SENATE AMENDED PRIOR PRINTER'S NOS. 1785, 2559, 3261, PRINTER'S NO. 3577 3558
No. 1467 Session of 2005
INTRODUCED BY T. STEVENSON, DALLY, ARGALL, BALDWIN, BARRAR, BOYD, BUNT, CALTAGIRONE, CAPPELLI, CLYMER, CREIGHTON, DENLINGER, FAIRCHILD, GERGELY, GILLESPIE, GINGRICH, GRELL, HANNA, HERMAN, HUTCHINSON, KILLION, KOTIK, LaGROTTA, LEH, LESCOVITZ, LEVDANSKY, MACKERETH, MANN, MICOZZIE, R. MILLER, MUSTIO, NAILOR, PAYNE, PETRONE, PHILLIPS, REED, ROBERTS, ROSS, RUBLEY, SAYLOR, SCHRODER, SEMMEL, B. SMITH, SOLOBAY, SONNEY, R. STEVENSON, E. Z. TAYLOR, TIGUE, TRUE, TURZAI, WALKO, WILT, GEIST, McGILL, FRANKEL, BUXTON, REICHLEY, PYLE AND ALLEN, MAY 2, 2005
AS AMENDED ON THIRD CONSIDERATION, IN SENATE, FEBRUARY 14, 2006
AN ACT 1 Providing for dispute resolution procedures relating to 2 residential construction defects between contractors and 3 homeowners or members of associations. 4 The General Assembly of the Commonwealth of Pennsylvania 5 hereby enacts as follows: 6 Section 1. Short title. 7 This act shall be known and may be cited as the Residential 8 Construction Dispute Resolution Act. 9 Section 2. Definitions. 10 The following words and phrases when used in this act shall 11 have the meanings given to them in this section unless the 12 context clearly indicates otherwise: 13 "Action." A civil lawsuit, judicial action or arbitration
1 proceeding asserting a claim, in whole or in part, for damages 2 or other relief in connection with a dwelling caused by a 3 construction defect. 4 "Association." An association as defined under 68 Pa.C.S. §§ 5 3103 (relating to definitions), 4103 (relating to definitions) 6 and 5103 (relating to definitions). 7 "Claimant." Any person who asserts a claim concerning a 8 construction defect. The term includes an association. 9 "Construction defect." The term shall have the same meaning 10 assigned by a written express warranty either provided by the 11 contractor or required by applicable statutory law. If no 12 written express warranty or applicable statutory warranty 13 provides a definition, the term shall mean a matter concerning 14 the design or construction of a dwelling or addition to a 15 dwelling or an appurtenance to a dwelling on which a person has 16 a complaint against a contractor. The term may include any 17 physical damage to the dwelling or any appurtenance, or the real 18 property on which the dwelling or appurtenance is affixed, 19 proximately caused by a construction defect. 20 "Consultant." An engineer, architect, contractor, inspector 21 or other person purporting to have expertise relating to 22 residential construction or having that expertise as a result of 23 training or profession. 24 "Contractor." A person, firm, partnership, corporation, 25 association or other organization that is engaged in the 26 business of developing, constructing or selling newly 27 constructed dwellings or constructing additions or appurtenances 28 to an existing dwelling. The term includes an owner, officer, 29 director, shareholder, partner or employee of a contractor. For 30 purposes of this act, the term also includes an industrialized 20050H1467B3577 - 2 -
1 housing manufacturer. The term does not include a real estate 2 agent, broker or a contractor that installs a new device or 3 appurtenance which costs less than $2,000. 4 "Dwelling." A single-family house or duplex. The term 5 includes a multifamily unit STRUCTURE designed for residential <-- 6 use in which title to each individual unit is transferred to the 7 owner. Under a condominium or cooperative system, the term 8 includes common areas and improvements that are owned or 9 maintained by an association or by members of an association. 10 The term also includes the systems, other components, 11 improvements, other structures and recreational facilities that 12 are appurtenant to the house, duplex or multifamily unit <-- 13 STRUCTURE but not necessarily a part of the house, duplex or <-- 14 multifamily unit STRUCTURE. For purposes of this act, the term <-- 15 also includes industrialized housing. 16 "Industrialized housing." A structure designed primarily for 17 residential occupancy, and which is wholly or in substantial 18 part made, constructed, fabricated, formed or assembled in 19 manufacturing facilities for installation or assembly and 20 installation on the building site so that concealed parts or 21 processes of manufacture cannot be inspected at the site without 22 disassembly, damage or destruction. The term does not include a 23 structure or building classified as an institutional building or 24 manufactured home, as defined by the National Manufactured 25 Housing Construction and Safety Standards Act of 1974 (42 U.S.C. 26 §§ 5401-5426). 27 "Industrialized housing manufacturer." A person, firm, 28 partnership, corporation, association or other organization 29 involved in the process of making, constructing, fabricating, 30 forming or assembling, in a manufacturing facility, for 20050H1467B3577 - 3 -
1 installation or assembly and installation on the building site,
2 industrialized housing from raw, unfinished or semifinished
3 materials.
4 "Serve" or "service." For an individual, delivery by
5 certified mail, return receipt requested, to the last known
6 address of an addressee. For a corporation, limited partnership,
7 limited liability company or other registered business <--
8 organization, the term shall mean delivery to the registered
9 agent or other agent for service of process authorized by the
10 laws of this Commonwealth.
11 Section 3. Notice and opportunity to repair.
12 (a) Notice.--In every action subject to this act, the
13 claimant shall, no later than 75 days before initiating an
14 action against a contractor, provide service of written notice
15 of claim on the contractor. The notice of claim shall state that
16 the claimant asserts a construction defect claim or claims and
17 is providing notice of the claim or claims pursuant to the
18 requirements of this act. The notice of claim shall describe the
19 claim or claims sufficiently to explain the nature of the
20 alleged construction defects and IF KNOWN the results of the <--
21 defects.
22 (b) Service.--Service of the notice of the claim shall be
23 the equivalent of service of a lawsuit or demand for arbitration
24 with respect to imposing on the contractor a legal obligation to
25 pay as damages the cost of any repairs and/or monetary payment
26 made to settle the claim.
27 (c) Evidence.--In addition, the claimant shall provide to
28 the contractor any evidence known to the claimant or in the
29 claimant's possession that depicts the nature and cause of the
30 construction defect, including expert reports, photographs and
20050H1467B3577 - 4 -
1 videotapes, if the evidence would be discoverable under the <-- 2 State's evidentiary rules. If, after proper request, the 3 claimant fails to provide such evidence, the claimant shall not 4 be permitted to introduce any evidence not produced as evidence 5 in any action. VIDEOTAPES. IF EVIDENCE OF THE CLAIMANT IS <-- 6 DISCOVERED, DISCLOSED OR PRODUCED AFTER A CONTRACTOR'S OFFER, 7 THE CONTRACTOR MAY MAKE A NEW OFFER UNDER SECTION 5 WHICH SHALL 8 BE THE BASIS OF THE DETERMINATION OF ITS REASONABLENESS UNDER 9 SECTION 5(H) AND (I). 10 Section 4. Personal injury or death claims. 11 This act shall not apply to any claim for personal injury or 12 death. 13 Section 5. Procedure. 14 (a) Contents of notice.-- 15 (1) In an action under this act, the claimant shall, at 16 least 75 days before initiating the action against a 17 contractor, provide service of written notice of claim on the 18 contractor. The notice of claim shall: 19 (i) State that the claimant asserts a construction 20 defect claim and is providing notice of the claim 21 pursuant to the requirements of this act. 22 (ii) Describe the claim sufficiently to explain the 23 nature of the construction defect and the result of the 24 defect. 25 (iii) Include any evidence that describes the 26 construction defect that the claimant possesses. 27 (2) Service under this subsection shall toll all 28 applicable statutes of limitation until 75 days after receipt 29 of notice of the claim. 30 (b) Response.--Except as otherwise provided for under 20050H1467B3577 - 5 -
1 subsection (g), within 15 days after service of the notice of 2 claim, the contractor that has received the notice of claim 3 shall serve on the claimant and on any other contractor that has <-- 4 received the notice of claim a written response to the claim 5 which: 6 (1) offers to settle the claim by monetary payment, the 7 making of repairs or a combination of both, without 8 inspection, including a timetable for the making of the 9 payment or repairs; 10 (2) proposes to inspect at the contractor's expense the 11 dwelling that is the subject of the claim within 15 days; or 12 (3) rejects the claim. 13 (c) Inspection of dwelling.-- 14 (1) If the contractor requests the opportunity to 15 inspect the dwelling under subsection (b)(2), the claimant 16 shall provide the contractor and its consultants reasonable 17 and timely access to inspect the dwelling in order to 18 document the defect and perform any destructive or 19 nondestructive tests necessary to evaluate the claim. If 20 testing is performed, the CLAIMANT SHALL BE NOTIFIED OF <-- 21 TESTING AND SHALL BE PROVIDED THE OPPORTUNITY TO BE PRESENT 22 DURING TESTING. THE contractor shall return the dwelling to 23 its pretesting condition. 24 (2) If an inspection reveals a condition that requires 25 additional testing, the contractor shall provide prompt 26 notice to the claimant of the need for the additional 27 testing, and the claimant shall provide reasonable and timely 28 access to the dwelling. Additional testing, if necessary, 29 shall be completed within 15 days of the notice. 30 (3) If a claim is asserted on behalf of owners of 20050H1467B3577 - 6 -
1 multiple dwellings or multiple owners of units within a 2 multifamily complex, the contractor shall be entitled to 3 inspect each of the dwellings or units for which a defect has 4 been claimed. 5 (d) Process following inspection.--Within 15 days following 6 completion of an inspection or testing under subsection (c), the 7 contractor shall serve a written response INCLUDING COPIES OF <-- 8 ALL TEST REPORTS, EXPERT REPORTS, PHOTOGRAPHS AND VIDEO TAPES on 9 the claimant which: 10 (1) offers to settle the claim by monetary payment, the 11 making of repairs or a combination of both, including a 12 timetable for making the payment and/or repairs; or 13 (2) rejects the claim. 14 (e) Notice of claimant's response.-- 15 (1) The claimant shall accept or reject an offer by a 16 contractor under subsection (b)(1) or (d)(1) within 30 days 17 of receipt of the offer. 18 (2) If the claimant rejects the settlement offer made by 19 the contractor under subsection (b) or (d), the claimant 20 shall provide written notice of the claimant's rejection to 21 the contractor and include the specific reasons for the <-- 22 claimant's rejection. 23 (3) If the claimant fails to respond as required under 24 paragraph (1), the contractor's offer of monetary payment or 25 offer to repair shall be deemed to be rejected. 26 (4) After submitting notice under section 3, a claimant 27 may not initiate an action without conducting an in-person 28 meeting with the contractor in a good faith attempt to 29 resolve the dispute. In the case of an association claimant, 30 a majority of the association's board of directors shall 20050H1467B3577 - 7 -
1 attend the meeting. A meeting is not required if the 2 contractor has failed to timely respond to a claimant's 3 notice or refused or ignored a request for a meeting. 4 (f) Claimant's ability to bring an action.--If the 5 contractor: 6 (1) rejects the claim; 7 (2) does not respond to a notice of claim within the 8 time frames under this section; or 9 (3) does not make monetary payment or repair within the 10 proposed timetable of an accepted offer, the claimant may 11 bring an action against the contractor for the defect 12 described in the notice of claim without further notice, 13 notwithstanding the 75-day time period set forth under 14 subsection (a). 15 (g) Construction defects involving physical safety of 16 occupants.-- 17 (1) If a construction defect poses an imminent threat to 18 the physical safety of the occupants of the dwelling, the 19 notice shall so advise the contractor, and the deadline for 20 the contractor's initial response under subsection (b) shall 21 be seven days after receipt of the notice. 22 (2) If the contractor's response under subsection (b) 23 contains a request to inspect the dwelling, the contractor 24 shall arrange for the inspection within five days. 25 (3) If the contractor determines there is an imminent 26 threat to physical safety, the contractor shall provide the 27 claimant with a proposal for a monetary offer or offer to 28 repair within three days of the determination. 29 (4) Prior to the submission of an offer by the 30 contractor under this subsection, either the claimant or 20050H1467B3577 - 8 -
1 contractor may take interim repair steps to maintain the 2 structural integrity of the dwelling without prejudicing the 3 claimant's or contractor's claims or defenses. A CLAIMANT <-- 4 MAY, WITHOUT GIVING NOTICE TO THE CONTRACTOR, EMPLOY A 5 CONTRACTOR AND SUCH OTHER PERSONS AS ARE NECESSARY TO MAKE 6 SUCH IMMEDIATE REPAIRS TO A DWELLING AS ARE REQUIRED TO 7 PROTECT THE HEALTH, SAFETY AND WELFARE OF THE OCCUPANTS. 8 (h) Right of action.--If a claimant rejects a reasonable 9 monetary offer or reasonable supplemental monetary offer or does <-- 10 not permit the contractor to repair the defect pursuant to an 11 accepted offer to repair under subsection (e), the claimant may 12 not recover an amount in excess of: 13 (1) the fair market value of the offer to repair the 14 construction defect or the actual cost of the repairs, 15 whichever is less; or 16 (2) the amount of the monetary offer of settlement. 17 (i) Reasonableness of monetary offer or offer to repair.-- 18 (1) For purposes of this section, the trier of fact 19 shall determine the reasonableness of a monetary offer or <-- 20 offer to repair. AN OFFER. If the claimant has rejected a <-- 21 reasonable monetary offer or offer to repair, OFFER, the <-- 22 claimant may not recover costs or attorney fees incurred 23 after the date of rejection. 24 (2) If the contractor, through no fault of the claimant, 25 fails to make a reasonable offer, this act shall not limit 26 the remedies available to a claimant. 27 (j) Timely access for repairs.--If a claimant accepts a 28 contractor's offer to repair a construction defect, the claimant 29 shall provide the contractor and its subcontractors, agents, 30 experts and consultants reasonable and timely access to the 20050H1467B3577 - 9 -
1 dwelling to complete the repairs within the timetable set forth
2 under this section THE CONTRACTOR'S OFFER. <--
3 (k) Agreement between claimant and contractor.--Following
4 service under subsection (a), a claimant and a contractor may
5 alter the procedures under this act, including the tolling of
6 the statute of limitations, by mutual written agreement.
7 (l) Limitation of liability.--In an action involving a
8 construction defect, a contractor shall not be liable for
9 damages caused by:
10 (1) Normal shrinkage due to drying or settlement of
11 construction components with the tolerance of building
12 standards.
13 (2) The contractor's reasonable reliance on written
14 information relating to the dwelling that was obtained from
15 official government records or provided by a government
16 entity.
17 (3) Refusal of the claimant to REASONABLY allow the <--
18 contractor or the contractor's agents to perform their
19 warranty service work.
20 Section 6. Additional construction defects.
21 A construction defect that is discovered after a claimant has
22 served notice under section 3(a) (relating to notice and
23 opportunity to repair) may be alleged in an action provided the
24 claimant complies with the requirements of section 5 (relating
25 to procedure) with respect to the defect.
26 Section 7. Destructive test.
27 No claimant may employ a person to perform destructive tests
28 to determine any damage or injury to a dwelling caused by a
29 construction defect unless reasonable prior notice and
30 opportunity to observe the tests are given to the contractor
20050H1467B3577 - 10 -
1 against whom an action may be brought as a result of the test. 2 Section 8. Contractor employed by claimant. <-- 3 A claimant may, without giving notice to the contractor, 4 employ a contractor and such other persons as are necessary to 5 make such immediate repairs to a dwelling as are required to 6 protect the health, safety and welfare of the occupants. 7 Section 9 8. Construction. <-- 8 Nothing in this act shall be construed as establishing a 9 cause of action on behalf of any claimant or contractor. 10 Section 10 9. Notice required at time of contracting. <-- 11 (a) Form of notice.--Upon entering into a contract to 12 construct a dwelling, the contractor shall give the owner or 13 buyer a written notice worded substantially as follows: BUYER, <-- 14 AS THE CASE MAY BE, NOTICE OF THE CONTRACTOR'S RIGHTS TO OFFER 15 TO CURE CONSTRUCTION DEFECTS OR PAY TO SETTLE A CLAIM AGAINST 16 THE CONTRACTOR FOR CONSTRUCTION DEFECTS UNDER THIS ACT BEFORE A 17 CLAIMANT MAY COMMENCE AN ACTION FOR THE CONSTRUCTION DEFECTS. 18 THE NOTICE SHALL BE IN 10-POINT BOLD TYPE OR GREATER, SHALL BE 19 INCLUDED AS PART OF THE CONTRACT AND SHALL BE IN SUBSTANTIALLY 20 THE FOLLOWING FORM: 21 NOTICE CONCERNING CONSTRUCTION DEFECTS 22 Pennsylvania law contains important requirements you must 23 follow before you may file any A LEGAL action for <-- 24 defective construction against the contractor who 25 constructed your dwelling OR CONSTRUCTED YOUR ADDITION OR <-- 26 APPURTENANCE. Pennsylvania law requires you to deliver to <-- 27 the contractor a THAT YOU PROVIDE THE CONTRACTOR WITH <-- 28 written notice by certified mail of any construction 29 conditions that you believe are defective, with an <-- 30 opportunity to repair, before you file any action, and 20050H1467B3577 - 11 -
1 you must provide your contractor: 2 (1) The opportunity to make an offer to repair or 3 pay for the alleged defects. 4 (2) With any evidence in your possession that 5 described DESCRIBES the defect. If you do not disclose <-- 6 such evidence AFTER PROPER REQUEST, you will not be <-- 7 allowed to use the evidence in any action. YOU ALLEGE ARE <-- 8 DEFECTIVE, WITH ANY EVIDENCE IN YOUR POSSESSION THAT 9 DESCRIBED THE ALLEGED DEFECT SO THAT THE CONTRACTOR HAS 10 THE OPPORTUNITY TO MAKE AN OFFER TO REPAIR OR PAY FOR THE 11 ALLEGED CONSTRUCTION DEFECTS. 12 You are not obligated to accept any offer made by the 13 contractor, but failure to accept a reasonable offer, as 14 determined by a court or other trier of fact, may limit 15 your recoverable damages. There are strict deadlines and 16 procedures under State PENNSYLVANIA law, and failure to <-- 17 follow them may affect or impair your ability to file an <-- 18 action or to seek recovery for any A LEGAL ACTION TO SEEK <-- 19 RECOVERY FOR THE defects. There may also be requirements 20 which must be followed in a written warranty. It is 21 recommended that you consult with an attorney of your 22 choosing before entering into any agreement. IF YOU HAVE <-- 23 ANY QUESTIONS ABOUT YOUR RIGHTS AND OBLIGATIONS UNDER THE 24 LAW. 25 (b) Additional requirements.--The notice required under <-- 26 subsection (a) shall be in 10-point bold type or greater and 27 shall be included within the contract between the contractor and 28 potential claimant. 29 (c) (B) Failure to include notice.--Failure to include the <-- 30 notice IN CONTRACTS ENTERED INTO AFTER THE EFFECTIVE DATE OF <-- 20050H1467B3577 - 12 -
1 THIS ACT shall deprive the contractor of the benefits of this 2 act. 3 Section 11 10. Applicability. <-- 4 This act shall apply as follows: 5 (1) This act shall not affect a contractor's right to 6 seek contribution, indemnity or recovery against a 7 subcontractor, supplier or design professional for any claim 8 made against the contractor by a claimant. 9 (2) This act shall apply regardless of the date of sale <-- 10 or substantial completion of a dwelling, consistent with 42 11 Pa.C.S. § 5536 (relating to construction projects). 12 (3) (2) This act shall not restrict, modify or alter or <-- 13 otherwise interfere with the obligations, terms or conditions 14 of an insurance policy. 15 (4) (3) This act shall not apply to an insurer asserting <-- 16 a claim against a contractor for payments made by the insurer 17 pursuant to an insurance policy covering the dwelling. A 18 claim under this paragraph shall not be prejudiced, reduced 19 or otherwise modified because of the failure of the claimant 20 to comply with this act. 21 Section 12 20. Effective date. <-- 22 This act shall take effect in 60 days. C30L48MRD/20050H1467B3577 - 13 -