminal offense as an 19 incident to obtaining or attempting to obtain a public or 20 private contract or subcontract or in the performance of the 21 contract or subcontract. 22 (2) Conviction, including a plea of guilty or nolo 23 contendere, under state or Federal statutes of embezzlement, 24 theft, forgery, bribery, falsification or destruction of 25 records, receiving stolen property or any other offense 26 indicating a lack of business integrity or business honesty 27 which currently, seriously and directly affects 28 responsibility as a contractor. 29 (3) Conviction, including a plea of guilty or nolo 30 contendere, under state or Federal antitrust statutes arising 19830H1291B1524 - 33 -
1 out of the submission of bids or proposals. 2 (4) Violation of contract provisions, as set forth 3 below, of a character which is regarded by the head of a 4 purchasing agency to be so serious as to justify debarment 5 action: 6 (i) deliberate failure without good cause to perform 7 in accordance with the specifications or within the time 8 limit provided in the contract; or 9 (ii) a recent record of failure to perform or of 10 unsatisfactory performance in accordance with the terms 11 of one or more contracts. Failure to perform or 12 unsatisfactory performance caused by acts beyond the 13 control of the contractor shall not be considered to be a 14 basis for debarment. 15 (5) Any other cause the head of a purchasing agency 16 determines to be so serious and compelling as to affect 17 responsibility as a contractor, including debarment by 18 another governmental entity for any cause listed in 19 regulations of the policy office. 20 (6) For violation of the ethical standards set forth in 21 Chapter 23 (relating to ethics in public contracting) or the 22 act of July 19, 1957 (P.L.1017, No.451), known as the State 23 Adverse Interest Act. 24 (c) Decision.--The head of a purchasing agency shall issue a 25 written decision to debar or suspend. The decision shall: 26 (1) State the reasons for the action taken. 27 (2) Inform the debarred or suspended person involved of 28 his rights to administrative and judicial review as provided 29 in Chapter 17 (relating to legal and contractual remedies). 30 (d) Notice of decision.--A copy of the decision under 19830H1291B1524 - 34 -
1 subsection (c) shall be delivered by registered mail to the 2 debarred or suspended person and any other party intervening. 3 (e) Finality of decision and appeal.--A decision under 4 subsection (c) shall be final and conclusive unless the debarred 5 or suspended person appeals to the Board of Claims within 30 6 days of receipt of the decision. 7 § 532. Prequalification of bidders and offerors. 8 Prospective bidders and offerors may be prequalified for 9 particular types of supplies, services and construction. 10 Solicitation mailing lists of potential contractors shall 11 include, but shall not be limited to, prequalified bidders and 12 offerors. 13 § 533. Responsibility of bidders and offerors. 14 (a) Determination of nonresponsibility.--A written 15 determination of nonresponsibility of a bidder or offeror shall 16 be made in accordance with regulations promulgated by the policy 17 office. The unreasonable failure of a bidder or offeror to 18 promptly supply information in connection with an inquiry with 19 respect to responsibility may be grounds for a determination of 20 nonresponsibility with respect to that bidder or offeror. 21 (b) Right of nondisclosure.--Information furnished by a 22 bidder or offeror pursuant to this section shall not be 23 disclosed outside of the purchasing agency without prior written 24 consent by the bidder or offeror, except as otherwise provided 25 in section 563 (relating to retention of procurement records). 26 § 534. Bid security and performance bonds. 27 (a) Contract for supplies.-- 28 (1) In the case of competitive sealed bidding for a 29 contract for supplies, bidders may be required by the head of 30 a purchasing agency pursuant to regulations promulgated by 19830H1291B1524 - 35 -
1 the policy office to provide bid security. Bid security shall 2 be by certified or bank check or a bond provided by a surety 3 company authorized to do business in this Commonwealth or the 4 equivalent in cash. Bid security shall be at least in the 5 minimum amount or percentage of the amount of the bid as 6 shall be specified in the advertisement. 7 (2) When the invitation for bids requires security, 8 noncompliance by the bidder requires that the bid be rejected 9 unless, pursuant to policy office regulations, it is 10 determined that the bid fails to comply with the security 11 requirements in a nonsubstantial manner. 12 (3) After the bids are opened, they shall be irrevocable 13 for the period specified in the invitation for bids except as 14 provided in section 512(f) (relating to competitive sealed 15 bidding). If a bidder is permitted to withdraw his bid before 16 award, no action shall be had against the bidder or the bid 17 security. 18 (4) A contractor may be required by the head of a 19 purchasing agency under regulations promulgated by the policy 20 office to provide a performance bond executed by a surety 21 company authorized to do business in this Commonwealth. In 22 lieu of a bond, a contractor may provide other security as 23 permitted by regulations promulgated by the policy office. 24 The performance bond shall be in an amount determined by the 25 head of the purchasing agency and it shall be conditioned 26 upon the faithful performance of the contract. 27 (b) Contract for construction.--Bid security and performance 28 bonds as required for contracts for construction are provided 29 for in sections 903 (relating to bid security) and 904 (relating 30 to contract performance and payment bonds). 19830H1291B1524 - 36 -
1 § 535. Cost or pricing data. 2 (a) Submission by contractor.--A contractor shall, except as 3 provided in subsection (c), submit cost or pricing data and 4 shall certify that, to the best of his knowledge and belief, the 5 cost or pricing data submitted was accurate, complete and 6 current as of a mutually determined specified date prior to the 7 date of: 8 (1) the pricing of any contract awarded under section 9 513 (relating to competitive sealed proposals) or 515 10 (relating to sole source procurement) where the total 11 contract price is expected to exceed an amount established by 12 the policy office; or 13 (2) the pricing of any change order or contract 14 modification which is expected to exceed an amount 15 established by policy office regulations. 16 (b) Price adjustment.--Any contract, change order or 17 contract modification under which a certificate is required 18 shall contain a provision that the price to the Commonwealth 19 agency, including profit or fee, shall be adjusted to exclude 20 any significant sums by which the Commonwealth agency finds that 21 the price was increased because the cost or pricing data 22 furnished by the contractor was inaccurate, incomplete or not 23 current as of the date agreed upon between the parties. 24 (c) Cost or pricing data not required.--The requirements of 25 this section need not be applied to contracts under any of the 26 following circumstances: 27 (1) The contract price is based on adequate price 28 competition. 29 (2) The contract price is based on established catalogue 30 prices or market prices. 19830H1291B1524 - 37 -
1 (3) Contract prices are set by statute or regulation. 2 (4) It is determined in writing in accordance with 3 regulations promulgated by the policy office that the 4 requirements of this section may be waived and the reasons 5 for the waivers are stated in writing. 6 SUBCHAPTER E 7 TYPES OF CONTRACTS 8 Sec. 9 541. Restrictions on contracts. 10 542. Approval of accounting system. 11 543. Multiterm contracts. 12 § 541. Restrictions on contracts. 13 The use of a cost-plus-a-percentage-of-cost contract is 14 prohibited. A cost-reimbursement contract may be used only when 15 a determination is made in writing that the contract is likely 16 to be less costly to the Commonwealth than any other type or 17 that it is impracticable to obtain the supplies, services or 18 construction required except under a cost-reimbursement 19 contract. 20 § 542. Approval of accounting system. 21 Except with respect to firm fixed-price contracts, no 22 contract type shall be used unless it has been determined in 23 writing by the head of a purchasing agency that: 24 (1) the proposed contractor's accounting system will 25 permit timely development of all necessary cost data in the 26 form required by the specific contract type contemplated; and 27 (2) the proposed contractor's accounting system is 28 adequate to allocate costs in accordance with generally 29 accepted accounting principles. 30 § 543. Multiterm contracts. 19830H1291B1524 - 38 -
1 (a) Specified period.--A contract for supplies or services 2 may be entered into for any period of time deemed to be in the 3 best interests of the Commonwealth. The term of the contract and 4 conditions of renewal or extension, if any, shall be included in 5 the solicitation and funds shall be available for the first 6 fiscal period at the time of contracting. Payment and 7 performance obligations for succeeding fiscal periods shall be 8 subject to the availability and appropriation of funds. 9 (b) Determination prior to use.--Before using a multiterm 10 contract, it shall be determined in writing that: 11 (1) Estimated requirements cover the period of the 12 contract and are reasonably firm and continuing. 13 (2) The contract will serve the best interests of the 14 Commonwealth by encouraging effective competition or 15 otherwise promoting economy in Commonwealth agency 16 procurement. 17 (c) Cancellation for unavailability of funds in succeeding 18 fiscal periods.--When funds are not appropriated or otherwise 19 made available to support continuation of performance in a 20 subsequent fiscal period, the contract shall be cancelled and 21 the contractor shall be reimbursed for the reasonable value of 22 any nonrecurring costs incurred but not amortized in the price 23 of the supplies or services delivered under the contract. The 24 cost of cancellation may be paid from any appropriations 25 available for that purpose. 26 SUBCHAPTER F 27 INSPECTION OF PLANT AND AUDIT OF RECORDS 28 Sec. 29 551. Right to inspect plant. 30 552. Right to audit records. 19830H1291B1524 - 39 -
1 § 551. Right to inspect plant. 2 The purchasing agency may, at reasonable times, inspect the 3 part of the plant or place of business of a contractor or any 4 subcontractor which is related to the performance of any 5 contract awarded or to be awarded by the purchasing agency. 6 § 552. Right to audit records. 7 (a) Audit of cost or pricing data.--The purchasing agency 8 may, at reasonable times and places, audit the books and records 9 of any person who has submitted cost or pricing data under 10 section 535 (relating to cost or pricing data) to the extent 11 that the books and records relate to the cost or pricing data. 12 Any person who receives a contract, change order or contract 13 modification for which cost or pricing data is required shall 14 maintain the books and records that relate to the cost or 15 pricing data for three years from the date of final payment 16 under the contract unless a shorter period is otherwise 17 authorized in writing. 18 (b) Contract audit.--The purchasing agency may audit the 19 books and records of a contractor or any subcontractor under any 20 negotiated contract or subcontract other than a firm fixed-price 21 contract to the extent that the books and records relate to the 22 performance of the contract or subcontract. The books and 23 records shall be maintained by the contractor for a period of 24 three years from the date of final payment under the prime 25 contract and by the subcontractor for a period of three years 26 from the date of final payment under the prime contract unless a 27 shorter period is otherwise authorized in writing. 28 SUBCHAPTER G 29 DETERMINATIONS AND REPORTS 30 Sec. 19830H1291B1524 - 40 -
1 561. Finality of determinations. 2 562. Anti-competitive practices. 3 563. Retention of procurement records. 4 564. Record of certain actions. 5 § 561. Finality of determinations. 6 The determinations required by the following sections are 7 final and conclusive unless they are clearly erroneous, 8 arbitrary, capricious or contrary to law: 9 Section 512(f) (relating to competitive sealed bidding). 10 Section 513(a) and (g) (relating to competitive sealed 11 proposals). 12 Section 515 (relating to sole source procurement). 13 Section 516 (relating to emergency procurement). 14 Section 518(e) (relating to competitive selection 15 procedures for certain services). 16 Section 519(f) (relating to selection procedure for 17 insurance and bonds). 18 Section 533(a) (relating to responsibility of bidders and 19 offerors). 20 Section 535(c) (relating to cost or pricing data). 21 Section 541 (relating to restrictions on contracts). 22 Section 542 (relating to approval of accounting system). 23 Section 543(b) (relating to multiterm contracts). 24 § 562. Anti-competitive practices. 25 Collusion among bidders is unlawful. Every contract, 26 combination or conspiracy which unreasonably restrains trade 27 among bidders or offerors is unlawful. Contracts so arrived at 28 may be declared void at the option of the Commonwealth. In 29 addition to remedies available to the Commonwealth in the 30 Federal courts, there shall be the same remedies in the courts 19830H1291B1524 - 41 -
1 of this Commonwealth. When any person has reason to believe 2 collusion or other anti-competitive practices have occurred 3 among any bidders or offerors, a notice of the relevant facts 4 shall be transmitted to the Attorney General who shall 5 investigate the reports. 6 § 563. Retention of procurement records. 7 All procurement records shall be retained for a minimum of 8 three years and disposed of in accordance with records retention 9 guidelines and schedules approved by the General Counsel. All 10 retained documents shall be made available to the General 11 Counsel or Attorney General upon request. 12 § 564. Record of certain actions. 13 (a) Contents of record.--The department shall maintain a 14 record listing all contracts made under sections 514 (relating 15 to small purchases), 515 (relating to sole source procurement) 16 and 516 (relating to emergency procurement) for a minimum of 17 three years from the date of final payment under the contract. 18 The record shall contain: 19 (1) Each contractor's name. 20 (2) The amount and type of each contract. 21 (3) A listing of the supplies, services or construction 22 procured under each contract. 23 (b) Submission to General Assembly.--A copy of the record 24 required by subsection (a) shall be submitted to the General 25 Assembly on an annual basis. 26 CHAPTER 7 27 SPECIFICATIONS 28 Sec. 29 701. Purpose and scope. 30 702. Duties of policy office. 19830H1291B1524 - 42 -
1 703. Duties of department. 2 704. Exempted items. 3 705. Relationship with using agencies. 4 706. Wage specifications. 5 § 701. Purpose and scope. 6 All specifications shall seek to promote overall economy for 7 the purpose intended and encourage competition in satisfying 8 Commonwealth agency needs and shall not be unduly restrictive. 9 The requirements of this chapter regarding the purposes and 10 nonrestrictiveness of specifications shall apply to all 11 specifications including, but not limited to, those prepared by 12 architects, engineers, designers and drafters for public 13 contracts. 14 § 702. Duties of policy office. 15 The policy office shall promulgate regulations governing the 16 preparation, maintenance and content of specifications for 17 supplies, services and construction required by Commonwealth 18 agencies. 19 § 703. Duties of department. 20 The department shall prepare, issue, revise, maintain and 21 monitor the use of specifications for supplies, services and 22 construction required by Commonwealth agencies. 23 § 704. Exempted items. 24 Specifications for supplies, services or construction items 25 procured under sections 516 (relating to emergency procurement) 26 and 518 (relating to competitive selection procedures for 27 certain services) or exempted under section 301(d) (relating to 28 procurement responsibility) may be prepared by a purchasing 29 agency in accordance with the provisions of this chapter. 30 § 705. Relationship with using agencies. 19830H1291B1524 - 43 -
1 The department shall obtain expert advice and assistance from 2 personnel of using agencies in the development of specifications 3 and may delegate in writing to a using agency the authority to 4 prepare and use its own specifications. 5 § 706. Wage specifications. 6 (a) Prevailing wages.--Specifications prepared under this 7 chapter for construction contracts shall be consistent with the 8 requirements of the act of August 15, 1961 (P.L.987, No.442), 9 known as the Pennsylvania Prevailing Wage Act. 10 (b) Minimum wages.--Specifications prepared under this 11 chapter for construction contracts shall contain the minimum 12 wages which may be paid by the contractor or subcontractor for 13 work performed by laborers and mechanics. The specifications 14 shall require that the laborers and mechanics be paid at least 15 the minimum wages contained in the specifications and that the 16 laborers and mechanics shall not be required to refund, directly 17 or indirectly, any part of those wages. The specifications shall 18 require that the contractor or subcontractor certify that he is 19 not receiving or requiring, or will not receive or require, 20 directly or indirectly, any refund of the specified minimum 21 wages. 22 CHAPTER 9 23 PROCUREMENT OF CONSTRUCTION, ARCHITECT, ENGINEER 24 AND LAND SURVEYING SERVICES 25 Sec. 26 901. Definitions. 27 902. Selection of method of construction contracting. 28 903. Bid security. 29 904. Contract performance and payment bonds. 30 905. Bond forms and copies. 19830H1291B1524 - 44 -
1 906. Contract clauses and their administration. 2 907. Fiscal responsibility. 3 908. Architect, engineer and land surveying services. 4 § 901. Definitions. 5 The following words and phrases when used in this chapter 6 shall have the meanings given to them in this section unless the 7 context clearly indicates otherwise: 8 "Architect, engineer and land surveying services." Those 9 professional services within the scope of the practice of 10 architecture, professional engineering or land surveying as 11 defined by the laws of this Commonwealth. 12 § 902. Selection of method of construction contracting. 13 (a) General rule.--Construction contracts shall be awarded 14 by competitive sealed bidding under section 512 (relating to 15 competitive sealed bidding) or, when competitive sealed bidding 16 is either not practicable or advantageous to the Commonwealth, 17 by competitive sealed proposals under section 513 (relating to 18 competitive sealed proposals). 19 (b) Separate contracts for certain construction items.--In 20 the case of a public building, if the entire cost of the 21 construction exceeds $4,000, the architect, engineer, designer 22 or drafter of specifications under Chapter 7 (relating to 23 specifications) shall prepare separate specifications for the 24 following construction items: 25 (1) Plumbing. 26 (2) Heating, ventilating and air conditioning. 27 (3) Electrical work. 28 The purchasing agency shall invite bids or request proposals and 29 award a contract for each separate construction item. 30 § 903. Bid security. 19830H1291B1524 - 45 -
1 (a) Requirement for bid security.--Bid security is required 2 for all competitive sealed bidding for construction contracts 3 when the price is estimated by the procurement officer to exceed 4 $5,000. Bid security shall be by certified or bank check or a 5 bond provided by a surety company authorized to do business in 6 this Commonwealth or the equivalent in cash. This subsection 7 does not prevent the requirement of bid security for 8 construction contracts under $5,000. 9 (b) Amount of bid security.--Bid security shall be at least 10 in the minimum amount or percentage of the amount of the bid as 11 shall be specified in the advertisement. 12 (c) Rejection of bids.--When the invitation for bids 13 requires security, noncompliance requires that the bid be 14 rejected unless, pursuant to policy office regulations, it is 15 determined that the bid fails to comply with the security 16 requirements in a nonsubstantial manner. 17 (d) Withdrawal of bids.--After the bids are opened, they 18 shall be irrevocable for the period specified in the invitation 19 for bids except as provided in section 512(f) (relating to 20 competitive sealed bidding). If a bidder is permitted to 21 withdraw his bid before award, no action shall be had against 22 the bidder or the bid security. 23 § 904. Contract performance and payment bonds. 24 (a) When required and amounts.--When a construction contract 25 is awarded in excess of $5,000, the following bonds or security 26 shall be delivered to the purchasing agency and shall be binding 27 on the parties upon the execution of the contract: 28 (1) A performance bond, executed by a surety company 29 authorized to do business in this Commonwealth, in an amount 30 equal to 100% of the price specified in the contract and 19830H1291B1524 - 46 -
1 conditioned upon the faithful performance of the contract in 2 accordance with the plans, specifications and conditions of 3 the contract. 4 (2) A payment bond, executed by a surety company 5 authorized to do business in this Commonwealth, in an amount 6 equal to 100% of the price specified in the contract and 7 conditioned upon the prompt payment for all materials 8 furnished or labor supplied or performed in the prosecution 9 of the work. Labor or materials includes public utility 10 services and reasonable rentals of equipment for the periods 11 when the equipment is actually used at the site. 12 (b) Protection.--A performance bond shall be solely for the 13 protection of the purchasing agency which awarded the contract. 14 A payment bond shall be solely for the protection of claimants 15 supplying labor or materials to the prime contractor to whom the 16 contract was awarded or to any of his subcontractors in the 17 prosecution of the work provided for in the contract, whether or 18 not the labor or materials constitute a component part of the 19 construction. 20 (c) Reduction of bond amounts.--The policy office may 21 promulgate regulations that authorize the head of a purchasing 22 agency to reduce the amount of performance and payment bonds to 23 50% of the contract price for each bond. 24 (d) Authority to require additional bonds.--Nothing in this 25 section shall be construed to limit the authority of the 26 Commonwealth agency to require a performance bond or other 27 security in addition to those bonds or in circumstances other 28 than specified in subsection (a). 29 (e) Actions on payment bonds.-- 30 (1) Subject to paragraph (2), any claimant who has 19830H1291B1524 - 47 -
1 performed labor or furnished material in the prosecution of 2 the work provided for in any contract for which a payment 3 bond has been given under subsection (a) and who has not been 4 paid in full before the expiration of 90 days after the day 5 on which the claimant performed the last of the labor or 6 furnished the last of the materials for which he claims 7 payments may bring an action on the payment bond in his own 8 name, in assumpsit, to recover any amount due him for the 9 labor or material and may prosecute the action to final 10 judgment and have execution on the judgment. 11 (2) Any claimant who has a direct contractual 12 relationship with any subcontractor of the prime contractor 13 who gave the payment bond but has no contractual 14 relationship, express or implied, with the prime contractor 15 may bring an action on the payment bond only if he has given 16 written notice to the contractor within 90 days from the date 17 on which the claimant performed the last of the labor or 18 furnished the last of the materials for which he claims 19 payment stating with substantial accuracy the amount and the 20 name of the person for whom the work was performed or to whom 21 the material was furnished. 22 (3) Notice shall be served by registered mail in an 23 envelope addressed to the contractor at any place where his 24 office is regularly maintained for the transaction of 25 business, or served in any manner in which legal process may 26 be served in the manner provided by law for the service of a 27 summons except that the service need not be made by a public 28 officer. 29 § 905. Bond forms and copies. 30 (a) Bond forms.--The policy office shall promulgate by 19830H1291B1524 - 48 -
1 regulation the form of the bonds required by this chapter. 2 (b) Certified copies of bonds.--The purchasing agency shall 3 furnish a certified copy of any payment bond and the contract 4 for which the bond was given to any person who makes an 5 application for the copy and who submits an affidavit stating 6 that the applicant: 7 (1) has furnished material or performed labor for the 8 completion of the work provided for in the contract and that 9 he has not been fully paid for the labor or material; 10 (2) is a defendant in an action brought on a payment 11 bond; or 12 (3) is surety in a payment bond on which an action has 13 been brought. 14 (c) Fee for certified copies.--Each applicant shall pay for 15 each certified copy of any payment bond a fee fixed by the 16 purchasing agency to cover the actual cost of the preparation of 17 the copy. 18 (d) Evidence.--A certified copy of any payment bond and of 19 the contract for which the bond was given constitutes prima 20 facie evidence of the contents, execution and delivery of the 21 original of the bond and contract. 22 § 906. Contract clauses and their administration. 23 (a) Contract clauses.--The policy office may promulgate 24 regulations permitting or requiring the inclusion in 25 Commonwealth agency construction contracts of clauses providing 26 for, but not limited to, adjustments in prices, time of 27 performance or other contract provisions, as appropriate, and 28 covering the following subjects: 29 (1) The unilateral right of the purchasing agency to 30 order in writing changes in the work within the scope of the 19830H1291B1524 - 49 -
1 contract and changes in the time of performance of the 2 contract that do not alter the scope of the contract work. 3 (2) Variations occurring between estimated and actual 4 quantities of work. 5 (3) Suspension of work ordered by the purchasing agency. 6 (4) Site conditions differing from those indicated in 7 the contract or ordinarily encountered except when the 8 contract is negotiated, the contractor provides the site or 9 design or the parties have otherwise agreed with respect to 10 the risk of differing site conditions. 11 (b) Price adjustments.-- 12 (1) Adjustments in price pursuant to clauses promulgated 13 under subsection (a) shall be computed in one or more of the 14 following ways: 15 (i) By agreement on a fixed price adjustment before 16 commencement of the pertinent performance or as soon 17 after commencement as practicable. 18 (ii) By unit prices specified in the contract or 19 subsequently agreed upon. 20 (iii) By the costs attributable to the events or 21 situations under the clauses with adjustment of profit or 22 fee, all as specified in the contract or subsequently 23 agreed upon. 24 (iv) In any other manner as the contracting parties 25 may mutually agree. 26 (v) In the absence of agreement by the parties, by a 27 unilateral determination by the purchasing agency of the 28 costs attributable to the events or situations under the 29 clauses with adjustment of profit or fee, all as computed 30 by the purchasing agency in accordance with applicable 19830H1291B1524 - 50 -
1 sections of the regulations issued under Chapter 13 2 (relating to cost principles) and subject to the 3 provisions of Chapter 17 (relating to legal and 4 contractual remedies). 5 (2) A contractor shall be required to submit cost or 6 pricing data if any adjustment in contract price is subject 7 to the provisions of section 535 (relating to cost or pricing 8 data). 9 (c) Additional contract clauses.--The policy office may 10 promulgate regulations including, but not limited to, 11 regulations permitting or requiring the inclusion in 12 Commonwealth agency construction contracts of clauses providing 13 for appropriate remedies and covering the following subjects: 14 (1) Liquidated damages as appropriate. 15 (2) Specified excuses for delay or nonperformance. 16 (3) Termination of the contract for default. 17 (4) Termination of the contract in whole or in part for 18 the convenience of the purchasing agency. 19 (5) Noncompliance with the specifications issued under 20 section 706(b) (relating to wage specifications). 21 (d) Modification of required clauses.--The head of a 22 purchasing agency may vary the clauses promulgated under 23 subsections (a) and (c) for inclusion in any particular 24 Commonwealth agency construction contract. Any variation shall 25 be supported by a written determination that states the 26 circumstances justifying the variation. Notice of any material 27 variation shall be stated in the invitation for bids or request 28 for proposals. 29 § 907. Fiscal responsibility. 30 Every contract modification, change order or contract price 19830H1291B1524 - 51 -
1 adjustment under a construction contract with a Commonwealth 2 agency in excess of an amount set forth in regulations 3 promulgated by the policy office shall be subject to prior 4 written certification by the fiscal officer of the entity 5 responsible for funding the project or the contract or other 6 official responsible for monitoring and reporting upon the 7 status of the costs of the total project budget or contract 8 budget as to the effect of the contract modification, change 9 order or adjustment in contract price on the total project 10 budget or the total contract budget. In the event that the 11 certification of the fiscal officer or other responsible 12 official discloses a resulting increase in the total project 13 budget or the total contract budget, the procurement officer 14 shall not execute or make the contract modification, change 15 order or adjustment in contract price unless sufficient funds 16 are available or the scope of the project or contract is 17 adjusted so as to permit the degree of completion that is 18 feasible within the total project budget or total contract 19 budget as it existed prior to the contract modification, change 20 order or adjustment in contract price under consideration. 21 However, with respect to the validity, as to the contractor, of 22 any executed contract modification, change order or adjustment 23 in contract price which the contractor has reasonably relied 24 upon, it shall be presumed that there has been compliance with 25 the provisions of this section. 26 § 908. Architect, engineer and land surveying services. 27 (a) Applicability.--Architect, engineer and land surveying 28 services shall be procured as provided in this section except as 29 authorized by sections 514 (relating to small purchases), 515 30 (relating to sole source procurement) and 516 (relating to 19830H1291B1524 - 52 -
1 emergency procurement). 2 (b) Policy.--It is the policy of this Commonwealth to 3 publicly announce all requirements for architect, engineer and 4 land surveying services and to negotiate contracts for 5 architect, engineer and land surveying services on the basis of 6 demonstrated competence and qualification for the types of 7 services required at fair and reasonable prices. There shall be 8 a committee to review the qualifications, experience and work of 9 architect, engineer and land surveying services seeking 10 contracts with purchasing agencies. 11 (c) Selection committees for the Departments of 12 Transportation and Environmental Resources.--The Departments of 13 Transportation and Environmental Resources shall each establish 14 a selection committee in accordance with regulations promulgated 15 by each department and approved by the policy office. None of 16 the members of these committees shall hold any elective office 17 or office in any political party. 18 (d) Selection committee for all other Commonwealth 19 agencies.--Except as provided for in subsection (c), all 20 purchasing agencies shall use the selection committee appointed 21 by the policy office which shall be composed of five members 22 none of whom shall be employees or hold any elective office or 23 office in any political party. The members shall be architects, 24 engineers, land surveyors or other persons knowledgeable in 25 construction. The members shall serve for terms of two years and 26 shall not be removed except for cause. Each member shall be 27 reimbursed for reasonable travel and other expenses incurred 28 incident to his attendance and to his assigned duty and also a 29 per diem allowance as determined by the policy office. 30 (e) Procedure for selection committees.--The selection 19830H1291B1524 - 53 -
1 committees shall use the procedure set forth in this subsection: 2 (1) The committee shall give public notice of projects 3 requiring the services of architects, engineers and land 4 surveyors and publicly recommend to the purchasing agency 5 three qualified architects, engineers or land surveyors for 6 each project. 7 (2) If desired, the committee may conduct discussions 8 with three or more professional firms regarding anticipated 9 design concepts and proposed methods of approach to the 10 assignment. The committee shall select, based upon criteria 11 established by the head of the purchasing agency, no less 12 than three professional firms deemed to be the most highly 13 qualified to provide the services required. In exercising his 14 responsibility, the committee shall consider the following 15 factors: 16 (i) An equitable distribution of contracts to 17 architects, engineers and land surveyors. 18 (ii) Particular capability to perform the design, 19 construction or surveying services for the contract being 20 considered. 21 (iii) Geographic proximity of the architect, 22 engineer or land surveyor to the proposed facility. 23 (iv) The architect, engineer or land surveyor 24 selected has the necessary available personnel to perform 25 the services required by the project. 26 (v) Any other relevant circumstances peculiar to the 27 proposed contract. 28 (3) Of the three firms selected by the committee, the 29 head of the purchasing agency shall negotiate a contract with 30 the firm he determines to be the highest qualified firm for 19830H1291B1524 - 54 -
1 architectural, engineering or land surveying services at 2 compensation which he determines to be fair and reasonable to 3 the Commonwealth. In making this decision the head of the 4 purchasing agency shall take into account the estimated 5 value, scope, complexity and professional nature of the 6 services to be rendered. Should the head of the purchasing 7 agency be unable to negotiate a satisfactory contract with 8 the firm considered to be the most qualified, at a fee he 9 determines to be fair and reasonable to the Commonwealth, 10 negotiations with that firm shall be formally terminated. The 11 head of the purchasing agency shall then undertake 12 negotiations with the firm he determines to be the second 13 highest qualified firm. Failing accord with second most 14 qualified firm, the head of the purchasing agency shall 15 formally terminate negotiations and then undertake 16 negotiations with the third highest qualified firm. Should 17 the head of the purchasing agency be unable to negotiate a 18 satisfactory contract with any of the selected firms, the 19 committee shall select additional qualified firms and the 20 head of the purchasing agency shall continue negotiations in 21 accordance with this section until an agreement is reached. 22 CHAPTER 11 23 MODIFICATION AND TERMINATION OF CONTRACTS FOR 24 SUPPLIES AND SERVICES 25 Sec. 26 1101. Contract clauses and their administration. 27 § 1101. Contract clauses and their administration. 28 (a) Contract clauses.--The policy office may promulgate 29 regulations permitting or requiring the inclusion of clauses 30 providing for, but not limited to, adjustments in prices, time 19830H1291B1524 - 55 -
1 of performance or other contract provisions, as appropriate, 2 covering the following subjects: 3 (1) The unilateral right of the purchasing agency to 4 order in writing changes in the work within the scope of the 5 contract and temporary stopping of the work or delaying 6 performance. 7 (2) Variations occurring between estimated quantities of 8 work in a contract and actual quantities. 9 (b) Price adjustments.-- 10 (1) Adjustments under subsection (a) shall be computed 11 in one or more of the following ways: 12 (i) By agreement on fixed price adjustment before 13 commencement of the pertinent performance or as soon as 14 practicable. 15 (ii) By unit prices specified in the contract or 16 subsequently agreed upon. 17 (iii) By the costs attributable to the events or 18 situations under the clauses with adjustment of profit or 19 fee, all as specified in the contract or subsequently 20 agreed upon. 21 (iv) In any other manner as the contracting parties 22 may mutually agree. 23 (v) In the absence of agreement by the parties, by a 24 unilateral determination by the purchasing agency of the 25 costs attributable to the events or situations under the 26 clauses with adjustment of profit or fee, all as computed 27 by the purchasing agency in accordance with applicable 28 sections of the regulations promulgated under Chapter 13 29 (relating to cost principles) and subject to the 30 provisions of Chapter 17 (relating to legal and 19830H1291B1524 - 56 -
1 contractual remedies). 2 (2) A contractor shall be required to submit cost or 3 pricing data if any adjustment in contract price is subject 4 to the provisions of section 533 (relating to cost or pricing 5 data). 6 (c) Additional contract clauses.--The policy office may 7 promulgate regulations including, but not limited to, 8 regulations permitting or requiring the inclusion in 9 Commonwealth agency contracts of clauses providing for 10 appropriate remedies and covering the following subjects: 11 (1) Liquidated damages as appropriate. 12 (2) Specified excuses for delay or nonperformance. 13 (3) Termination of the contract for default. 14 (4) Termination of the contract in whole or in part for 15 the convenience of the purchasing agency. 16 (d) Modification of clauses.--The head of a purchasing 17 agency may vary the clauses promulgated under subsections (a) 18 and (c) for inclusion in any particular Commonwealth agency 19 contract. Any variation shall be supported by a written 20 determination that states the circumstances justifying the 21 variation. Notice of any material variation shall be stated in 22 the invitation for bids or requests for proposals. 23 CHAPTER 13 24 COST PRINCIPLES 25 Sec. 26 1301. Cost principles regulations required. 27 § 1301. Cost principles regulations required. 28 The policy office shall promulgate regulations setting forth 29 cost principles which shall be used to determine the 30 allowability of incurred costs for the purpose of reimbursing 19830H1291B1524 - 57 -
1 costs under contract provisions which provide for the 2 reimbursement of costs. However, if a written determination is 3 approved at a level above the procurement officer, the cost 4 principles may be modified by contract. 5 CHAPTER 15 6 SUPPLY MANAGEMENT 7 Sec. 8 1501. Definitions. 9 1502. Supply management regulations required. 10 1503. Proceeds from sale or disposal of surplus supplies. 11 § 1501. Definitions. 12 The following words and phrases when used in this chapter 13 shall have the meanings given to them in this section unless the 14 context clearly indicates otherwise: 15 "Excess supplies." Any supplies other than expendable 16 supplies having a remaining useful life but which are no longer 17 required by the using agency in possession of the supplies. 18 "Expendable supplies." All tangible supplies other than 19 nonexpendable supplies. 20 "Nonexpendable supplies." All tangible supplies having an 21 original acquisition cost of over $100 per unit and a probable 22 useful life of more than one year. 23 "Supplies." Supplies owned by Commonwealth agencies. 24 "Surplus supplies." Any supplies other than expendable 25 supplies no longer having any use to any Commonwealth agency. 26 This includes obsolete supplies, scrap materials and 27 nonexpendable supplies that have completed their useful life 28 cycle. 29 § 1502. Supply management regulations required. 30 The policy office shall promulgate regulations governing: 19830H1291B1524 - 58 -
1 (1) The management of supplies during their entire life 2 cycle. 3 (2) The sale, lease or disposal of surplus supplies by 4 public auction, competitive sealed bidding or other 5 appropriate method designated by regulation. However, no 6 employee of the owning or disposing agency shall be entitled 7 to purchase any of these supplies. 8 (3) Transfer of excess supplies. 9 § 1503. Proceeds from sale or disposal of surplus supplies. 10 The proceeds from the sale, lease or disposal of surplus 11 supplies shall be paid into the State Treasury and deposited in 12 the appropriate fund. 13 CHAPTER 17 14 LEGAL AND CONTRACTUAL REMEDIES 15 Subchapter 16 A. General Provisions 17 B. Prelitigation Resolution of Controversies 18 C. Board of Claims 19 D. Solicitations or Awards in Violation of Law 20 E. Interest 21 SUBCHAPTER A 22 GENERAL PROVISIONS 23 Sec. 24 1701. Definitions. 25 1702. Sovereign immunity. 26 § 1701. Definitions. 27 The following words and phrases when used in this chapter 28 shall have the meanings given to them in this section unless the 29 context clearly indicates otherwise: 30 "Claimant." Any person appealing to the Board of Claims or 19830H1291B1524 - 59 -
1 filing a claim with the board under section 1724(b) (relating to 2 jurisdiction). 3 § 1702. Sovereign immunity. 4 (a) General rule.--The General Assembly pursuant to section 5 11 of Article I of the Constitution of Pennsylvania reaffirms 6 sovereign immunity and, except as otherwise provided in this 7 chapter, no provision of this part shall constitute a waiver of 8 sovereign immunity for the purpose of 1 Pa.C.S. § 2310 (relating 9 to sovereign immunity reaffirmed; specific waiver) or otherwise. 10 (b) Exception.--The General Assembly pursuant to section 11 11 of Article I of the Constitution of Pennsylvania does hereby 12 waive sovereign immunity as a bar to claims against Commonwealth 13 agencies arising under this chapter but only to the extent set 14 forth in this chapter. 15 SUBCHAPTER B 16 PRELITIGATION RESOLUTION OF CONTROVERSIES 17 Sec. 18 1711. Authority to resolve protests of solicitations or 19 awards. 20 1712. Authority to resolve contract and breach of contract 21 controversies. 22 § 1711. Authority to resolve protests of solicitations or 23 awards. 24 (a) Right to protest.--Any actual or prospective bidder, 25 offeror or contractor who is aggrieved in connection with the 26 solicitation or award of a contract may protest to the head of a 27 purchasing agency in writing. All protests under this subsection 28 must be made within seven days after the protestant knows or 29 should have known of the facts giving rise to the protest. 30 (b) Authority to resolve protests.--The head of a purchasing 19830H1291B1524 - 60 -
1 agency shall have the authority to settle and resolve a protest 2 of an aggrieved bidder, offeror or contractor, actual or 3 prospective, concerning the solicitation or award of a contract. 4 This authority shall be exercised in accordance with regulations 5 promulgated by the policy office. 6 (c) Decision.--If the protest is not resolved by mutual 7 agreement, the head of a purchasing agency shall promptly issue 8 a decision in writing. The decision shall: 9 (1) State the reasons for the action taken. 10 (2) Inform the protestant of his right to administrative 11 and judicial review as provided in this chapter. 12 (d) Notice of decision.--A copy of the decision under 13 subsection (c) shall be delivered by registered mail to the 14 protestant and any other person determined by the head of the 15 purchasing agency to be affected by the decision. 16 (e) Finality of decision and appeal.--A decision under 17 subsection (c) shall be final and conclusive unless a person 18 adversely affected by the decision appeals to the Board of 19 Claims within 14 days of receipt of the decision. 20 (f) Stay of procurements during protests.--In the event of a 21 timely protest under subsection (a), the purchasing agency shall 22 not proceed further with the solicitation or with the award of 23 the contract unless and until the head of the purchasing agency, 24 after consultation with the head of the using agency, makes a 25 written determination that the award of the contract without 26 delay is necessary to protect substantial interests of the 27 Commonwealth. 28 (g) Entitlement to costs.--In addition to relief granted 29 under Subchapter D (relating to solicitations or awards in 30 violation of law), when a protest is sustained and if it is 19830H1291B1524 - 61 -
1 determined that the protesting bidder or offeror should have 2 been awarded the contract under the solicitation, then the 3 protesting bidder or offeror shall be entitled to the reasonable 4 costs incurred in connection with the solicitation, including 5 bid preparation costs other than attorney's fees. 6 § 1712. Authority to resolve contract and breach of contract 7 controversies. 8 (a) Applicability.--This section applies to controversies 9 between a Commonwealth agency and a contractor which arise 10 under, or by virtue of, a contract between them, including 11 controversies based upon breach of contract, mistake, 12 misrepresentation or other cause for contract modification or 13 rescission. A claim under this section must be filed in writing 14 with the head of the purchasing agency within six months after 15 it accrues and not thereafter. 16 (b) Authority.--The head of a purchasing agency is 17 authorized to settle and resolve a controversy described in 18 subsection (a). This authority shall be exercised in accordance 19 with regulations promulgated by the policy office. 20 (c) Decision.--If the controversy is not resolved by mutual 21 agreement, the head of a purchasing agency shall promptly issue 22 a decision in writing. The decision shall: 23 (1) State the reasons for the action taken. 24 (2) Inform the contractor of his right to administrative 25 and judicial review as provided in this chapter. 26 (d) Notice of decision.--A copy of the decision under 27 subsection (c) shall be delivered by registered mail to the 28 contractor. 29 (e) Finality of decision and appeal.--The decision under 30 subsection (c) shall be final and conclusive unless, where the 19830H1291B1524 - 62 -
1 amount in controversy amounts to $300 or more, the contractor 2 appeals to the Board of Claims within 60 days of receipt of the 3 decision. 4 (f) Failure to render timely decision.--If the head of a 5 purchasing agency does not issue the written decision required 6 under subsection (c) within 120 days after written request for a 7 final decision or within a longer period as may be agreed upon 8 by the parties, then the contractor may proceed as if an adverse 9 decision had been received. 10 SUBCHAPTER C 11 BOARD OF CLAIMS 12 Sec. 13 1721. Composition. 14 1722. Hearing panels. 15 1723. Administrative matters. 16 1724. Jurisdiction. 17 1725. Procedure. 18 1726. Appeals. 19 § 1721. Composition. 20 (a) Appointment and qualifications.--The Board of Claims 21 shall be an independent administrative board and shall consist 22 of three members appointed by the Governor. The members shall be 23 a lawyer who shall be chairman and hold the title of chief 24 administrative judge, a professional engineer who shall 25 specialize in civil engineering and a citizen and resident of 26 this Commonwealth. 27 (b) Terms.--Each member shall serve for a term of eight 28 years. In the event any member dies or resigns during his term 29 of office, the Governor shall appoint a successor who shall hold 30 office for the unexpired term. 19830H1291B1524 - 63 -
1 (c) Compensation.--Each member shall serve full time and 2 shall perform no duties inconsistent with his duties and 3 responsibilities as a member of the Board of Claims. Each member 4 shall receive an annual compensation set by the Executive Board 5 and shall be entitled to all necessary traveling and other 6 expenses incurred by him in the discharge of his official 7 duties. During the term of a member, his salary shall not be 8 diminished. 9 § 1722. Hearing panels. 10 (a) Appointment and qualifications.--The Board of Claims may 11 appoint three hearing panels consisting of two individuals each, 12 a lawyer who shall be chairman and a professional engineer who 13 shall specialize in civil engineering. 14 (b) Compensation.--An individual serving on a hearing panel 15 shall be entitled to all necessary traveling and other expenses 16 incurred by him in the discharge of his official duties and to 17 per diem compensation at the rate of $150 per day for the time 18 actually devoted to the business of the Board of Claims. No 19 panel member shall be paid more than $10,000 per diem 20 compensation in any calendar year. 21 (c) Jurisdiction.--The hearing panels shall be designated 22 the Eastern, Middle and Western District Hearing Panel, 23 respectively, and shall have jurisdiction in areas of this 24 Commonwealth coterminous with the three judicial districts of 25 the United States District Courts in this Commonwealth. 26 § 1723. Administrative matters. 27 (a) Employees.--The Board of Claims shall appoint an 28 executive secretary and may appoint other persons including 29 lawyers, engineers and stenographers as are needed in the proper 30 exercise of its functions. Administrative services shall be 19830H1291B1524 - 64 -
1 provided by the Department of the Auditor General. 2 (b) Location of office and official seal.--The Board of 3 Claims shall maintain its office in Harrisburg and adopt an 4 official seal which shall authenticate its proceedings. 5 (c) Copies of testimony and opinions.--No charge shall be 6 made against any Commonwealth agency for copies of notes of 7 testimony or other papers furnished to the agency. The claimant 8 or any other party may purchase a copy of testimony directly 9 from the official stenographer. The Board of Claims may employ a 10 reporter who shall catalogue and have published all opinions of 11 the board. 12 § 1724. Jurisdiction. 13 (a) Appellate jurisdiction.--The Board of Claims shall have 14 exclusive jurisdiction to review and determine de novo any 15 appeal by a claimant from a decision by the head of a purchasing 16 agency which is authorized by: 17 Section 531 (relating to debarment or suspension). 18 Section 1711 (relating to authority to resolve protests 19 of solicitations or awards). 20 Section 1712 (relating to authority to resolve contract 21 and breach of contract controversies). 22 (b) Original jurisdiction.--The Board of Claims shall have 23 exclusive jurisdiction to hear and determine those claims filed 24 with it within six months after the claim accrues authorized by 25 the act of March 30, 1811 (P.L.145, Ch.99), entitled "An act to 26 amend and consolidate the several acts relating to the 27 settlement of the public accounts and the payment of the public 28 monies, and for other purposes," and continued by Article X, of 29 the act of April 9, 1929 (P.L.343, No.176), known as The Fiscal 30 Code, where the Auditor General and State Treasurer were granted 19830H1291B1524 - 65 -
1 the power to adjust and settle certain claims against the 2 Commonwealth. 3 (c) Other jurisdiction.--The Board of Claims shall have 4 exclusive jurisdiction to hear and determine claims against the 5 Commonwealth filed within six months after the claim accrues to 6 the extent that it had such jurisdiction, other than that 7 provided for in subsections (a) and (b), under the former 8 provisions of the act of May 20, 1937 (P.L.728, No.193), 9 referred to as the Board of Claims Act. 10 § 1725. Procedure. 11 (a) General rule.--To the extent not inconsistent with the 12 provisions of this section, all trials before the Board of 13 Claims and hearings before panels appointed by the board shall 14 be governed by the Pennsylvania Rules of Civil Procedure and 2 15 Pa.C.S. Ch. 5, Subch. A (relating to practice and procedure of 16 Commonwealth agencies). 17 (b) Filing of claim.--The claimant shall file with the 18 executive secretary a concise and specific written statement of 19 his claim, signed and subject to the penalties of 18 Pa.C.S. § 20 4904 (relating to unsworn falsification to authorities). The 21 claimant at the same time shall file six copies of the 22 statement. The executive secretary shall deliver a copy to the 23 Commonwealth agency involved. At the time of filing the 24 statement of claim, the claimant shall pay to the State 25 Treasury, through the executive secretary, $50 as a filing fee 26 unless the fee is waived under regulations promulgated by the 27 Board of Claims. All filing fees received shall be credited to 28 the General Fund. 29 (c) Answer.--Within 30 days of the filing of the statement 30 with the executive secretary and delivery to the Commonwealth 19830H1291B1524 - 66 -
1 agency involved, the Commonwealth agency shall file with the 2 executive secretary an answer in writing to the averments of the 3 statement, signed and subject to the penalties of 18 Pa.C.S. § 4 4904. The Commonwealth agency at the same time shall file two 5 copies of the answer. The executive secretary shall deliver a 6 copy to the claimant. The answer may include a counterclaim 7 which arises from the same contract, transaction or occurrence 8 or series of transactions or occurrences from which the claim 9 arose. 10 (d) Place and time of trial.--Trials shall be held in this 11 Commonwealth at a place and time determined by the Board of 12 Claims. When the pleadings are complete, the executive secretary 13 shall list the case for trial at the earliest available date but 14 not earlier than 30 days after the filing of the answer. All 15 cases shall, as far as practicable, be listed for trial in the 16 order of the date of the filing of the respective claims. The 17 executive secretary shall serve upon the claimant and the 18 Commonwealth agency 30 days written notice of the trial. 19 (e) Hearing panels.--If in the opinion of the executive 20 secretary it appears unlikely that the case will be listed for 21 trial within 60 days after pleadings are complete, the executive 22 secretary may refer the case to one of the three hearing panels. 23 The hearing panel shall list the case for hearing at the 24 earliest available date after receipt of the case. The hearing 25 panel shall be subject to the same requirements, as to procedure 26 and opinions, as the Board of Claims. The hearing panel shall 27 forward its recommendation to the board within the time 28 established in subsection (h). 29 (f) Interpleader and impleader.--The Board of Claims shall 30 have the power to order the interpleader or impleader of other 19830H1291B1524 - 67 -
1 parties whenever necessary for a complete determination of any 2 claim or counterclaim. 3 (g) Subpoenas.--The executive secretary shall have the power 4 to issue subpoenas at the request of either the claimant or the 5 Commonwealth agency and to require the attendance of witnesses 6 and the production of books, documents and papers pertinent to 7 the case before the Board of Claims. The board shall prescribe 8 the form for all subpoenas. Each subpoena shall be signed by the 9 executive secretary. The subpoena may be served by any adult in 10 any part of this Commonwealth. Any person who refuses to obey a 11 subpoena or who refuses to testify or who fails to produce any 12 papers, books or documents pertinent to the case in which he is 13 subpoenaed or who is guilty of any contempt after summoned to 14 appear, may be punished for contempt of court. Witness fees and 15 expenses shall be divided between the claimant and the 16 Commonwealth agency in any proportion the board directs. 17 (h) Trial or hearing and decision.--All trials before the 18 Board of Claims or hearings before a hearing panel shall be 19 public and the proceedings shall be de novo. Any prior 20 determinations by administrative officials shall not be final or 21 conclusive except as provided in section 561 (relating to 22 finality of determinations). The board or hearing panel shall 23 make a decision within a reasonable time from the date of trial 24 or hearing. If the claim is a debarment or suspension under 25 section 531 (relating to debarment or suspension), the board 26 shall promptly decide whether, or the extent to which, the 27 debarment or suspension was in accordance with the Constitution 28 of Pennsylvania, statutes, regulations and the best interests of 29 the Commonwealth. If the claim is a protest of a solicitation or 30 award under section 1711 (relating to authority to resolve 19830H1291B1524 - 68 -
1 protests of solicitations or awards), the board shall promptly 2 decide whether the solicitation or award was in accordance with 3 the Constitution of Pennsylvania, statutes, regulations and the 4 terms and conditions of the solicitation. If the claim is a 5 contract controversy under section 1712 (relating to authority 6 to resolve contract and breach of contract controversies), the 7 board shall promptly decide the contract or breach of contract 8 controversy and, if appropriate, make an award of a sum that it 9 determines the claimant is entitled to receive. If the claim is 10 brought under section 1724(b) or (c) (relating to jurisdiction), 11 the board shall promptly decide to either dismiss the claim or 12 make an award of a sum it determines the claimant is entitled to 13 receive. If the proceeding is before a panel, the panel shall 14 make its decision in the form of a recommendation to the board 15 within 30 days after the hearing. The board shall dispose of all 16 costs of the proceedings by providing for their payment by the 17 claimant or the Commonwealth agency or by providing that the 18 costs be shared by the claimant and the Commonwealth agency in 19 any proportion as the board directs. 20 (i) Certification of decision and costs.--Within 30 days 21 after a final decision is made by the Board of Claims, the 22 executive secretary shall certify to the claimant and 23 Commonwealth agency involved, under the seal of the board, a 24 statement of the decision, including any costs assessed against 25 the claimant or the Commonwealth agency or both and the persons 26 entitled to the costs. The award shall be paid by the 27 Commonwealth agency to the claimant out of any available funds. 28 Any costs assessed against the Commonwealth agency shall be paid 29 by the agency to the persons entitled, as evidenced by the 30 certificate of the executive secretary, out of the same funds. 19830H1291B1524 - 69 -
1 If the costs are assessed against the claimant, they shall be 2 deducted from the balance due the claimant under the contract 3 from which the claim arose and shall be paid by the Commonwealth 4 agency to the persons entitled, as evidenced by the certificate 5 of the executive secretary. 6 (j) Certification of award by court-of-record.--The claimant 7 or the Commonwealth agency involved may petition the 8 Commonwealth Court to have an award of the Board of Claims 9 certified as a judgment of a court-of-record. 10 (k) Public records.--All papers filed under this subchapter 11 shall be a public record to the extent provided in the act of 12 June 21, 1957 (P.L.390, No.212), referred to as the Right-to- 13 Know Law, and shall be available to the public as provided in 14 that act. 15 (l) Regulations.--The Board of Claims shall promulgate 16 regulations governing practice and procedure before it. 17 § 1726. Appeals. 18 Any person, including a Commonwealth agency, aggrieved by a 19 decision of the Board of Claims may appeal to the Commonwealth 20 Court under 42 Pa.C.S. § 763(a)(1) (relating to direct appeals 21 from government agencies) within 30 days after certification of 22 the decision under section 1725(i) (relating to procedure). 23 SUBCHAPTER D 24 SOLICITATIONS OR AWARDS IN VIOLATION OF LAW 25 Sec. 26 1741. Applicability. 27 1742. Remedies prior to an award. 28 1743. Remedies after the award. 29 § 1741. Applicability. 30 The provisions of this subchapter apply where it is 19830H1291B1524 - 70 -
1 determined by the head of a purchasing agency or upon Board of 2 Claims or judicial review that a solicitation or award of a 3 contract is in violation of law. 4 § 1742. Remedies prior to an award. 5 If prior to award it is determined that a solicitation or 6 proposed award of a contract is in violation of law, then the 7 remedies are limited to cancellation of the solicitation or 8 proposed award or revision of the solicitation or proposed award 9 to comply with the law. 10 § 1743. Remedies after the award. 11 If after an award it is determined that a solicitation or 12 award of a contract is in violation of law, then: 13 (1) If the person awarded the contract has not acted 14 fraudulently or in bad faith: 15 (i) the contract may be ratified and affirmed, 16 provided it is determined that doing so is in the best 17 interest of the Commonwealth; or 18 (ii) the contract may be terminated and the person 19 awarded the contract shall be compensated for the actual 20 expenses reasonably incurred under the contract, plus a 21 reasonable profit, prior to the termination. 22 (2) If the person awarded the contract has acted 23 fraudulently or in bad faith: 24 (i) the contract may be declared void; or 25 (ii) the contract may be ratified and affirmed if 26 that action is in the best interests of the Commonwealth, 27 without prejudice to the right of the Commonwealth agency 28 to damages as may be appropriate. 29 SUBCHAPTER E 30 INTEREST 19830H1291B1524 - 71 -
1 Sec. 2 1751. Interest. 3 § 1751. Interest. 4 Interest on amounts ultimately determined to be due shall be 5 payable at the statutory rate applicable to judgments from the 6 date the claim was filed with the head of the purchasing agency. 7 Interest on claims arising out of the provisions of section 1507 8 of the act of April 9, 1929 (P.L.343, No.176), known as The 9 Fiscal Code, shall be payable as provided therein. In the case 10 of a claim filed under section 1724(b) or (c) (relating to 11 jurisdiction), interest shall be payable from the date the claim 12 was filed with the Board of Claims. 13 CHAPTER 19 14 INTERGOVERNMENTAL RELATIONS 15 Sec. 16 1901. Definitions. 17 1902. Cooperative purchasing authorized. 18 1903. Sale, acquisition or use of supplies by a public 19 procurement unit. 20 1904. Cooperative use of supplies or services. 21 1905. Joint use of facilities. 22 1906. Supply of personnel, information and technical services. 23 1907. Use of payments received by a supplying public 24 procurement unit. 25 1908. Compliance of public procurement units. 26 1909. Review of procurement requirements. 27 1910. Contract controversies. 28 § 1901. Definitions. 29 The following words and phrases when used in this chapter 30 shall have the meanings given to them in this section unless the 19830H1291B1524 - 72 -
1 context clearly indicates otherwise: 2 "Cooperative purchasing." Procurement conducted by, or on 3 behalf of, more than one public procurement unit or by a public 4 procurement unit with an external procurement activity. 5 "External procurement activity." Any buying organization not 6 located in this Commonwealth which, if located in this 7 Commonwealth, would qualify as a public procurement unit. An 8 agency of the United States is an external procurement activity. 9 "Local public procurement unit." Any political subdivision, 10 public authority, educational, health or other institution and, 11 to the extent provided by law, any other entity, including a 12 council of governments or an area government, which expends 13 public funds for the procurement of supplies, services and 14 construction, and any nonprofit corporation operating a 15 charitable hospital. 16 "Public procurement unit." A local public procurement unit 17 or a purchasing agency. 18 § 1902. Cooperative purchasing authorized. 19 Any public procurement unit may either participate in, 20 sponsor, conduct or administer a cooperative purchasing 21 agreement for the procurement of any supplies, services or 22 construction with one or more public procurement units or 23 external procurement activities in accordance with an agreement 24 entered into between the participants. Cooperative purchasing 25 may include, but is not limited to, joint or multiparty 26 contracts between public procurement units and open-ended 27 purchasing agency contracts which are made available to local 28 public procurement units. 29 § 1903. Sale, acquisition or use of supplies by a public 30 procurement unit. 19830H1291B1524 - 73 -
1 Any public procurement unit may sell to, acquire from or use 2 any supplies belonging to another public procurement unit or 3 external procurement activity independent of the requirements of 4 Chapters 5 (relating to source selection and contract formation) 5 and 15 (relating to supply management). 6 § 1904. Cooperative use of supplies or services. 7 Any public procurement unit may enter into an agreement, 8 independent of the requirements of Chapters 5 (relating to 9 source selection and contract formation) and 15 (relating to 10 supply management), with any other public procurement unit or 11 external procurement activity for the cooperative use of 12 supplies or services under the terms agreed upon between the 13 parties. 14 § 1905. Joint use of facilities. 15 Any public procurement unit may enter into agreements for the 16 common use or lease of warehousing facilities, capital equipment 17 and other facilities with another public procurement unit or an 18 external procurement activity under the terms agreed upon 19 between the parties. 20 § 1906. Supply of personnel, information and technical 21 services. 22 (a) Supply of personnel.--Any public procurement unit is 23 authorized, in its discretion, upon written request from another 24 public procurement unit or external procurement activity, to 25 provide personnel to the requesting public procurement unit or 26 external procurement activity. The public procurement unit or 27 external procurement activity making the request shall pay the 28 public procurement unit providing the personnel the direct and 29 indirect cost of furnishing the personnel, in accordance with an 30 agreement between the parties. 19830H1291B1524 - 74 -
1 (b) Supply of services.--The informational, technical and 2 other services of any public procurement unit may be made 3 available to any other public procurement unit or external 4 procurement activity. However, the requirements of the public 5 procurement unit tendering the services shall have precedence 6 over the requesting public procurement unit or external 7 procurement activity. The requesting public procurement unit or 8 external procurement activity shall pay for the expenses of the 9 services provided, in accordance with an agreement between the 10 parties. 11 (c) Information services.--Upon request, the department may 12 make available to public procurement units or external 13 procurement activities the following services, among others: 14 (1) Standard forms. 15 (2) Printed manuals. 16 (3) Product specifications and standards. 17 (4) Quality assurance testing services and methods. 18 (5) Qualified products lists. 19 (6) Source information. 20 (7) Common use commodities listings. 21 (8) Supplier prequalfication information. 22 (9) Supplier performance ratings. 23 (10) Debarred and suspended bidders lists. 24 (11) Forms for invitations for bids, requests for 25 proposals, instructions to bidders, general contract 26 provisions and other contract forms. 27 (12) Contracts or published summaries of contracts, 28 including price and time of delivery information. 29 (d) Technical services.--The department may provide the 30 following technical services, among others: 19830H1291B1524 - 75 -
1 (1) Development of products specifications. 2 (2) Development of quality assurance test methods, 3 including receiving, inspection and acceptance procedures. 4 (3) Use of product testing and inspection facilities. 5 (4) Use of personnel training programs. 6 (e) Fees.--The department may enter into contractual 7 arrangements and publish a schedule of fees for the services 8 provided under subsections (c) and (d). 9 § 1907. Use of payments received by a supplying public 10 procurement unit. 11 All payments from any public procurement unit or external 12 procurement activity received by a public procurement unit 13 supplying personnel or services shall be available to the 14 supplying public procurement unit. 15 § 1908. Compliance of public procurement units. 16 Where the public procurement unit or external procurement 17 activity administering a cooperative purchase complies with the 18 requirements of this part, any public procurement unit 19 participating in the purchase shall be deemed to have complied 20 with this part. Public procurement units may not enter into a 21 cooperative purchasing agreement for the purpose of 22 circumventing this part. 23 § 1909. Review of procurement requirements. 24 To the extent possible, the department may collect 25 information concerning the type, cost, quality and quantity of 26 commonly used supplies, services or construction being procured 27 or used by Commonwealth agencies. The department may also 28 collect this information from local procurement units. The 29 department may make this information available to any public 30 procurement unit upon request. 19830H1291B1524 - 76 -
1 § 1910. Contract controversies. 2 (a) Public procurement unit subject to certain legal and 3 contractual remedies.--Under a cooperative purchasing agreement, 4 controversies arising between an administering public 5 procurement unit, subject to Chapter 17 (relating to legal and 6 contractual remedies), and its bidders, offerors or contractors 7 shall be resolved in accordance with Chapter 17. 8 (b) Local public procurement unit not subject to certain 9 legal and contractual remedies.--Any local public procurement 10 unit which is not subject to Chapter 17 (relating to legal and 11 contractual remedies) is authorized to: 12 (1) Enter into an agreement with the Board of Claims to 13 use the board to resolve controversies between the local 14 public procurement unit and its contractors, whether or not 15 the controversy arose from a cooperative purchasing 16 agreement. 17 (2) Enter into an agreement with another local public 18 procurement unit or external procurement activity to 19 establish procedures or use existing procedures of the unit 20 or activity to resolve controversies with contractors, 21 whether or not the controversy arose under a cooperative 22 purchasing agreement. 23 CHAPTER 21 24 SMALL AND DISADVANTAGED BUSINESSES 25 Sec. 26 2101. Policy. 27 2102. Definitions. 28 2103. Regulations. 29 2104. Duties of department. 30 2105. Bonding and progress payments. 19830H1291B1524 - 77 -
1 2106. Business assistance offices. 2 2107. Report to policy office and General Assembly. 3 2108. Compliance with Federal requirements. 4 § 2101. Policy. 5 The policy of this Commonwealth is to assist small and 6 disadvantaged businesses in learning how to do business with 7 Commonwealth agencies. The department shall implement this 8 policy in accordance with regulations promulgated by the policy 9 office. 10 § 2102. Definitions. 11 Subject to section 2103 (relating to regulations), the 12 following words and phrases when used in this chapter shall have 13 the meanings given to them in this section unless the context 14 clearly indicates otherwise: 15 "Disadvantaged business." A small business which is owned or 16 controlled by a majority of persons, not limited to members of 17 minority groups, who have been deprived of the opportunity to 18 develop and maintain a competitive position in the economy 19 because of social disadvantages. 20 "Small business." A business in the United States which is 21 independently owned and which is not dominant in its field of 22 operation or an affiliate or subsidiary of a business dominant 23 in its field of operation. 24 § 2103. Regulations. 25 The policy office shall promulgate regulations establishing 26 detailed definitions of the words and phrases defined in section 27 2102 (relating to definitions) using, in addition to the 28 criteria set forth in section 2102, other criteria as it deems 29 desirable, including the number of employees and the dollar 30 volume of business. 19830H1291B1524 - 78 -
1 § 2104. Duties of department. 2 The department shall have the following duties: 3 (1) Where feasible, provide appropriate staff who shall 4 be responsible to the department and who shall serve within 5 designated Commonwealth agencies to assist Pennsylvania small 6 and disadvantaged businesses in learning how to do business 7 with Commonwealth agencies. 8 (2) Give special publicity to procurement procedures and 9 issue special publications designed to assist small and 10 disadvantaged businesses in learning how to do business with 11 Commonwealth agencies. 12 (3) Compile, maintain and make available source lists of 13 small and disadvantaged businesses for the purpose of 14 encouraging procurement from small and disadvantaged 15 businesses. 16 (4) To the extent the department deems appropriate and 17 as may be required by regulation, include small and 18 disadvantaged businesses on solicitation mailing lists. 19 (5) Assure that small and disadvantaged businesses are 20 solicited on each procurement for which the businesses may be 21 suited. 22 (6) Develop special training programs to assist small 23 and disadvantaged businesses in learning how to do business 24 with Commonwealth agencies. 25 § 2105. Bonding and progress payments. 26 (a) Bonding.--Notwithstanding other provisions of this part, 27 the department may reduce the level or change the types of 28 bonding normally required or accept alternative forms of 29 security to the extent reasonably necessary to encourage 30 procurement from small and disadvantaged businesses. 19830H1291B1524 - 79 -
1 (b) Progress payments.--The department may make special 2 provisions for progress payments as it deems reasonably 3 necessary to encourage procurement from small and disadvantaged 4 businesses. 5 § 2106. Business assistance offices. 6 The department may establish, as it deems appropriate, 7 business assistance offices throughout this Commonwealth to 8 assist and carry out the provisions of this chapter. 9 § 2107. Report to policy office and General Assembly. 10 The department shall annually, before October 1, report in 11 writing to the policy office and the General Assembly concerning 12 the awarding of contracts to small and disadvantaged businesses 13 during the preceding fiscal year. 14 § 2108. Compliance with Federal requirements. 15 If a procurement involves the expenditure of Federal 16 assistance or contract funds, the department shall comply with 17 Federal law and authorized regulations which are mandatorily 18 applicable and which are not presently reflected in this part. 19 CHAPTER 23 20 ETHICS IN PUBLIC CONTRACTING 21 Subchapter 22 A. General Policy and Standards 23 B. Specific Standards 24 SUBCHAPTER A 25 GENERAL POLICY AND STANDARDS 26 Sec. 27 2301. Policy. 28 2302. General standards of ethical conduct. 29 2303. Reporting of breaches of ethical standards. 30 § 2301. Policy. 19830H1291B1524 - 80 -
1 Public employment is a public trust. It is the policy of this 2 Commonwealth to promote and balance the objective of protecting 3 government integrity and the objective of facilitating the 4 recruitment and retention of personnel needed by the 5 Commonwealth. Implementation of this policy requires that public 6 employees discharge their duties impartially so as to assure 7 fair competitive access to Commonwealth agency procurement by 8 responsible contractors and that they conduct themselves in a 9 manner that fosters public confidence in the integrity of the 10 Commonwealth procurement process. It is also essential that 11 those doing business with the Commonwealth agencies observe high 12 standards of honesty and integrity. 13 § 2302. General standards of ethical conduct. 14 (a) Employees.--Any attempt to realize personal gain through 15 public employment by conduct inconsistent with the proper 16 discharge of the duties of the employee is a breach of a public 17 trust. In order to fulfill this general prescribed standard, 18 employees must avoid any conflict of interest or improper use of 19 confidential information. 20 (b) Nonemployees.--Any effort to influence any employee to 21 breach the standards of ethical conduct set forth in this 22 section is also a breach of ethical standards. 23 § 2303. Reporting of breaches of ethical standards. 24 When any person has reason to believe that any breach of 25 standards set forth in this chapter has occurred, that person 26 shall report all relevant facts to the State Ethics Commission 27 and to the Attorney General for any appropriate action. 28 SUBCHAPTER B 29 SPECIFIC STANDARDS 30 Sec. 19830H1291B1524 - 81 -
1 2311. Bonds. 2 § 2311. Bonds. 3 It is a breach of ethical standards and unlawful for any 4 employee in issuing an invitation for bids or request for 5 proposals to require that any bond required by this part be 6 furnished by a particular surety company or through a particular 7 agent or broker. Any employee who violates this section commits 8 a misdemeanor of the first degree. 9 PART II 10 GENERAL PROCUREMENT PROVISIONS 11 Chapter 12 31. General Provisions 13 33. Prevention of Environmental Pollution 14 35. Foreign Corporations 15 37. Contract Clauses and Preference Provisions 16 39. Construction Contracts Over $50,000 17 41. Purchase of Surplus Federal Property 18 43. Public Facilities Concessions 19 CHAPTER 31 20 GENERAL PROVISIONS 21 Sec. 22 3101. Application of part. 23 3102. Definitions. 24 § 3101. Application of part. 25 This part applies to government agencies. In the case of 26 Commonwealth agencies, this part shall be read in pari materia 27 with Part I (relating to Commonwealth Procurement Code). 28 § 3102. Definitions. 29 Subject to additional definitions contained in subsequent 30 provisions of this part which are applicable to specific 19830H1291B1524 - 82 -
1 provisions of this part, the following words and phrases when 2 used in this part shall have the meanings given to them in this 3 section unless the context clearly indicates otherwise: 4 "Commonwealth agency." A Commonwealth agency as defined in 5 section 103 (relating to definitions). 6 "Government agency." Any Commonwealth agency or any 7 political subdivision or municipal or other local authority, or 8 any officer or agency of any such political subdivision or local 9 authority. 10 CHAPTER 33 11 PREVENTION OF ENVIRONMENTAL POLLUTION 12 Sec. 13 3301. Invitations for bids and requests for proposals. 14 3302. Additional work. 15 3303. Arbitration of disputes. 16 § 3301. Invitations for bids and requests for proposals. 17 All invitations for bids and requests for proposals for 18 construction projects issued by any government agency shall set 19 forth any provision of Federal and State statutes, rules and 20 regulations dealing with the prevention of environmental 21 pollution and the preservation of public natural resources that 22 affect the projects. 23 § 3302. Additional work. 24 If the successful bidder or offeror must undertake additional 25 work due to the enactment of new or the amendment of existing 26 statutes, rules or regulations occurring after the submission of 27 the successful bid or proposal, the government agency shall 28 issue a change order setting forth the additional work that must 29 be undertaken, which shall not invalidate the contract. The cost 30 of a change order to the government agency shall be determined 19830H1291B1524 - 83 -
1 in accordance with the provisions of the contract for change 2 orders or force accounts or, if there is not a provision set 3 forth in the contract, then the cost to the government agency 4 shall be the costs to the contractor for wages, labor costs 5 other than wages, wage taxes, materials, equipment rentals, 6 insurance and subcontracts attributable to the additional 7 activity plus a reasonable sum for overhead and profit. 8 Additional costs to undertake work not specified in the 9 invitation for bids or requests for proposals shall not be 10 approved unless written authorization is given the successful 11 bidder or offeror prior to his undertaking the additional 12 activity. 13 § 3303. Arbitration of disputes. 14 In the event of a dispute between the government agency and 15 the successful bidder or offeror, arbitration procedures may be 16 commenced under the applicable terms of the construction 17 contract or, if the contract does not contain a provision for 18 arbitration, the then obtaining rules of the American 19 Arbitration Association. 20 CHAPTER 35 21 FOREIGN CORPORATIONS 22 Sec. 23 3501. Condition precedent to release of bond. 24 § 3501. Condition precedent to release of bond. 25 In any case where a government agency enters into a contract 26 with a foreign corporation for the erection, construction, 27 alteration or repair of any public building, public work or 28 public project, the bond required by law to be furnished by the 29 corporation, before the letting of the contract or in relation 30 to the contract, shall contain a provision that the corporation 19830H1291B1524 - 84 -
1 or its sureties shall not be discharged from liability on the 2 bond or bond surrendered until the corporation files with the 3 government agency the following: 4 (1) A certificate from the Department of Revenue 5 evidencing the payment in full of all bonus taxes, penalties 6 and interest. 7 (2) A certificate from the Department of Labor and 8 Industry evidencing the payment of all unemployment 9 compensation contributions, penalties and interest due the 10 Commonwealth from the corporation or subcontractor or for 11 which liability has accrued but the time for payment has not 12 arrived. 13 CHAPTER 37 14 CONTRACT CLAUSES AND PREFERENCE PROVISIONS 15 Subchapter 16 A. Labor 17 B. Steel Products 18 C. Trade Practices 19 D. Used Oil Products 20 SUBCHAPTER A 21 LABOR 22 Sec. 23 3701. Contract provisions prohibiting discrimination. 24 3702. Contract provision requiring United States citizens to 25 be employed. 26 3703. Contract provision requiring residents to be employed. 27 § 3701. Contract provisions prohibiting discrimination. 28 Each contract entered into by a government agency for the 29 construction, alteration or repair of any public building or 30 public work shall contain the following provisions by which the 19830H1291B1524 - 85 -
1 contractor agrees that: 2 (1) In the hiring of employees for the performance of 3 work under the contract or any subcontract, no contractor, 4 subcontractor or any person acting on behalf of the 5 contractor or subcontractor shall by reason of race, creed or 6 color discriminate against any citizen of this Commonwealth 7 who is qualified and available to perform the work to which 8 the employment relates. 9 (2) No contractor or subcontractor or any person on 10 their behalf shall, in any manner, discriminate against or 11 intimidate any employee hired for the performance of work 12 under the contract on account of race, creed or color. 13 (3) There may be deducted, from the amount payable to 14 the contractor under the contract, a penalty of $5 for each 15 person for each calendar day during which the person was 16 discriminated against or intimidated in violation of the 17 contract. 18 (4) The contract may be cancelled or terminated by the 19 government agency and all money due or to become due under 20 the contract may be forfeited for a second or any subsequent 21 violation of the terms or conditions of that portion of the 22 contract. 23 § 3702. Contract provision requiring United States citizens 24 to be employed. 25 (a) General rule.--Each contract entered into by a 26 government agency for the erection, enlargement or improvement 27 of any public building or public work shall contain a provision 28 that only citizens of the United States shall be employed in the 29 erection, enlargement or improvement of the public building or 30 work. 19830H1291B1524 - 86 -
1 (b) Exceptions.--This section does not apply to: 2 (1) Apprentices to a trade or profession who are under 3 21 years of age. 4 (2) Public work where the cost of the public work is 5 paid in whole or in part from assessments of benefits. 6 § 3703. Contract provision requiring residents to be employed. 7 Each contract entered into by a government agency for the 8 construction, alteration or repairs of any public works shall 9 contain a provision that laborers and mechanics employed on the 10 public works shall have been residents of this Commonwealth for 11 at least 90 days prior to their employment. Failure to comply 12 with this section shall be sufficient legal reason to refuse 13 payment of the contract price to the contractor. 14 SUBCHAPTER B 15 STEEL PRODUCTS 16 Sec. 17 3711. Short title of subchapter. 18 3712. Definitions. 19 3713. Required contract provisions. 20 3714. Payments under contracts. 21 § 3711. Short title of subchapter. 22 This subchapter shall be known and may be cited as the Steel 23 Products Procurement Act. 24 § 3712. Definitions. 25 The following words and phrases when used in this subchapter 26 shall have the meanings given to them in this section unless the 27 context clearly indicates otherwise: 28 "Public works." Any structure, building, highway, waterway, 29 street, bridge, transit system, airport or other betterment, 30 work or improvement whether of a permanent or temporary nature 19830H1291B1524 - 87 -
1 and whether for governmental or proprietary use. 2 "Steel products." Products rolled, formed, shaped, drawn, 3 extruded, forged, cast, fabricated or otherwise similarly 4 processed, or processed by a combination of two or more of these 5 operations, from steel made in the United States by the open 6 hearth, basic oxygen, electric furnace, Bessemer or other steel 7 making process. The term includes cast iron products. 8 "United States." The United States of America including all 9 territory, continental or insular, subject to the jurisdiction 10 of the United States. 11 § 3713. Required contract provisions. 12 (a) General rule.--Each contract entered into by a 13 government agency for the construction, reconstruction, 14 alteration, repair, improvement or maintenance of public works 15 shall contain a provision that, if any steel products are to be 16 used or supplied in the performance of the contract, only steel 17 products as defined in this subchapter shall be used or supplied 18 in the performance of the contract or any subcontracts. 19 (b) Exception.--This section does not apply in any case 20 where the head of the government agency, in writing, determines 21 that steel products as defined in this subchapter are not 22 produced in the United States in sufficient quantities to meet 23 the requirements of the contract. 24 § 3714. Payments under contracts. 25 No government agency shall authorize, provide for or make any 26 payments to any person under any contract containing the 27 provision required by section 3713 (relating to required 28 contract provisions) unless the government agency is satisfied 29 that the person has fully complied with section 3713. Any 30 payments made to any person by any government agency which 19830H1291B1524 - 88 -
1 should not have been made as a result of this section shall be 2 recoverable by either the government agency or the Attorney 3 General directly from the contractor or subcontractor who did 4 not comply with section 3713. 5 SUBCHAPTER C 6 TRADE PRACTICES 7 Sec. 8 3721. Short title of subchapter. 9 3722. Definitions. 10 3723. Unlawful acts. 11 3724. Preference. 12 3725. Listing discriminating countries. 13 3726. Determining discrimination. 14 3727. Foreign registry docket. 15 3728. Aluminum or steel products from a discriminating 16 country. 17 § 3721. Short title of subchapter. 18 This subchapter shall be known and may be cited as the Trade 19 Practices Act. 20 § 3722. Definitions. 21 The following words and phrases when used in this subchapter 22 shall have the meanings given to them in this section unless the 23 context clearly indicates otherwise: 24 "Aluminum or steel products made in a foreign country." 25 Aluminum or steel products rolled, formed, shaped, drawn, 26 extruded, forged, cast, fabricated or otherwise similarly 27 processed, or processed by a combination of two or more of these 28 operations, from aluminum or steel not made in the United 29 States. 30 "Court." The Commonwealth Court. 19830H1291B1524 - 89 -
1 "Discriminates." Any act, regulation or policy of a foreign 2 country which, directly or indirectly: 3 (1) Prevents the importation, sale or use of any 4 supplies, materials or equipment manufactured in this 5 Commonwealth. 6 (2) Grants or bestows a preference, discount or other 7 competitive advantage to supplies, materials or equipment 8 manufactured in the foreign country, the effect of which is 9 to place similar supplies, materials or equipment 10 manufactured in this Commonwealth at a competitive 11 disadvantage. 12 (3) Restricts the opportunities for persons having a 13 business situs in this Commonwealth to bid on or compete for 14 government contracts including, but not limited to, a 15 preference for residents of the foreign country. 16 (4) Solicits for awards or negotiates public works 17 contracts on a selective tender basis. 18 (5) Imposes discriminatory duties, tariffs or border 19 taxes on the importation of supplies, materials or equipment 20 not produced in the foreign country, the effect of which is 21 to place supplies, materials, or equipment manufactured in 22 this Commonwealth at a competitive disadvantage with like 23 goods manufactured in any foreign country. 24 (6) Adopts or condones any other unfair method of 25 competition in international trade including, but not limited 26 to, the exportation of aluminum or steel products made in the 27 foreign country through cartels or the subsidization of 28 aluminum or steel products. 29 "Importer." Any person registered and doing business in this 30 Commonwealth who engages in the receiving, storing, distributing 19830H1291B1524 - 90 -
1 or other processing of aluminum or steel products made in a 2 foreign country or who engages in the solicitation or acceptance 3 of orders or contracts for the furnishing of or supplying of 4 aluminum or steel products made in a foreign country. 5 "Public works." Any structure, building, highway, waterway, 6 street, bridge, pier, transit car or system, airport or other 7 betterment, work or improvement whether of a permanent or 8 temporary nature and whether for governmental or proprietary use 9 contracted for by any government agency or financed in whole or 10 in part by any government agency. 11 § 3723. Unlawful acts. 12 It is unlawful for: 13 (1) Any government agency to specify, purchase or permit 14 to be furnished or used, in any public works, aluminum or 15 steel products made in a foreign country which has been 16 determined as discriminating by the court. 17 (2) Any person to sell or offer for sale to any person, 18 for use in any public works, aluminum or steel products made 19 in a foreign country which has been determined as 20 discriminating by the court. 21 § 3724. Preference. 22 If all considerations in or affecting a bid or proposal or a 23 bidder or offeror are equal, each government agency shall give 24 preference to aluminum and steel products made in the United 25 States. 26 § 3725. Listing discriminating countries. 27 Every government agency shall include in all its invitations 28 for bids or requests for proposals, schedules or purchase orders 29 issued for public works a listing of the foreign countries which 30 have been found by the court to discriminate. 19830H1291B1524 - 91 -
1 § 3726. Determining discrimination. 2 (a) Petition.--Any government agency, importer or taxpayer 3 of this Commonwealth may file with the court a petition 4 specifically setting forth alleged discrimination by a foreign 5 country and praying for a determination. A copy of the petition 6 to the court and notice of the time of hearing set by the court 7 shall be served by registered mail, on the consular officer, if 8 any, of the country having an office in this Commonwealth and 9 upon a person in charge of the embassy of the foreign country in 10 Washington, D.C. 11 (b) Hearing.--Upon presentation of a petition filed pursuant 12 to subsection (a), the court shall make an order fixing a time 13 for a hearing. The hearing shall be fixed on a day not later 14 than 45 days after the filing of the petition. The 15 representative of the foreign country and any other interested 16 person may appear and present testimony at the hearing. At the 17 hearing, the court shall consider the statutes, regulations, 18 policies, procedures and practices of the foreign country 19 specified in the petition. 20 § 3727. Foreign registry docket. 21 (a) Entering name in docket.--If, after a hearing, the court 22 determines that the foreign country discriminates, it shall 23 direct the prothonotary of the court to enter the name of the 24 foreign country in a foreign registry docket maintained in the 25 office of the prothonotary. 26 (b) Striking name from docket.--Any foreign country 27 determined to be practicing discrimination may petition the 28 court to have its name stricken from the foreign registry 29 docket. The court shall grant the prayer of the petition if, 30 after hearing, it determines that the foreign country has 19830H1291B1524 - 92 -
1 discontinued and not engaged in discrimination for a period of 2 at least one year prior to the filing of the petition. Notice of 3 the filing of the petition shall be served upon the original 4 petitioner and all other parties to the original petition. 5 § 3728. Aluminum or steel products from a discriminating 6 country. 7 (a) General rule.--It is unlawful for any person, in the 8 performance of a public works contract, subcontract or purchase 9 order, to furnish aluminum or steel products made in a foreign 10 country that is listed on a foreign registry docket. The person 11 or any organization, corporation, partnership, business unit, 12 association or joint venture in which the person has a 13 substantial interest shall not be eligible to bid or submit an 14 offer on or be awarded any contract or subcontract or be issued 15 a purchase order for public works for a period of three years. 16 (b) Persons deemed not in violation.--Notwithstanding 17 subsection (a), a person shall not be held to have violated this 18 subchapter if he has not received notification of the listing as 19 provided in section 3725 (relating to listing discriminating 20 countries) or solely because his subcontractor or supplier of 21 materials violates this subchapter if the person had no 22 knowledge of the violation. 23 SUBCHAPTER D 24 USED OIL PRODUCTS 25 Sec. 26 3741. Preference. 27 § 3741. Preference. 28 As provided for in the act of April 9, 1982 (P.L.314, No. 29 89), known as the Pennsylvania Used Oil Recycling Act, 30 government agencies and persons holding contracts with 19830H1291B1524 - 93 -
1 government agencies shall encourage and, to the extent possible, 2 require the procurement and purchase of recycled oil products as 3 substantially equivalent to products made from new oil. 4 CHAPTER 39 5 CONSTRUCTION CONTRACTS OVER $50,000 6 Sec. 7 3901. Application of chapter. 8 3902. Definitions. 9 3903. Time for awarding contract. 10 3904. Time for executing contract. 11 3905. Release of successful bidder. 12 3906. Retainage. 13 3907. Payment of retainage to subcontractors. 14 3908. Final payment under contract. 15 3909. Arbitration. 16 § 3901. Application of chapter. 17 Except as otherwise specifically provided in this chapter, 18 this chapter applies to contracts entered into by a government 19 agency through competitive sealed bidding or competitive sealed 20 proposals. 21 § 3902. Definitions. 22 The following words and phrases when used in this chapter 23 shall have the meanings given to them in this section unless the 24 context clearly indicates otherwise: 25 "Contract." A contract exceeding $50,000 for construction as 26 defined in section 103 (relating to definitions). 27 "Substantial completion." Construction that is sufficiently 28 completed in accordance with the contract and certified by the 29 architect or engineer of the government agency, as modified by 30 change orders agreed to by the parties, so that the project can 19830H1291B1524 - 94 -
1 be used, occupied or operated for its intended use. In no event 2 shall a project be certified as substantially complete until at 3 least 90% of the work on the project is completed. 4 § 3903. Time for awarding contract. 5 (a) General rule.--In the case of a contract to be entered 6 into by a government agency through competitive sealed bidding, 7 the contract shall be awarded to the lowest responsible and 8 responsive bidder within 60 days of the bid opening or all bids 9 shall be rejected except as otherwise provided in this section. 10 (b) Delay.--If the award is delayed by the required approval 11 of another government agency, the sale of bonds or the award of 12 a grant, the contract shall be awarded to the lowest responsible 13 and responsive bidder within 120 days of the bid opening or all 14 bids shall be rejected. 15 (c) Extensions.--Thirty-day extensions of the date for the 16 award may be made by the mutual written consent of the 17 government agency and the lowest responsible and responsive 18 bidder. 19 § 3904. Time for executing contract. 20 In the case of a contract entered into by a government agency 21 through competitive sealed bidding, the contract shall be 22 executed by the government agency within 30 days of the date 23 that the contract is awarded. The successful bidder and the 24 government agency shall issue a notice to proceed unless the 25 time shall be extended by the mutual written consent of the 26 government agency and the successful bidder. 27 § 3905. Release of successful bidder. 28 Failure of the government agency to comply with the 29 requirements of sections 3903 (relating to time for awarding 30 contract) and 3904 (relating to time for executing contract) 19830H1291B1524 - 95 -
1 shall, unless the successful bidder waives the noncompliance by 2 written notice to the government agency, release the successful 3 bidder from any liability in respect to its bid or contract and 4 entitle all bidders to the immediate return of any bonds or 5 security deposits posted in connection with the bid or contract. 6 § 3906. Retainage. 7 (a) Contract provision.--A contract may include a provision 8 for the retainage of a portion of the amount due the contractor 9 to insure the proper performance of the contract, except that 10 the sum withheld by the government agency from the contractor 11 shall not exceed 10% of the amount due the contractor until 50% 12 of the contract is completed. When the contract is 50% 13 completed, one-half of the amount retained by the government 14 agency shall be returned to the contractor. However, the 15 architect or engineer must approve the application for payment. 16 The contractor must be making satisfactory progress and there 17 must be no specific cause for greater withholding. The sum 18 withheld by the government agency from the contractor after the 19 contract is 50% completed shall not exceed 5% of the value of 20 completed work based on monthly progress payment requests. In 21 the event a dispute arises between the government agency and any 22 prime contractor, which dispute is based upon increased costs 23 claimed by one prime contractor occasioned by delays or other 24 actions of another prime contractor, additional retainage in the 25 sum of one and one-half times the amount of any possible 26 liability may be withheld until a time as a final resolution is 27 agreed to by all parties directly or indirectly involved, unless 28 the contractor causing the additional claim furnishes a bond 29 satisfactory to the government agency to indemnify the agency 30 against the claim. All money retained by the government agency 19830H1291B1524 - 96 -
1 may be withheld from the contractor until substantial completion 2 of the contract. 3 (b) Department of General Services.--Notwithstanding 4 subsection (a), when the Department of General Services is the 5 government agency, the contract may include a provision for the 6 retainage of a portion of the amount due the contractor to 7 insure the proper performance of the contract, except that the 8 sum withheld by the department for the contractor shall not 9 exceed 6% of the then total estimates until 50% of the contract 10 is satisfactorily completed. The sum withheld by the department 11 from the contractor after the contract is 50% satisfactorily 12 completed shall not exceed 3% of the original contract amount. 13 § 3907. Payment of retainage to subcontractors. 14 In the absence of sufficient reason, within 20 days of the 15 receipt of payment by the contractor, the contractor shall pay 16 all subcontractors with whom he has contracted their earned 17 share of the payment the contractor received. 18 § 3908. Final payment under contract. 19 (a) Contract containing provision for retainage.--A contract 20 containing a provision for retainage as provided in section 3906 21 (relating to retainage) shall contain a provision requiring the 22 architect or engineer to make final inspection within 30 days of 23 receipt of the request of the contractor for final inspection 24 and application for final payment. If the work is substantially 25 completed, the architect or engineer shall issue a certificate 26 of completion and a final certificate for payment, and the 27 government agency shall make payment in full within 45 days 28 except as provided in section 3906, less only one and one-half 29 times the amount as is required to complete any then remaining 30 uncompleted minor items, which amount shall be certified by the 19830H1291B1524 - 97 -
1 architect or engineer, and upon receipt by the government agency 2 of any guarantee bonds which may be required, in accordance with 3 the contract, to insure proper workmanship for a designated 4 period of time. The certificate given by the architect or 5 engineer shall list in detail each uncompleted item and a 6 reasonable cost of completion. Final payment of any amount 7 withheld for the completion of the minor items shall be paid 8 upon completion of the items in the certificate of the engineer 9 or architect. 10 (b) Interest.--The final payment due the contractor from the 11 government agency after substantial completion of the contract 12 shall bear interest at a rate of 6% for all contracts without 13 provisions for retainage and at a rate of 10% for all contracts 14 with provisions for retainage, the interest to begin after the 15 date that such payment shall become due and payable to the 16 contractor. However, where the government agency has issued 17 bonds to finance the project, interest shall be payable to the 18 contractor at the rate of interest of the bond issue or at the 19 rate of 10%, whichever is less. 20 § 3909. Arbitration. 21 If a dispute should arise between the contractor and the 22 government agency over the payment of retainages and final 23 payment, then the dispute shall be arbitrated under the 24 applicable terms of the contract. If the contract contains no 25 provision for arbitration, then both parties may mutually agree 26 to arbitrate the dispute through the then obtaining rules of the 27 American Arbitration Association. In any event, either party 28 shall have the right of appeal from any decision and award as 29 provided by law. 30 CHAPTER 41 19830H1291B1524 - 98 -
1 PURCHASE OF SURPLUS FEDERAL PROPERTY 2 Sec. 3 4101. Contracts with United States. 4 4102. Bids and down payments. 5 § 4101. Contracts with United States. 6 Any government agency may enter into a contract with the 7 Federal Government for the purchase, lease or other acquisition, 8 including the warehousing and distribution, of any surplus real 9 or personal Federal property without complying with any 10 requirement of law as to specifications, advertising, award of 11 contract or approval by another government agency. However, any 12 Commonwealth agency may only enter into a contract authorized by 13 this section through the Department of General Services. 14 § 4102. Bids and down payments. 15 Any government agency authorized to enter into a contract 16 under section 4101 (relating to contracts with United States) 17 may designate by appropriate order an office holder or employee 18 of its own to enter a bid in its behalf at any sale of any 19 surplus real or personal Federal property and may authorize the 20 designee to make any down payment or payment in full required in 21 connection with the bidding. 22 CHAPTER 43 23 PUBLIC FACILITIES CONCESSIONS 24 Sec. 25 4301. Short title of chapter. 26 4302. Definitions. 27 4303. Terms of contracts. 28 § 4301. Short title of chapter. 29 This chapter shall be known and may be cited as the Public 30 Facilities Concession Regulation Act. 19830H1291B1524 - 99 -
1 § 4302. Definitions. 2 The following words and phrases when used in this chapter 3 shall have the meanings given to them in this section unless the 4 context clearly indicates otherwise: 5 "Public facility." Any building, airport, school, park, 6 hospital or other structure, grounds or place owned or operated 7 by a government agency, whether for governmental or proprietary 8 use. 9 § 4303. Terms of contracts. 10 (a) General rule.--Each government agency shall require that 11 every contract granting any concession, license, permit or right 12 to sell, lease, contract for or otherwise make available for 13 consideration goods or services to the public in any public 14 facility contain provisions giving the government agency the 15 right to regulate the kinds, quality and prices of the goods and 16 services, upon terms and conditions as may be appropriate. 17 (b) Exceptions.--This section is not intended to apply in 18 any of the following cases: 19 (1) Where the right to regulate price or quality is 20 vested exclusively in or has been preempted by the United 21 States or any of its agencies or another government agency. 22 (2) Where the head of the government agency, in writing, 23 determines that the retention of the right to regulate is not 24 necessary to protect the general welfare. 25 Section 4. This act is intended to provide a complete and 26 exclusive procedure to govern the procurement by Commonwealth 27 agencies of supplies, services and construction, including the 28 disposal of surplus supplies. This act is not intended to 29 enlarge or diminish the authority of any Commonwealth agency to 30 procure supplies, services and construction or to dispose of 19830H1291B1524 - 100 -
1 surplus property. However, the Commonwealth agency must procure 2 the supplies, services and construction or dispose of the 3 surplus supplies through the Department of General Services as 4 its purchasing agent unless the procurement or disposal is 5 exempted by 62 Pa.C.S. § 301 (relating to procurement 6 responsibility). 7 Section 5. The members of the Board of Claims appointed 8 pursuant to the act of May 20, 1937 (P.L.728, No.193), referred 9 to as the Board of Claims Act, repealed by this act, serving as 10 members when this act becomes effective shall continue to serve 11 as members of the board until the term for which they were 12 respectively appointed expires. 13 Section 6. (a) The following acts and parts of acts are 14 repealed: 15 Act of June 25, 1895 (P.L.269, No.182), entitled "An act 16 providing that none but citizens of the United States shall be 17 employed in any capacity in the erection, enlargement or 18 improvement of any public building or public work within this 19 Commonwealth." 20 Act of May 24, 1917 (P.L.260, No.141), entitled "An act 21 regulating the time for advertising for and receiving proposals 22 for furnishing paper, cardboard, cuts, plates, and other 23 supplies for the use of the Commonwealth for executing the 24 public printing, and the time contracts for furnishing such 25 supplies shall run." 26 Act of May 8, 1923 (P.L.161, No.120), entitled "An act 27 providing for and regulating the public printing and binding, 28 the editing for publication and the distribution of all 29 documents, reports, bulletins, and other publications for the 30 use of the Commonwealth, the several departments, boards, 19830H1291B1524 - 101 -
1 commissions, and other agencies engaged in the legislative, 2 judicial, and administrative work of the State Government; the 3 sale of waste paper; the appointment of a director and other 4 employes; and repealing inconsistent and conflicting 5 legislation." 6 Act of April 7, 1925 (P.L.189, No.137), entitled "An act 7 authorizing the Department of Property and Supplies under 8 certain conditions to exchange unservicable personal property of 9 this Commonwealth for, or on account of, the purchase price of 10 new personal property required by the Commonwealth." 11 Sections 478, 507, 508, 510, 511, 515, 522, 523, 709(i) and 12 as much of (j) as reads "to determine the number and type of 13 automobiles to be purchased by the Department of Property and 14 Supplies, acting either on its own behalf or as purchasing 15 agency for any other department, except the Department of the 16 Auditor General and the Treasury Department, or for any board or 17 commission, and", 2003(f), 2401.1(1), (2), (3), (5), (6), (7), 18 (8), (9), (10), (11) and (19), 2402(d), (i), (j) and (n), 2403, 19 2405, 2406(g), 2408, 2409, 2409.1, 2410, 2412 and 2413 of the 20 act of April 9, 1929 (P.L.177, No.175), known as The 21 Administrative Code of 1929. 22 Section 1809 of the act of June 24, 1931 (P.L.1206, No. 331), 23 known as The First Class Township Code. 24 Section 808 of the act of May 1, 1933 (P.L.103, No.69), known 25 as The Second Class Township Code. 26 Act of July 18, 1935 (P.L.1173, No.382), entitled "An act to 27 prohibit discrimination on account of race, creed or color in 28 employment under contracts for public buildings or public 29 works." 30 Act of July 19, 1935 (P.L.1321, No.414), entitled "An act 19830H1291B1524 - 102 -
1 requiring specifications for the construction, alteration, or 2 repair of public works of the Commonwealth, county, 3 municipality, or other subdivisions of the Commonwealth, to 4 contain a provision that the laborers or mechanics employed 5 thereon shall have been residents of this Commonwealth for at 6 least ninety days prior to their employment; and prescribing 7 penalties." 8 Act of May 20, 1937 (P.L.728, No.193), entitled, as amended, 9 "An act providing for the creation of a Board of Claims arising 10 from contracts with the Commonwealth; providing for and 11 regulating the procedure in prosecuting claims before such 12 board; defining the powers of the board; and fixing the 13 compensation of members and employes thereof; providing that the 14 awards of such board shall be final; providing for the payment 15 of awards; and authorizing an appropriation." 16 Section 1401(w), as much of the third sentence as reads 17 "direct, without prior confirmation of the Department of General 18 Services," and the penultimate sentence of section 1401(w) of 19 the act of June 3, 1937 (P.L.1225, No.316), known as The Game 20 Law. 21 Act of April 12, 1945 (P.L.220, No.99), entitled "An act 22 authorizing the Commonwealth and any administrative department, 23 boards, and commissions thereof acting through the Department of 24 Property and Supplies, and political subdivisions of the 25 Commonwealth, including municipal authorities, to enter into 26 contracts with the United States of America, or any agency 27 thereof, for the purchase, lease, or other acquisition of 28 property, real or personal, offered for sale pursuant to the 29 Surplus Property Act of one thousand nine hundred forty-four, 30 without complying with any requirement of existing law as to 19830H1291B1524 - 103 -
1 specifications, advertising, award of contract, and approval of 2 purchases by a State agency receiving competitive bids, or the 3 delivery of property purchased before payment therefor." 4 Sections 404, 404.1, 405 and 405.1 of the act of June 1, 1945 5 (P.L.1242, No.428), known as the State Highway Law. 6 Act of June 10, 1947 (P.L.493, No.223), entitled "An act 7 further prescribing the bonds required of foreign corporations 8 contracting for public buildings, public works or projects." 9 Section 10 of the act of July 5, 1947 (P.L.1217, No.498), 10 known as the State Public School Building Authority Act. 11 Sections 754 and 755 of the act of March 10, 1949 (P.L.30, 12 No.14), known as the Public School Code of 1949. 13 Section 11 of the act of March 31, 1949 (P.L.372, No.34), 14 known as The General State Authority Act of one thousand nine 15 hundred forty-nine. 16 Act of May 5, 1965 (P.L.40, No.34), entitled "An acting 17 authorizing the Commonwealth through the Department of Property 18 and Supplies and its duly authorized bureau or agents, to enter 19 into contracts with the United States of America or any agency 20 thereof, for the acquisition, acceptance, receipt, warehousing 21 and distribution of surplus property of the United States of 22 America pursuant to the 'Federal Property and Administrative 23 Services Act of 1949,' particularly section 203(j) and (k), as 24 amended, and Federal regulations appertaining thereto." 25 Section 1408 of the act of February 1, 1966 (1965 P.L.1656, 26 No.581), known as The Borough Code. 27 Section 12 of the act of December 6, 1967 (P.L.678, No.318), 28 known as The Pennsylvania Higher Educational Facilities 29 Authority Act of 1967. 30 Act of July 23, 1968 (P.L.686, No.226), entitled "An act 19830H1291B1524 - 104 -
1 equalizing trade practices in public works procurement; 2 authorizing the purchase by the Commonwealth, its political 3 subdivisions, and all public agencies, of aluminum and steel 4 products produced in a foreign country, provided the foreign 5 country does not prohibit or discriminate against the 6 importation to, sale or use in the foreign country of supplies, 7 material or equipment manufactured in this Commonwealth; 8 establishing procedures for determining whether foreign 9 countries discriminate against supplies, materials or equipment 10 manufactured in this Commonwealth; and imposing penalties and 11 providing for relief for violation of this act." 12 Section 4 of the act of November 20, 1968 (P.L.1075, No.329), 13 entitled "An act providing for the growth and development of 14 noncommercial educational television; creating the Pennsylvania 15 Public Television Network Commission as an independent 16 commission and defining its powers and duties." 17 Act of October 26, 1972 (P.L.1017, No.247), entitled "An act 18 relating to the prevention of environment pollution and the 19 preservation of public natural resources in construction 20 projects." 21 Act of March 3, 1978 (P.L.6, No.3), known as the Steel 22 Products Procurement Act. 23 Act of November 26, 1978 (P.L.1303, No.315), known as the 24 Public Facilities Concession Regulation Act. 25 Act of November 26, 1978 (P.L.1309, No.317), entitled "An act 26 awarding and execution of certain public contracts; providing 27 for contract provisions relating to the retention, interest and 28 payment of funds payable under the contracts; and repealing 29 inconsistent acts." 30 30 Pa.C.S. § 521(a)(12) (relating to establishment and use of 19830H1291B1524 - 105 -
1 fish fund) as much as reads "direct" and "in any amount, without 2 prior confirmation of the Department of General Services,". 3 (b) The following acts and parts of acts are repealed 4 insofar as they relate to Commonwealth agencies as defined in 62 5 Pa.C.S. § 103 (relating to definitions): 6 Act of June 12, 1879 (P.L.170, No.187), entitled "An act to 7 carry out the provisions of section twelve, article three, of 8 the constitution, relative to contracts for supplies for the 9 legislature and the various departments of the state 10 government." 11 Act of May 1, 1913 (P.L.155, No.104), entitled "An act 12 regulating the letting of certain contracts for the erection, 13 construction, and alteration of public buildings." 14 Act of June 23, 1931 (P.L.1181, No.321), entitled "An act 15 authorizing persons, co-partnerships, associations, and 16 corporations, who, whether as sub-contractor or otherwise, have 17 furnished material or supplied or performed labor in connection 18 with any public work or improvement, to intervene in or 19 institute actions on certain bonds given to the Commonwealth or 20 to municipal corporations in connection with the performance of 21 public contracts; fixing the time within which such actions must 22 be brought, and the amounts recoverable therein; and providing 23 for distribution of amounts recovered; and prescribing 24 procedure." 25 Act of December 20, 1967 (P.L.869, No.385), known as the 26 Public Works Contractors' Bond Law of 1967. 27 Act of January 23, 1974 (P.L.9, No.4), entitled "An act 28 prescribing the procedure, after the opening of bids, for the 29 withdrawal of bids on certain public contracts, setting forth 30 the rights of the parties involved and providing penalties." 19830H1291B1524 - 106 -
1 (c) The following acts and parts of acts are repealed 2 insofar as they are inconsistent with this act: 3 Act of May 14, 1915 (P.L.524, No.227), entitled "An act 4 creating a fund for the purpose of rebuilding, restoring, and 5 replacing buildings, structures, equipment, or other property of 6 the Commonwealth of Pennsylvania, damaged or destroyed by fire 7 or other casualty, and regulating the placing of insurance 8 thereon, and providing penalties for any violation of the 9 provisions of this act." 10 Sections 509, 1311(c.1), 1902-A(6), 1903-A, 1906-A(4), (8) 11 and (9), 1908-A(3), 1926-A, 2404 and 2407 of the act of April 9, 12 1929 (P.L.177, No.175), known as The Administrative Code of 13 1929. 14 Articles X and XI of the act of April 9, 1929 (P.L.343, 15 No.176), known as The Fiscal Code. 16 Section 10 of the act of August 7, 1936 (1st Sp. Sess., 17 P.L.106, No.46), entitled "An act relating to flood control; 18 prescribing the powers and duties of the Water and Power 19 Resources Board of the Department of Forests and Waters in 20 relation to the creation of flood control districts, adoption of 21 plans for flood control works and improvements, carrying into 22 effect of such plans, assistance, aid and cooperation with 23 public and private agencies and the Federal Government in 24 Federal flood control works and improvements, and entering into 25 compacts and agreements with other states for flood control 26 works and improvements; conferring the power of eminent domain; 27 imposing certain charges upon the Commonwealth; providing for 28 appeals; and conferring certain powers on municipalities, 29 counties, and townships, the Department of Highways and the 30 Department of Property and Supplies." 19830H1291B1524 - 107 -
1 Sections 906(b), (c) and (d), 907 and the first sentence of 2 section 1401(w) of the act of June 3, 1937 (P.L.1225, No.316), 3 known as The Game Law. 4 Sections 2009-A(9) and 2010-A(10) of the act of March 10, 5 1949 (P.L.30, No.14), known as the Public School Code of 1949. 6 Section 2 of the act of July 7, 1955 (P.L.258, No.82), 7 entitled "An act providing for anthracite mine drainage, 8 contingent on Federal aid, and making an appropriation." 9 Sections 206 and 443.5 of the act of June 13, 1967 (P.L.31, 10 No.21), known as the Public Welfare Code. 11 (d) Nothing in this act shall repeal, modify or supplant the 12 following acts and parts of acts: 13 Sections 516, 1908-A(1)(h) and 2801-A(j) of the act of April 14 9, 1929 (P.L.177, No.175), known as The Administrative Code of 15 1929. 16 Act of July 19, 1957 (P.L.1017, No.451), known as the State 17 Adverse Interest Act. 18 Act of August 15, 1961 (P.L.987, No.442), known as the 19 Pennsylvania Prevailing Wage Act. 20 Act of January 22, 1968 (P.L.42, No.8), known as the 21 Pennsylvania Urban Mass Transportation Law. 22 Act of February 11, 1976 (P.L.14, No.10), known as the 23 Pennsylvania Rural and Intercity Common Carrier Surface 24 Transportation Assistance Act. 25 (e) All other acts and parts of acts are repealed insofar as 26 they are inconsistent with this act. 27 Section 7. This act shall apply to contracts solicited or 28 entered into on or after the effective date unless the parties 29 agree to its application to a contract solicited or entered into 30 prior to the effective date. 19830H1291B1524 - 108 -
1 Section 8. This act shall take effect in 180 days. F14L62CM/19830H1291B1524 - 109 -